Avoidance of Labor Disputes Sample Clauses

Avoidance of Labor Disputes. In constructing or causing its contractor to construct, Alterations (as defined in Section 14.1) and Tenant's Work (as defined in Exhibit C) and throughout the Lease Term, Tenant shall conduct its activities in such a manner as to avoid any labor dispute which causes or is likely to cause stoppage or impairment of work, deliveries or any other services in the Project. If there shall be any such stoppage or impairment as the result of any such labor dispute or potential labor dispute, Tenant shall immediately undertake such action as may be necessary to eliminate such dispute or potential dispute, including (a) removing all disputants from the job site until such time as the labor dispute no longer exists, (b) seeking a temporary restraining order and other injunctive relief with regard to illegal union activities or a breach of contract between Tenant and Tenant's contractor, and (c) filing appropriate unfair labor practice charges. Should Landlord incur or sustain any Claims (as defined in Section 17.1) in connection with any such labor dispute or potential labor dispute, the provisions of Section 17.1 shall apply regardless of whether Tenant has performed its duties under this Section 30.5.
AutoNDA by SimpleDocs
Avoidance of Labor Disputes. During Tenant’s construction of Tenant’s Work, Tenant agrees to conduct its labor relations so as to minimize the chances of strikes, picketing, and boycotts which could delay completion of Tenant’s Work or affect any other construction then occurring in the Building or on the Property. Tenant shall ensure that any pickets or boycotts resulting from such labor disputes are sufficiently contained within the Leased Premises so as to avoid a secondary boycott or picket line which could affect other construction then occurring in the Building or on the Property. Tenant also agrees to include within any construction contract it may execute, language requiring the general contractor to, in the event of a labor dispute: (a) find alternative labor to complete Tenant’s Work on schedule; or (b) terminate the construction contract and cease its activities as general contractor for Tenant’s Work. This Section shall also apply to Tenant’s construction of any Tenant Alterations.
Avoidance of Labor Disputes. During the period of any construction by Tenant on or within the Premises, Xxxxxx will conduct the labor relations of Tenant so as to avoid strikes, picketing and boycotts which would delay completion of the work of Tenant. Tenant will include within any construction contract Tenant may execute, language to the effect that the general contractor agrees that if a labor dispute occurs, the general contractor will either find alternative labor to complete the project on schedule, or terminate the construction contract and cease the activities of general contractor as general contractor on the Premises.
Avoidance of Labor Disputes. 3.10.7 Use DOTA-Approved Entrances, Roads, Access Ways

Related to Avoidance of Labor Disputes

  • Absence of Labor Disputes No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, which would reasonably be expected to result in a Material Adverse Effect.

  • Absence of Labor Dispute No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, and the Company is not aware of any existing or imminent labor disturbance by the employees of any of its or any subsidiary’s principal suppliers, manufacturers, customers or contractors, which, in either case, would result in a Material Adverse Effect.

  • NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority. (b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.

  • No Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is contemplated or threatened, and the Company is not aware of any existing or imminent labor disturbance by, or dispute with, the employees of any of its or its subsidiaries’ principal suppliers, contractors or customers, except as would not have a Material Adverse Effect.

  • Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its Subsidiaries exists or, to the knowledge of the Company, is threatened which would reasonably be expected to result in a Material Adverse Effect.

  • Litigation, Labor Controversies, etc There is no pending or, to the knowledge of the Borrower, threatened litigation, action, proceeding, or labor controversy affecting the Borrower or any of its Subsidiaries, or any of their respective properties, businesses, assets or revenues, which could reasonably be expected to have a Material Adverse Effect, except as disclosed in Item 6.7 ("Litigation") of the Disclosure Schedule.

  • No Labor Dispute No labor disturbance by or dispute with the employees of any of the Partnership Entities exists or, to the knowledge of the Partnership Parties, is imminent or threatened that could reasonably be expected to have a Material Adverse Effect.

  • Labour Disputes 15.01 If employees are prevented from performing their duties because of a strike or lock-out on the premises of another employer, the employees shall report the matter to the Employer, and the Employer will make reasonable efforts to ensure that such employees are employed elsewhere, so that they shall receive their regular pay and benefits to which they would normally be entitled.

  • GRIEVANCE ARBITRATION PROCEDURE 8.01 For purposes of this Agreement, a grievance is defined as a difference arising between the parties relating to the interpretation, application, administration or alleged violation of the Agreement, including any question as to whether a matter is arbitrable. 8.02 In all steps of this Grievance Procedure, the aggrieved nurse, if desired, may be accompanied by or represented by a nurse representative. 8.03 It is the mutual desire of the parties hereto that complaints of the nurses shall be adjusted as quickly as possible, and it is understood that a nurse has no grievance until she has first given the Unit Manager the opportunity of adjusting her complaint. Such complaint shall be discussed with the Unit Manager within ten (10) days after the circumstances giving rise to it have occurred or ought reasonably to have come to the attention of the nurse and failing settlement within five (5) days, it shall then be taken up as a grievance within ten (10) days following the Unit Manager's decision in the following manner and sequence: The nurse may submit a written grievance on the form set out in Appendix "A", signed by her, to the Unit Manager. The grievance shall identify the nature of the grievance and the remedy sought and should identify the provisions of the Agreement which are alleged to be violated. The Unit Manager will deliver her decision in writing within five (5) days of the submission of the grievance. Failing settlement, then: Within five (5) days following the decision in Step No. 1, the nurse may submit the written grievance to the Director of Resident Care who will deliver her decision, in writing, within five (5) days from the date on which the written grievance was presented to her. The parties may, if they so desire, meet to discuss the grievance at a time and place suitable to both parties. Failing settlement, then: Within ten (10) days of receiving the decision under Step 2, the grievance, in writing, may be referred to the Chief Executive Officer who shall call a meeting of the Grievance Committee within five (5) days of receipt of same. Within five (5) days following the meeting, the Chief Executive Officer shall reply, in writing, to the nurse and the Chairperson of the Grievance Committee. If the decision is unsatisfactory to the nurse, it may be referred to arbitration within fifteen (15) days and the Chief Executive Officer so notified, in writing.

  • GRIEVANCE AND ARBITRATION PROCEDURE 8.01 The parties to this agreement believe it is important to adjust complaints and grievances as quickly as possible as provided for herein. The employee or Union shall first discuss any individual complaint informally with the Director of Care or designate at the first opportunity. 8.02 In all steps of this grievance procedure an aggrieved employee, if she so desires may be accompanied by or represented by her Union Representative. At Step 1 of the grievance procedure a representative of the Ontario Nurses' Association may be present at the request of either party. 8.03 Should any dispute arise between the Employer and an employee, or between the Employer and the Union, as to the interpretation, application, administration or alleged violation of any of the provisions of this Agreement, the employee or Union Representative will bring it to the attention of the immediate supervisor to settle such differences within ten (10) days of the occurrence. If further action is to be taken, then within ten (10) days of the discussion, the employee, who may request the assistance of her Union Representative and/or Labour Relations Officer, shall submit the written grievance to the Administrator or designate. A meeting will be held between the parties within ten (10) days. The Administrator shall give a written decision within ten (10) days of the meeting to the Bargaining Unit President or her designate with a copy to the Labour Relations Officer. Should the Administrator fail to render his decision or failing settlement of any grievance under the foregoing procedure, including any questions as to whether a matter is arbitrable, the grievance may be referred to arbitration by either party. If no written notice of intent to submit the matter for arbitration is received within ten (10) days after the decision under Step No. 1 is received, the grievance shall be deemed to have been settled or abandoned. 8.04 A written grievance will indicate the nature of the grievance and the remedy sought by the grievor. Union grievances shall be set out on the union grievance form. Alternately, the parties may agree to an electronic version of this form and a process for signing. 8.05 Time limits fixed in the grievance and arbitration procedures may be extended only by written, mutual consent of the parties. Should the Employer not respond within the time limit(s) fixed, such failure to respond shall be deemed to be a denial of the grievance. Should a grievance not be submitted within the various time limits specified in this Agreement, unless mutually extended, it shall be considered to have been settled or abandoned.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!