Additional Work If changes in the work seem merited by Consultant or the City, and informal consultations with the other party indicate that a change is warranted, it shall be processed in the following manner: a letter outlining the changes shall be forwarded to the City by Consultant with a statement of estimated changes in fee or time schedule. An amendment to this Agreement shall be prepared by the City and executed by both Parties before performance of such services, or the City will not be required to pay for the changes in the scope of work. Such amendment shall not render ineffective or invalidate unaffected portions of this Agreement.
Excess Utility Use Landlord shall not be required to furnish electrical power that exceeds Tenant’s floor proportionate share of the electrical capacity of the Building floor on which the Premises are located made available for general tenant usage. If Tenant’s requirements for or consumption of electricity exceed the electricity to be provided by Landlord as described in Section 7.1, Landlord shall, at Tenant’s expense, make reasonable efforts to supply such service through the then-existing feeders and risers serving the Building and the Premises, provided the additional use of such feeders and risers caused by Tenant’s excess electrical requirements do not adversely affect Landlord’s ability to provide reasonable electrical service to the balance of the Building (as determined by Landlord in the exercise of its reasonable discretion); and Tenant shall pay to Landlord the cost of such service within 30 days after Landlord has delivered to Tenant an invoice therefor. Landlord may determine the amount of such additional consumption and potential consumption by any verifiable method, including installation of a separate meter in the Premises installed, maintained, and read by Landlord, at Tenant’s expense. Tenant shall not install any electrical equipment requiring special wiring or requiring voltage in excess of 110 volts unless approved in advance by Landlord, which approval shall not be unreasonably withheld. Tenant shall not install any electrical equipment requiring voltage in excess of the prorata capacity available to Tenant as of the date of this Lease unless approved in advance by Landlord, which approval may be withheld in Landlord’s sole discretion. The use of electricity in the Premises shall not exceed the capacity of existing feeders and risers to or wiring in the Premises. Any risers or wiring required to meet Tenant’s excess electrical requirements shall, upon Tenant’s written request, be installed by Landlord, at Tenant’s cost, if, in Landlord’s judgment, the same are necessary and shall not cause permanent damage to the Building or the Premises, cause or create a dangerous or hazardous condition, entail excessive or unreasonable alterations, repairs, or expenses, adversely affect Landlord’s ability to provide reasonable service to the balance of the Building, or interfere with or disturb other tenants of the Building. If Tenant (a) uses machines or equipment in the Premises or (b) operates within the Premises at a density, either of which (1) affects the temperature otherwise maintained by the air conditioning system or (2) otherwise overloads any utility, Landlord may install supplemental air conditioning units or other supplemental equipment in the Premises, and the cost thereof, including the cost of design, installation, operation, use, and maintenance, in each case plus an administrative fee of 15% of such cost, shall be paid by Tenant to Landlord within 30 days after Landlord has delivered to Tenant an invoice therefor. To the extent practicable, and subject to Landlord’s prior written consent, not to be unreasonably withheld, conditioned or delayed, Tenant shall have the right to elect, at Tenant’s sole cost and expense, to separately submeter electricity consumption in the entire Premises or any portion thereof. If Tenant elects, and Landlord approves, separately submetering the any portion of the Premises, Landlord and Tenant shall enter into an amendment to this Lease revising Tenant’s obligations for the payment of Electrical Costs, including separately submetered electricity usage, common area electricity usage, and any portions of the Premises not covered by the separate submeter(s).
Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.
Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.