Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.
Claims for Additional Costs 11.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum not related to a requested change, it shall give the Owner and the A/E written notice thereof within twenty-one (21) days after the occurrence of the event giving rise to such claim, but, in any case before proceeding to execute the work considered to give rise to the additional cost or time, except in an emergency endangering life or property in which case the Contractor shall act in accordance with Article 7.2.1. No such claim shall be valid unless so made. If the Owner and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined as set forth under Article 15. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.
CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
APPEAL ACTIONS Appeal of TMA actions under this agreement, to the extent they are allowable, will be pursuant to 32 CFR 199.10.
TIME LIMIT ON CERTAIN DEFENSES The policy’s Time Limit On Certain Defenses provision will apply to this rider as of the effective date of this rider.
Step 3 – Contract Language Disputes (a) If a grievance concerning the interpretation or application of this Agreement, other than a grievance alleging that a disciplinary action (reduction in base pay, demotion, involuntary transfer of more than 50 miles by highway, suspension, or dismissal) was taken without cause, is not resolved at Step 2, the grievant or designated representative may appeal the grievance by submitting it to the Office Manager for the Office of the General Counsel of the Department of Management Services, 0000 Xxxxxxxxx Xxx, Xxxxx 000, Xxxxxxxxxxx, Xxxxxxx, 00000-0950, or by email to: Xxxx0Xxxxxxxxxx@xxx.xxxxxxxxx.xxx within 15 days following receipt of the decision at Step 2. The grievance shall include a copy of the grievance forms submitted at Steps 1 and 2, together with all written responses and documents in support of the grievance. When the grievance is eligible for initiation at Step 3, the grievance shall be filed on the grievance form contained in Appendix B of this Contract, setting forth specifically the facts on which the grievance is based, the specific provision(s) of the Contract allegedly violated, and the relief requested.
Effective Date of Settlements Settlements reached at any step of the grievance procedure in this article, other than Clause 8.11, shall be applied retroactively to the date of the occurrence of the action or situation which gave rise to the grievance, but not prior to the effective date of the agreement in effect at the time of the occurrence or the date set by a board of arbitration.
