REMEDIES IN DEFAULT. On the occurrence of the Tenant Default and after the applicable notice and cure period, and subject to terms and conditions provided herein, Landlord may, without limiting Landlord in the exercise of any other right or remedy that Landlord may have by reason or such default, the remedies of Landlord hereunder being cumulative and not exclusive of one another: (a) perform on Tenant’s behalf, any unperformed covenant or obligation hereunder constituting such Tenant Default (after giving Tenant written notice of Landlord’s intention to do so except in the case of emergency), in which event Tenant shall reimburse Landlord for all expenses reasonably incurred by Landlord in doing so, plus interest at the Default Rate, which expenses and interest shall be additional rent and shall be payable by Tenant immediately on demand therefore by Landlord; and/or (b) terminate this Lease and collect liquidated damages from Tenant in an amount equal to (i) the sum of all amounts due hereunder to the date of termination; plus (ii) the aggregate rent remaining over the unexpired portion of the Term, plus the reasonable cost to Landlord of any repairs required to comply with Tenant’s obligations, all reduced to present value using a discount rate equal to the interest rate of a governmental security having a mutual closest to the then current expiration of the Term; less (iii) the aggregate fair net rental value of the Premises over the remaining portion of the Term (provided, however, a reasonable period of time, not to exceed twenty four (24) months, may be considered as a leasing period by which the Premises would not be leased and therefore no income would be realized for such period) reduced to present value at the above specified discount rate; plus (iv) Landlord’s costs and expenses incurred in the enforcement hereof including reasonable attorneys fees as herein provided, or (c) maintain Tenant’s right to possession, in which case this Lease shall continue in effect and Landlord shall be entitled to enforce all of Landlord’s right and remedies under this Lease, include the right to recover the Rent and other amounts payable hereunder as they become due hereunder.
REMEDIES IN DEFAULT. In the event of any such material default or breach by Tenant, Landlord may at any time thereafter, with or without notice or demand and without limiting Landlord in the exercise of a right or remedy which Landlord may have by reason of such default or breach:
A. Terminate Tenant's right to possession of the Premises by any lawful means, in which case this Lease shall terminate and Tenant shall immediately surrender possession of the Premises to Landlord. In such event Landlord shall be entitled to recover from Tenant all damages incurred by necessary renovation and alteration of the Premises, reasonable attorney's fees, any real estate commission actually paid, the worth at the time of award by the court having jurisdiction thereof of the amount by which the unpaid rent for the balance of the term after the time of such award exceeds the amount of such rental loss for the same period that Tenant proves could be reasonably avoided, that portion of the leasing commission paid by Landlord and applicable to the unexpired term of this Lease. Unpaid installments of rent or other sums shall bear interest from the date due at the rate of ten (10%) per cent per annum. In the event Tenant shall have abandoned the Premises, Landlord shall have the option of (a) taking possession of the Premises and recovering from Tenant the amount specified in this paragraph, or (b) proceeding under the provisions of the following Article 24.
REMEDIES IN DEFAULT. In the event of any default or breach of this Lease by Tenant (whether or not set forth in Section 23.1 above), Landlord may at any time thereafter, with or without notice or demand and without limiting Landlord in the exercise of a right or remedy which Landlord may have by reason of such default or breach:
REMEDIES IN DEFAULT. In the event of any such material default or breach by Tenant, Landlord may at any time thereafter, with or without notice or demand and without limiting Landlord in the exercise of a right or remedy which Landlord may have by reason of such default or breach:
24.a. Terminate Tenant's right to possession of the Premises by any lawful means, in which case this Lease shall terminate and Tenant shall immediately surrender possession of the Premises to Landlord. In such event Landlord shall be entitled to recover from Tenant all damages incurred by Landlord by reason of Tenant's default including, but not limited to, the cost of recovering possession of the Premises; expenses of reletting, including necessary renovation and alteration of the Premises, reasonable attorney's fees, any real estate commission actually paid; the worth at the time of award by (lie court having jurisdiction thereof of the amount by which the unpaid rent for the balance of the term after the time of such award exceeds the amount of such rental loss for the same period that Tenant proves could be reasonably avoided; that portion of the leasing commission paid by Landlord and applicable to the unexpired term of this Lease. Unpaid installments of rent or other sums shall bear
REMEDIES IN DEFAULT. In case of default by CONTRACTOR, CITY shall notify CONTRACTOR, in writing, of such abandonment, delay, refusal, failure, neglect, or default and direct CONTRACTOR to comply with all provisions of this Agreement. If the abandonment, delay, refusal, failure, neglect or default is not cured within seven (7) days of when notice was sent by CITY, CITY may declare a default of the Agreement and notify CONTRACTOR of such declaration of default and terminate the Agreement.
18.3.1. Upon such declaration of default, all payments remaining due CONTRACTOR at the time of default, less all sums due CITY for damages suffered, or expenses incurred by reason of default, shall be due and payable to CONTRACTOR.
18.3.2. CITY may complete the Agreement, or any part thereof, either by day labor or re- letting a contract for the same, and procure the equipment and the facilities necessary for the completion of the Agreement, and charge the cost of same to CONTRACTOR and/or the Surety together with the costs incident thereto to such default.
18.3.3. In the event CITY completes the Agreement at a lesser cost than would have been payable to CONTRACTOR under this Agreement, if the same had been fulfilled by CONTRACTOR, CITY shall retain such differences. Should such cost to CITY be greater, CONTRACTOR shall pay the amount of such excess to the CITY.
18.3.4 Notwithstanding the other provisions in this Article, CITY reserves the right to terminate the Agreement at any time, whenever the service provided by CONTRACTOR fails to meet reasonable standards of the trade after CITY gives written notice to the CONTRACTOR of the deficiencies as set forth in the written notice within fourteen calendar (14) days of the receipt by CONTRACTOR of such notice from CITY.
REMEDIES IN DEFAULT. IN the event on any such material default or breach by Tenant, Landlord may at any time thereafter, with or without notice or demand and without limiting landlord in the exercise of a right or remedy which Landlord may have by reason of such default or breach:
REMEDIES IN DEFAULT. In event of any default or breach, Landlord may, at any time without waiving or limiting any other right or remedy, reenter and take possession of the premises or terminated this Lease, or pursue any remedy allowed by law or equity. Tenant agrees to pay Landlord the cost of recovering possession of the Premises, the expenses or reletting, and any other costs or damages arising out of Tenant’s default including, without limitation, the costs of removing persons and property from the Premises, the costs of preparing or altering the Premises for reletting, broker’s commissions and legal fees not withstanding any reentry or termination, the liability of Tenant for the rent provided for therein shall not be extinguished for the balance of the term of this Lease, and Tenant covenants and agrees to make good to the Landlord any deficiency arising form reletting the Premises at a lesser rent than herein agreed to. Tenant shall pay such deficiency each month as the amount thereof as ascertained by the Landlord. 20.
REMEDIES IN DEFAULT. Upon the occurrence of a Default by Tenant, Landlord, without notice to Tenant (except where expressly provided for in this Lease or by applicable law) may do any one or more of the following:
14.2.1. Elect to terminate this Lease and the tenancy created hereby by giving notice of such election to Tenant, and reenter the Premises, without the necessity of legal proceedings, and remove Tenant and all other persons and property from the Premises, and may store such property in a public warehouse or elsewhere at the cost of and for the account of Tenant without resort to legal process and without Landlord being deemed guilty of trespass or becoming liable for any loss or damage occasioned thereby; and
14.2.2. Exercise any other legal or equitable right o remedy which it may have.
REMEDIES IN DEFAULT. Nonpayment of any amounts due hereunder shall constitute a default and breach of this Agreement by College. City agrees to provide College written Notice of Default. College shall remedy any default within ten (10) days of the date of Notice. In the event College fails to remedy a default, City may at any time thereafter avail itself of the following remedies which are cumulative and not exclusive:
a. City shall be entitled to recover from College all damages incurred by City by reason of College’s default, including, but not limited to, all payments due hereunder for upgrades to Xxxxxx Xxxx ball fields, the cost of recovering possession of the ball fields, interest in the maximum amount allowed by
REMEDIES IN DEFAULT. In the event of any default or breach, Landlord may, at any time without waiving or limiting any other right or remedy, reenter and take possession of the premises, or terminate this Lease, or pursue any remedy allowed by law or equity. Tenant agrees to pay Landlord the cost of recovering possession of the Premises, the expenses of reletting, and any other reasonable costs or damages arising out of Tenant's default, including, without limitation, the costs of removing persons and property from the Premises, the costs of preparing or altering the Premises for reletting, broker's commissions, and legal fees.
