District Indemnity of Architect Sample Clauses

District Indemnity of Architect. The District shall indemnify and hold harmless the Architect from all claims arising out of bodily injury (including death), economic damages related thereto and physical damage (other than to the Assigned Project itself and property covered by insurance under Article 4.1.2 hereof) which arise out of the negligent or willful acts, omissions or other such conduct of the District and its agents except for the Architect, its employees or consultants.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
District Indemnity of Architect. It is understood and agreed by the parties to this agreement that, to the extent because the ARCHITECT utilizes Contract Documents prepared by others for the Projects as identified in ARTICLE/PARAGRAPH 28, it is impossible for the ARCHITECT to assure the accuracy, completeness and sufficiency of the Contract Documents, either because it is impossible to verify, or because of errors or omissions which may have occurred in assembling the information. Accordingly, the DISTRICT agrees, to the fullest extent permitted by law, to indemnify and hold the ARCHITECT harmless from any claim, liability or cost (including reasonable attorneys’ fees and costs of defense) for injury or loss arising or allegedly arising from errors or omissions contained in the plans, specifications, or other Contract Documents prepared by others, except for the sole negligence or willful misconduct of the ARCHITECT. The DISTRICT further agrees to indemnify and hold the ARCHITECT harmless from any claim, liability, or cost (including reasonable attorneys’ fees and cost of defense) for copyright or patent infringement arising from the use or reuse of the Contract Documents. The DISTRICT warrants that any documents provided to the ARCHITECT by the DISTRICT or by KPI Architects may be relied upon as to their accuracy and completeness without independent investigation by the ARCHITECT, and that the DISTRICT has the right to provide such documents to the ARCHITECT free of any claims of copyright or patent infringement or violation of any other party’s rights in intellectual property.
Sample 1
District Indemnity of Architect. The District shall indemnify and hold harmless Architect from all claims arising out of bodily injury (including death) and physical damage (other than to the Project itself and property covered by insurance under Article 4.1.2 hereof) which arise out of the negligent or willful acts, omissions or other conduct of the District. District shall indemnify and hold harmless Architect from all claims on account of any damages or loss to property or persons, including death, arising out of Hazardous Substances, except where the Architect is found to be liable for such damages or losses by a court or forum of competent jurisdiction.
Sample 1

Related to District Indemnity of Architect

  • Intellectual Property Indemnification Supplier agrees to defend, indemnify, and hold harmless DXC and its affiliates, subsidiaries, assigns, agents, subcontractors, distributors and customers (collectively “Indemnitees”) from and against all claims, losses, demands, fees, damages, liabilities, costs, expenses, obligations, causes of action, suits, or injuries, of any kind or nature, arising from: (i) any claim that Supplier’s Products or Services, or the use, sale or importation of them, infringes any intellectual property right. Without limiting the foregoing, Supplier will pay all costs, damages and expenses (including reasonable attorneys’ fees) incurred by DXC and/or its Indemnitees and will pay any award with respect to any such claim or agreed to in settlement of that claim.

  • RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY The Respondent shall be liable for all damages to government-owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance pursuant to the Contract. The Respondent shall notify the City of Xxxxxx Procurement Manager in writing of any such damage within one (1) calendar day.

  • INDEMNIFICATION, INSURANCE AND PROTECTION OF PROPERTY The following provisions shall only apply if and to the extent Seller’s personnel enter or perform work at premises owned or controlled by Buyer or Buyer’s customer:

  • Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 13 and 14 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.

  • Liability of City CITY’S PAYMENT OBLIGATIONS UNDER THIS AGREEMENT SHALL BE LIMITED TO THE PAYMENT OF THE COMPENSATION PROVIDED FOR IN SECTION 3.3.1, “PAYMENT,” OF THIS AGREEMENT. NOTWITHSTANDING ANY OTHER PROVISION OF THIS AGREEMENT, IN NO EVENT SHALL CITY BE LIABLE, REGARDLESS OF WHETHER ANY CLAIM IS BASED ON CONTRACT OR TORT, FOR ANY SPECIAL, CONSEQUENTIAL, INDIRECT OR INCIDENTAL DAMAGES, INCLUDING, BUT NOT LIMITED TO, LOST PROFITS, ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT OR THE SERVICES PERFORMED IN CONNECTION WITH THIS AGREEMENT.

  • Liability of District 13.1. Other than as provided in this Agreement, District’s financial obligations under this Agreement shall be limited to the payment of the compensation provided in this Agreement. Notwithstanding any other provision of this Agreement, in no event shall District be liable, regardless of whether any claim is based on contract or tort, for any special, consequential, indirect or incidental damages, including, but not limited to, lost profits or revenue, arising out of or in connection with this Agreement or the Services performed in connection with this Agreement.

  • Intellectual Property Indemnity To the fullest extent permitted by law, Contractor shall defend, indemnify, and hold Enterprise Services and any Purchaser and their employees and agents harmless from against any and all Claims resulting from allegations of infringement of any patents, copyrights, trade secret, or similar intellectual property rights covering the Goods or Services provided, or the use of the Goods or Services under this Master Contract. If Purchaser’s use of Goods or Services provided by Contractor is enjoined based on an intellectual property infringement Claim, Contractor shall, at its own expense, either procure for Purchaser the right to continue using the Goods or Services or, after consulting with Purchaser and obtaining Purchaser’s consent, replace or modify the Goods or Services with substantially similar and functionally equivalent non-infringing Goods or Services.

  • Obligation to Defend; Notice; Cooperation Whenever a claim arises for indemnification under this Section (the “Claim”), the relevant Indemnitee, as appropriate, will promptly notify the Indemnifying party and request the Indemnifying Party to defend the same. Failure to so notify the Indemnifying Party will not relieve the Indemnifying Party of any liability that the Indemnifying Party might have, except to the extent that such failure prejudices the Indemnifying Party's rights or ability to defend such Claim. The Indemnifying Party will have the right to defend against such Claim in which event the Indemnifying Party will give written notice to the Indemnitee of acceptance of the defense of such Claim and the identity of counsel selected by the Indemnifying Party. Except as set forth below, such notice to the relevant Indemnitee will give the Indemnifying Party full authority to defend, adjust, compromise, or settle such Claim with respect to which such notice has been given, except to the extent that any compromise or settlement might prejudice the Intellectual Property Rights or other rights of the relevant Indemnities. The Indemnifying Party will consult with the relevant Indemnitee prior to any compromise or settlement that would affect the Intellectual Property Rights or other rights of any Indemnitee, and the relevant Indemnitee will have the right to refuse such compromise or settlement and, at such Indemnitee’s sole cost, to take over defense of such Claim. Provided, however, that in such event the Indemnifying Party will not be responsible for, nor will it be obligated to indemnify the relevant Indemnitee against any damages, costs, expenses, or liabilities, including without limitation, attorneys’ fees, in excess of such refused compromise or settlement. With respect to any defense accepted by the Indemnifying Party, the relevant Indemnitee will be entitled to participate with the Indemnifying Party in such defense if the Claim requests equitable relief or other relief (other than monetary damages) that could affect the rights of the Indemnitee and also will be entitled to employ separate counsel for such defense at such Indemnitee's expense. In the event the Indemnifying Party does not accept the defense of any indemnified Claim as provided above, the relevant Indemnitee will have the right to employ counsel for such defense at the expense of the Indemnifying Party, and the Indemnifying Party shall be liable for all costs associated with Indemnitee’s defense of such Claim including court costs, and any settlement or damages awarded a third party. Each Party agrees to cooperate and to cause its employees and agents to cooperate with the other Party in the defense of any such Claim.

  • Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.

  • Conduct of Indemnification Proceedings If any Proceeding shall be brought or asserted against any Person entitled to indemnity hereunder (an “Indemnified Party”), such Indemnified Party shall promptly notify the Person from whom indemnity is sought (the “Indemnifying Party”) in writing, and the Indemnifying Party shall have the right to assume the defense thereof, including the employment of counsel reasonably satisfactory to the Indemnified Party and the payment of all fees and expenses incurred in connection with defense thereof, provided that the failure of any Indemnified Party to give such notice shall not relieve the Indemnifying Party of its obligations or liabilities pursuant to this Agreement, except (and only) to the extent that it shall be finally determined by a court of competent jurisdiction (which determination is not subject to appeal or further review) that such failure shall have materially and adversely prejudiced the Indemnifying Party. An Indemnified Party shall have the right to employ separate counsel in any such Proceeding and to participate in the defense thereof, but the fees and expenses of such counsel shall be at the expense of such Indemnified Party or Parties unless: (1) the Indemnifying Party has agreed in writing to pay such fees and expenses, (2) the Indemnifying Party shall have failed promptly to assume the defense of such Proceeding and to employ counsel reasonably satisfactory to such Indemnified Party in any such Proceeding, or (3) the named parties to any such Proceeding (including any impleaded parties) include both such Indemnified Party and the Indemnifying Party, and counsel to the Indemnified Party shall reasonably believe that a material conflict of interest is likely to exist if the same counsel were to represent such Indemnified Party and the Indemnifying Party (in which case, if such Indemnified Party notifies the Indemnifying Party in writing that it elects to employ separate counsel at the expense of the Indemnifying Party, the Indemnifying Party shall not have the right to assume the defense thereof and the reasonable fees and expenses of no more than one separate counsel shall be at the expense of the Indemnifying Party). The Indemnifying Party shall not be liable for any settlement of any such Proceeding effected without its written consent, which consent shall not be unreasonably withheld or delayed. No Indemnifying Party shall, without the prior written consent of the Indemnified Party, effect any settlement of any pending Proceeding in respect of which any Indemnified Party is a party, unless such settlement includes an unconditional release of such Indemnified Party from all liability on claims that are the subject matter of such Proceeding. Subject to the terms of this Agreement, all reasonable fees and expenses of the Indemnified Party (including reasonable fees and expenses to the extent incurred in connection with investigating or preparing to defend such Proceeding in a manner not inconsistent with this Section) shall be paid to the Indemnified Party, as incurred, within ten Trading Days of written notice thereof to the Indemnifying Party, provided that the Indemnified Party shall promptly reimburse the Indemnifying Party for that portion of such fees and expenses applicable to such actions for which such Indemnified Party is finally determined by a court of competent jurisdiction (which determination is not subject to appeal or further review) not to be entitled to indemnification hereunder.

Time is Money Join Law Insider Premium to draft better contracts faster.