Alternate Contractors Sample Clauses

Alternate Contractors. Except with respect to work regarding Substation Upgrade Facilities (which in all events shall be performed and/or controlled by Transmission Owner), Transco shall have the right, upon written notice to Transmission Owner and at its sole cost and expense, to obtain alternate contractors to perform the Services during any Force Majeure Event that prevents or delays Transmission Owner’s performance hereunder if the Force Majeure Event has or, in Transco’s reasonable judgment, threatens to have an adverse effect on Transco’s ability to conduct its operations (an “Alternate Contractor”); provided that Transmission Owner shall have no liability to Transco in respect of Services performed by an Alternate Contractor, and provided, further that any such Alternate Contractor satisfies and otherwise complies with Transmission Owner’s requirements, policies and procedures and with the requirements, if applicable, of the Lease. Transco shall ensure that any Alternate Contractor obtained pursuant to this agrees to comply with the terms and conditions of Article XIV hereof applicable to Transmission Owner while performing the Services in a Transmission Owner’s facility and shall remain liable to Transmission Owner in respect of any Alternate Contractor’s performance in accordance with §12.01.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Alternate Contractors. Owner shall have the right, upon written notice to Provider and at its sole cost and expense, to obtain alternate contractors to perform the Services during any Force Majeure Event that prevents or delays Provider’s performance hereunder if the Force Majeure Event has or, in Owner’s reasonable judgment, threatens to have an adverse effect on Owner’s ability to conduct its operations (an “Alternate Contractor”); provided that Provider shall have no liability to Owner in respect of Services performed by an Alternate Contractor. Owner shall ensure that any Alternate Contractor obtained pursuant to this Section 15.2 agrees to comply with the terms and conditions of Article IX hereof applicable to the Provider while performing the Services in a Provider facility and shall remain liable to Provider in respect of any Alternate Contractor’s performance in accordance with Section 18.1.‌
Sample 1
Alternate Contractors. Notwithstanding anything contained in this Article VII to the contrary, the Company shall be entitled to engage its own personnel to construct, operate and maintain the Complex and the Transmission Line or, in the case where the Construction Contract, the O&M Agreement or the O&M (Transmission) Agreement then in effect has been terminated by the Company in accordance with its terms, engage a new Contractor or some or all of the personnel of the former Contractors and construct, operate and maintain the Complex and the Transmission Line, in all cases without prior notice to the GOL.
Sample 1

Related to Alternate Contractors

  • Contractors All LAUSD Contractors and their Representatives are expected to conduct any and all business affiliated with LAUSD in an ethical and responsible manner that fosters integrity and public confidence. A “Contractor” is any individual, organization, corporation, sole proprietorship, partnership, nonprofit, joint venture, association, or any combination thereof that is pursuing or conducting business with and/or on behalf of LAUSD, including, without limitation, consultants, suppliers, manufacturers, and any other vendors, bidders or proposers. A Contractor’s “Representative” is also broadly defined to include any subcontractors, employees, agents, or anyone else who acts on a Contractor’s behalf.

  • Reasonable Overtime (a) There is a requirement to work reasonable overtime. Subject to that requirement being met, it is not compulsory for an Employee to work overtime in a particular case.

  • Subcontractors The Contractor will not subcontract any work under the Contract without prior written consent of the Department. The Contractor is fully responsible for satisfactory completion of all its subcontracted work. The Department supports diversity in its procurements and contracts, and requests that the Contractor offer subcontracting opportunities to certified woman-, veteran-, and minority-owned small businesses. The Contractor may contact the OSD at xxxxxxx@xxx.xxxxxxxxx.xxx for information on certified small business enterprises available for subcontracting opportunities.

  • SUBCONTRACTORS AND SUPPLIERS The Commissioner reserves the right to reject any proposed Subcontractor or supplier for bona fide business reasons, including, but not limited to: the company failed to solicit New York State certified minority- and women-owned business enterprises as required in prior OGS Contracts; the fact that such Subcontractor or supplier is on the New York State Department of Labor’s list of companies with which New York State cannot do business; the Commissioner’s determination that the company is not qualified or is not responsible; or the fact that the company has previously provided unsatisfactory work or services.

  • Requirement to Work Reasonable Overtime 6.4.2(a) Subject to clause 6.4.2(b) an employer may require an employee to work reasonable overtime at overtime rates.

  • Selection of Subcontractors Procurement of Materials and Leasing of Equipment: The contractor shall not discriminate on the grounds of race, color, religion, sex, sexual orientation, gender identity, national origin, age, or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.

  • CONTRACTOR's Agents and Subcontractors To impose the same restrictions and conditions set forth in this Personal Information and Security Contract on any subcontractors or other agents with whom CONTRACTOR subcontracts any activities under the Agreement that involve the disclosure of DHCS PI or PII to such subcontractors or other agents.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!