Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Vacation Scheduling (a) Employees shall indicate their vacation preference by February 1st of each year, and the Employer shall post the final vacation schedule by April 1st of each year. Choice of vacation period shall be based on seniority but shall be determined by the Director of Resident Care or designate having due regard to the proper operation of the Home. Vacation requests made after the posting of the vacation schedule shall be determined by the Director of Care or designate having due regard to the proper operation of the Home on a first come first serve basis, not on seniority. (b) Vacations may be taken at any time of year, and the Employer will grant request where possible, provided that vacation quotas shall not be unduly restrictive, and vacation shall not be unreasonably withheld. The Employer will give consideration to an employee’s request for vacation between the period of December 15 and January 15, provided the employee will be fulfilling her or his commitment to work either Christmas or New Year’s. (c) Employees may request pursuant to Article 13.08 to have the weekend off prior to or following their vacation. The Employer will endeavour to schedule such request subject to the following: i) Where the weekend off is granted and the employee was otherwise scheduled to work on those days, such extra days will be deemed to be vacation days; ii) The employee must have such vacation entitlement available; and, iii) The weekend off being requested must be contiguous with (i.e. consecutive with) the employee’s original vacation. (d) Prior to leaving on vacation, an employee shall be notified of the date on which to report back for work following vacation if the posted work schedule does not cover the employees’ vacation period, if the information is known to the employer. (e) Full-time employees will be granted time off in single days or multiples thereof upon request, provided the employer agrees to that request. The maximum allotment of these days will be five (5) days.
Allocation Schedule Attached hereto as Exhibit J is an Allocation Schedule, prepared by the Company for illustrative purposes, setting forth: (i) the name of each Company Equity Interest holder; (ii) the number and type of Company Equity Interests held by each such Company Equity Interest holder; (iii) the Fully Diluted Number as of the Execution Date, and the portion thereof attributable to each Company Equity Interest holder; and (iv) the amount of Equity Consideration attributable to each such Company Equity Interest holder’s Company Equity Interests in accordance with the Company LLCA and this Agreement. No later than ten Business Days prior to the Closing, the Company shall deliver to the Buyer an updated Allocation Schedule, prepared in conformance with the principles set forth in Exhibit J, which shall be updated to reflect: (A) the JDA Share Adjustment Amount as of the Closing Date; (B) the Interim Company Financing Cash; (C) the calculation of the Equity Consideration; and (D) the Fully Diluted Number as of the Closing Date; and thereby set forth the final allocation of the Equity Consideration among the holders of Company Equity Interests as of the Effective Time in accordance with the Company LLCA and this Agreement. Following the delivery thereof, the Company will provide the Buyer and their accountants and other Representatives with a reasonable opportunity to review the Allocation Schedule. At least two Business Days prior to the Closing Date, the Buyer may notify the Company of any comments or questions with respect to the Allocation Schedule and the Company shall (x) consider in good faith such comments or questions and (y) prepare and deliver an updated Allocation Schedule to the Company prior to the Closing Date reflecting any agreed upon changes resulting from such comments or questions. Notwithstanding the foregoing, the Allocation Schedule ultimately delivered by the Company to the Buyer in accordance with this Agreement shall control. The Company hereby acknowledges and agrees that the Buyer Parties may rely upon the Allocation Schedule, and in no event will the Buyer or any of its Affiliates (including the Surviving Company) have any liability to any Company Unitholder or other Person with respect to the Allocation Schedule delivered pursuant to this Agreement or on account of shares issued in accordance with the terms hereof as set forth in the Allocation Schedule; provided, that, for the avoidance of doubt, in no event shall the amounts set forth on the Allocation Schedule result in, or require the Buyer to issue a number of XXXX Interests greater, in the aggregate, than the Equity Consideration.
Auction Schedule The Auction Agent shall conduct Auctions in accordance with the schedule set forth below. Such schedule may be changed by the Auction Agent with the consent of the Company, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to each Broker-Dealer. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Company and the Broker-Dealers of the Reference Rate and the Maximum Applicable Rate as set forth in Section 2.2(e)(i) hereof.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement. 2. Time off, based upon service in the Industry Vacation Plan, may be granted to an employee by mutual agreement between the Employer and the employee. The Employer shall not be required to give time off based upon service under the Industry Vacation Plan. However, if such additional industry vacation time off is granted to an employee, such time off shall be counted as time worked for the purpose of computing the employee's earned vacation benefits on his next anniversary date of employment.
Amortization Schedule We do not provide an initial amortization schedule at the time of project agreement release but maintain a "Loan Summary Spreadsheet" on our website on the Financial Tab under "Loans". Once your loan is put into billing an amortization schedule will be posted to the same website, with a copy mailed to the Chief Financial Officer the month following project closeout.
Auction Schedule; Method of Submission of Orders (a) The Funds and the Auction Agent shall conduct Auctions for each series of Preferred Shares in accordance with the schedule set forth below. Such schedule may be changed at any time by the Auction Agent with the consent of the Fund, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to BD. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Funds and the Broker-Dealers of the Maximum Rate as set forth in Section 3.2(a) hereof.
Vacation Schedules (a) Completed vacation schedules will be posted by April 30th of each year. The schedule will be circulated commencing February 1st of the same year. (b) An employee who does not exercise her seniority rights within two (2) weeks of receiving the vacation schedule, shall not be entitled to exercise those rights in respect to any vacation time previously selected by an employee with less seniority. (c) An employee who relocates to another work location where the vacation schedule has already been completed will not be entitled to exercise her seniority rights for that year only. However, every effort shall be made to grant vacation at the time of the employee's choice.
