Compensation for Extra Services Sample Clauses

Compensation for Extra Services of CONSULTANT authorized in accordance with Paragraph 10 of this Agreement, shall be paid to CONSULTANT by CITY in accordance with said fee schedule. CONSULTANT shall only be entitled to payment for Extra Services under this Agreement if CONSULTANT has obtained authorization required under Paragraph 10 below.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Compensation for Extra Services. Contractor’s Extra Service Compensation shall be the compensation provided to Contractor for services that are not included in the Base Compensation. These services include: A. Backyard/Sideyard Collection of Solid Waste from Single-Family Premises. B. Drop box service (scheduled and on-call). C. Residential and Commercial/Industrial Compostable Materials processed. D. Overweight debris boxes (boxes weighing over 5 tons). E. Compost supplied by Contractor for Giveaways F. Contaminated Recyclable Materials G. Construction Related Materials as detailed in Attachment T H. Miscellaneous construction material; and I. New Recyclable Materials fees beginning on July 1, 2021 as described in Section 9.06. The Contractor shall be compensated on a unit-price basis for each of the extra services performed. Following completion of each calendar quarter, the Extra Service Compensation shall be calculated by the Contractor based on its billing records and billing reports submitted. The Extra Services Compensation shall equal the sum of each unit-price fee multiplied by the number of extra services performed by Contractor during each month in the most-recently completed calendar quarter. The City will pay the Contractor on a quarterly basis in arrears for all extra service performed. The Contractor’s unit-prices for Rate Periods One and Two were based on the Contractor’s Proposal and were presented in Attachment N-1 to the original Agreement. These unit prices are adjusted annually to reflect changes in a specified cost index in accordance with the procedures described in Attachment N-2. Revised Attachment N-1 shows the adjusted prices for Rate Periods Ten and Eleven and the unit prices for the extra services added through this Agreement as amended and restated. Contractor shall not be compensated for extra services other than those specified in this Section. The City may charge Customers additional fees for services such as collection of extra Bulky Items, but Contractor shall not receive extra compensation for these services. Contractor shall keep accurate and complete records of services billed by Contractor to allow City to verify the accuracy of Contractor’s billing reports and to calculate compensation for extra services.
Sample 1Sample 2
Compensation for Extra Services. Contractor’s Extra Service Compensation shall be the compensation provided to Contractor for services that are not included in the Base Compensation. These services include: A. Backyard/Sideyard Collection of Solid Waste from Single-Family Premises. B. Collection of Solid Waste, Recyclable Materials and Yard Trimmings from hard-to-service areas identified in Attachment C. C. Drop box service (scheduled and on-call).
Sample 1
Compensation for Extra Services. Straight time compensation for extra services shall be as follows except as provided in Section 14.3: 2016 2017 2018 (A) A ninth (9th) service will be paid at time-and one-half. (B) A tenth (10th) service will be paid at double time. (C) If nine (9) or more service weeks are consecutive, all ninth (9th) services after the first week are paid at time and one-half, all tenth (10th) services after the first week are paid at double time.
Sample 1
Compensation for Extra Services. 5.2.1 Payment for Architect’s extra services, as described in Section 4.10, shall be authorized and determined in the following manner: .1 At its discretion, the District may elect to negotiate a fixed fee for extra services; or .2 For work performed by Principals and employees of the Architect, the Architect shall receive an amount not to exceed established hourly rates (as indicated in the Work Authorization (Exhibit “A”), for actual time expended to provide the authorized extra services. The Architect shall provide a rate sheet at the onset of the project listing rates applicable to this Project within the limits listed above or, .3 For work performed by firms or individuals not employees of the Architect (and which Architect is not qualified to perform), but engaged by the Architect to assist in providing the authorized extra service, the Architect shall receive one and one tenth (1.10) times the amount to be paid by the Architect to the consultants for said services.
Sample 1
Compensation for Extra Services. Compensation for extra services shall be paid in accordance with the Schedule of Extra Services (Appendix E) as a separate check issued in December, March and May. The extra duty salary schedule shall be reviewed annually. The schedule will receive the same percentage adjustment as the certificated salary schedule.
Sample 1
Compensation for Extra Services. A. Meal Allowance
Sample 1
AutoNDA by SimpleDocs
Compensation for Extra Services. ENRON shall pay UNIVERSAL for labor involved in the performance of Extra Services in accordance with Section 4. (b). "Extra Services" shall consist of repairs, maintenance or other activity requested by ENRON from time to time that is not set forth in the Proposal. UNIVERSAL shall perform such Extra Services in compliance with the standards and requirements of Southwestern Public Service Company (including but not limited to timeliness of performance and availability of equipment, supplies and materials on a non-discriminatory basis) or with such standards and requirements as ENRON may reasonably require. ENRON may, at its sole option, provide materials and equipment for Extra Services. Should UNIVERSAL supply materials required for performance of the Extra Services, ENRON shall reimburse UNIVERSAL for the cost of any such materials required for the performance of Extra Services, plus a handling fee of 10%. Amounts owing under this section shall be due and payable no later than thirty days after UNIVERSAL delivers an invoice to ENRON. Invoices shall be submitted in duplicate to ENRON at the address set forth below with such documentation evidencing expenditures or charges as ENRON may reasonably request. ENRON may inspect and audit UNIVERSAL'S records pertaining to compensation for Extra Services during business hours at UNIVERSAL'S offices upon five days' notice.
Sample 1

Related to Compensation for Extra Services

  • Compensation for Consulting Services For each quarter (i.e., three-month period) that Executive provides consulting services to MediciNova pursuant to the option of MediciNova contained in Section 9 above, MediciNova shall pay Executive a sum equal to fifteen percent (15%) of Executive’s annual Base Compensation which shall be applicable at the time of Executive’s termination of employment with MediciNova (prorated for any period of less than a quarter). The parties expressly agree that when Executive is performing consulting services for MediciNova, Executive is acting as an independent contractor. Therefore, Executive shall be solely liable for Social Security and income taxes that result from Executive’s compensation as a consultant. In addition, Executive shall not be entitled to any other benefits including, without limitation, such group medical, life and disability insurance and other benefits as may be provided to employees and/or executives of MediciNova.

  • Developer Compensation for Emergency Services If, during an Emergency State, the Developer provides services at the request or direction of the NYISO or Connecting Transmission Owner, the Developer will be compensated for such services in accordance with the NYISO Services Tariff.

  • Compensation for Basic Services A. Owner shall make payment for Part I and Part II services monthly. The payments shall be in proportion to the progress of Engineer's work. Final payment for each phase shall become due and payable upon completion and approval by Owner of that phase of Engineer's work. B. Owner shall make payment for Construction Phase services not more frequently than monthly in proportion to the amount of the gross progress payments to Contractor(s). C. Owner shall make no deduction from Engineer's compensation on account of penalties, liquidated damages or other sums withheld from Contractor(s) through no fault of Engineer. D. Owner shall make payment for Construction Completion Phase services upon completion of the requirements set forth in subsections II. F. 1, 2 and 3. E. Engineer shall submit requests for payment monthly on forms provided and in a manner prescribed by Owner.

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • Services and Compensation Consultant shall perform the services described in Exhibit A (the “Services”) for the Company (or its designee), and the Company agrees to pay Consultant the compensation described in Exhibit A for Consultant’s performance of the Services.

  • COMPENSATION OF ULTIMUS The Trust, on behalf of each Fund, shall pay for the services to be provided by Ultimus under this Agreement in accordance with, and in the manner set forth in, Schedule B attached hereto, as such Schedule may be amended from time to time. If this Agreement becomes effective subsequent to the first day of a month or terminates before the last day of a month, Ultimus’ compensation for that part of the month in which the Agreement is in effect shall be prorated in a manner consistent with the calculation of the fees as set forth above. Payment of Ultimus’ compensation for the preceding month shall be made promptly.

  • Compensation for Services You may be eligible to receive compensation for providing certain services in respect of Shares of the Funds if you meet the requirements of and enter into a Bank Services Agreement with American Funds Service Company.

  • Compensation for Overtime Assigned overtime is designated as those hours over the regular hours of work which are requested of the employee by management. Assigned overtime worked shall be paid at the rate of time and one-half (1 1/2).

  • Compensation Review The compensation of the Executive will be reviewed not less frequently than annually by the board of directors of the Company.

  • Director Compensation Petitioner shall not compensate members of the Charter School’s Governing Board in excess of reasonable expenses incurred in connection with actual attendance at board meetings or with performance of duties associated therewith.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!