Selection of Architect/Construction Drawings Tenant shall retain the architect/space planner designated by Tenant and reasonably approved by Landlord (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.2. Tenant shall retain the engineering consultants selected by Tenant (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life safety, and sprinkler work in the Premises, which work is not part of the Base Building. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease shall specifically apply to the Construction Drawings.
Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.
Claim Decision Upon receipt of such claim, the Plan Administrator shall respond to such claimant within ninety (90) days after receiving the claim. If the Plan Administrator determines that special circumstances require additional time for processing the claim, the Plan Administrator can extend the response period by an additional ninety (90) days for reasonable cause by notifying the claimant in writing, prior to the end of the initial ninety (90) day period, that an additional period is required. The notice of extension must set forth the special circumstances and the date by which the Plan Administrator expects to render its decision. If the claim is denied in whole or in part, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Major Decisions (a) any proposed or actual foreclosure upon or comparable conversion of the ownership of the Property or the exercise of any other remedies with respect to the Loan;
Review of Decision Within sixty (60) days after the Secretary’s receipt of a request for review, he or she will review the Company’s determination. After considering all materials presented by the Claimant, the Secretary will render a written opinion, written in a manner calculated to be understood by the Claimant, setting forth the specific reasons for the decision and containing specific references to the pertinent provisions of this Agreement on which the decision is based. If special circumstances require that the sixty (60) day time period be extended, the Secretary will so notify the Claimant and will render the decision as soon as possible, but no later than one hundred twenty (120) days after receipt of the request for review.
Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.
Working Drawings Not later than 15 business days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlord’s receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the TI Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
SUBMITTALS Submittals required by the Contract Documents shall be prepared specifically for the Work by the Contractor to illustrate some portion of the Work. Submittals are not Contract Documents.
Investment Decisions The Subadviser shall determine from time to time what investments and securities will be purchased, retained, sold or loaned by the Series, and what portion of such assets will be invested or held uninvested as cash.
