Food Service Waste Reduction Requirements Contractor shall comply with the Food Service Waste Reduction Ordinance, as set forth in San Francisco Environment Code Chapter 16, including but not limited to the remedies for noncompliance provided therein.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Federal Medicaid System Security Requirements Compliance Party shall provide a security plan, risk assessment, and security controls review document within three months of the start date of this Agreement (and update it annually thereafter) in order to support audit compliance with 45 CFR 95.621 subpart F, ADP System Security Requirements and Review Process.
Prescription Safety Glasses Prescription safety glasses will be furnished by the employer. The employer retains the authority to establish reasonable rules and procedures regarding frequency of issue, replacement of damaged glasses, limits on reimbursement costs and coordination with the employer's vision plan.
Safety Footwear 1. The State will provide employees in the positions listed in Section 3 below, and employees who are currently required to wear safety footwear by Department Work Rules, an allowance of one hundred fifty dollars ($150.00) for replacement of safety footwear. This allowance will be paid to employees on a semiannual basis, with half paid in January and half paid in July to eligible employees on the payroll at the time of the payments. Employees of Departments with work rules that provide such safety footwear will not be eligible for the safety footwear allowance.
2. Safety footwear purchased must meet ANSI standards where applicable. Requirements for the wearing of safety footwear will be in accordance with work rules published by the State.
3. Positions required to wear safety footwear:
Switching System Hierarchy and Trunking Requirements For purposes of routing ECI traffic to Verizon, the subtending arrangements between Verizon Tandem Switches and Verizon End Office Switches shall be the same as the Tandem/End Office subtending arrangements Verizon maintains for the routing of its own or other carriers’ traffic (i.e., traffic will be routed to the appropriate Verizon Tandem subtended by the terminating End Office serving the Verizon Customer). For purposes of routing Verizon traffic to ECI, the subtending arrangements between ECI Tandem Switches and ECI End Office Switches shall be the same as the Tandem/End Office subtending arrangements that ECI maintains for the routing of its own or other carriers’ traffic.
Fire Safety Resident will not tamper with fire alarms, smoke detectors, fire extinguishers, fire hoses, or exit signs. Resident will promptly evacuate Residence Facility upon the sounding of an alarm or as otherwise directed by College Housing staff. Resident will participate in any periodic fire drill and fire safety training conducted by College for the Residence Facility.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
