Emissions Guarantee Sample Clauses

Emissions Guarantee. ‌ Seller shall conduct the Performance Tests in accordance with Appendix H and, as a condition of Substantial Completion, shall demonstrate that emissions from the Project meet the Guaranteed Emissions. If the Guaranteed Emissions are not met, either in whole or in part, Seller shall, at its sole cost and expense, to diligently make such changes, modifications and/or additions to the Plant or any part thereof as may be necessary to achieve the Guaranteed Emissions. Seller shall notify Buyer upon completion of the necessary changes, modifications or additions, and Seller shall repeat the Performance Tests as necessary until the Guaranteed Emissions have been met. Nothing contained in this Section 18.2 shall relieve Seller of Seller’s obligation to pay liquidated damages under this Agreement.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Emissions Guarantee. Contractor guarantees to Owner that the emission of air contaminants into the atmosphere from the Ethanol Plant shall be equal to or less than the emissions limitations contained in the Air Permit, attached hereto as Appendix I to the Scope of Work, as demonstrated through the use of the air quality sampling criteria and the techniques referenced therein (the “Emissions Guarantee”).
Sample 1
Emissions Guarantee. (a) EE guarantees to PREP A that the Vessel will not exceed the following annual emissions (collectively, the Emissions Gnarantees), as will be demonstrated by emissions testing conducted based on testing procedures established by regulating agencies and the air permit issued to PREPA by the Puerto Rico Environmental Quality Board (the EQB Permit): Pollutants Limited Emissions (tpy) NOx 110 co 123 voc 16 PM 21 PM10 21 PM25 21 so, 21 H2S04 2 Pb 0.0006 Fluoride 0 NH3 12 HAP 8 CH, 15 N20 1 co, 321,266 45 I co,e 321,773
Sample 1
Emissions Guarantee. Contractor shall conduct the Performance Tests in accordance with Exhibit A, Appendix M and, as a condition of Substantial Completion, shall demonstrate that emissions from the Project meet the Guaranteed Emissions. If at any time during the Performance Tests the Guaranteed Emissions are not met, either in whole or in part, Contractor shall, at its sole cost and expense, diligently make such changes, modifications and/or additions to the Project or any part thereof as may be necessary to achieve the Guaranteed Emissions, as provided in Exhibit A, Appendix M. Contractor shall notify Owner upon completion of the necessary changes, modifications or additions, and Contractor shall repeat the Performance Tests as necessary until the Guaranteed Emissions have been met. In the event that any adjustments made by Contractor result in failure to meet the Guaranteed Emissions at any time, Contractor shall be responsible to remedy such conditions at its own cost. Nothing contained in this Section 14.2 shall relieve Contractor of Contractor’s obligation to pay liquidated damages under this Contract.
Sample 1
Emissions Guarantee. Contractor guarantees that the emission of air contaminants into the atmosphere from the Plant will meet the emissions limitations (as demonstrated through the use of the air quality sampling criteria and the techniques referenced therein) of the EPA Prevention of Significant Deterioration ("PSD") permit and the permits granted pursuant to the CPCN proceeding, attached hereto in Exhibit G.
Sample 1
Emissions Guarantee. 19.4.1 Subject to the provisions of this Agreement, Seller guarantees to Buyer that, for the Operating Criteria, during each of the six, one hour Emission Tests, during an eight hour period throughout which each individual Turbine Generator Unit is operating at a net power output level within the range of fifty percent and one hundred percent of the Turbine Generator Unit's Electrical Output Guarantee, and in accordance with the Approved Test Procedures and Section 19.4.2 below, each Turbine Generator Unit will meet the Emissions Guarantee during each test period as specified in Section 19.1 for the Operating Criterion.
Sample 1

Related to Emissions Guarantee

  • Company Guarantee In order to induce the Lenders to extend credit to the other Borrowers hereunder, the Company hereby irrevocably and unconditionally guarantees, as a primary obligor and not merely as a surety, the payment when and as due of the Obligations of such other Borrowers. The Company further agrees that the due and punctual payment of such Obligations may be extended or renewed, in whole or in part, without notice to or further assent from it, and that it will remain bound upon its guarantee hereunder notwithstanding any such extension or renewal of any such Obligation. The Company waives presentment to, demand of payment from and protest to any Borrower of any of the Obligations, and also waives notice of acceptance of its obligations and notice of protest for nonpayment. The obligations of the Company hereunder shall not be affected by: (a) the failure of the Administrative Agent, the Issuing Bank or any Lender to assert any claim or demand or to enforce any right or remedy against any Borrower under the provisions of this Agreement, any other Loan Document or otherwise; (b) any extension or renewal of any of the Obligations; (c) any rescission, waiver, amendment or modification of, or release from, any of the terms or provisions of this Agreement, or any other Loan Document or agreement; (d) any default, failure or delay, willful or otherwise, in the performance of any of the Obligations; (e) the failure of the Administrative Agent to take any steps to perfect and maintain any security interest in, or to preserve any rights to, any security or collateral for the Obligations, if any; (f) any change in the corporate, partnership or other existence, structure or ownership of any Borrower or any other guarantor of any of the Obligations; (g) the enforceability or validity of the Obligations or any part thereof or the genuineness, enforceability or validity of any agreement relating thereto or with respect to any collateral securing the Obligations or any part thereof, or any other invalidity or unenforceability relating to or against any Borrower or any other guarantor of any of the Obligations, for any reason related to this Agreement, any Swap Agreement, any other Loan Document, or any provision of applicable law, decree, order or regulation of any jurisdiction purporting to prohibit the payment by such Borrower or any other guarantor of the Obligations, of any of the Obligations or otherwise affecting any term of any of the Obligations; or (h) any other act, omission or delay to do any other act which may or might in any manner or to any extent vary the risk of the Company or otherwise operate as a discharge of a guarantor as a matter of law or equity or which would impair or eliminate any right of the Company to subrogation. The Company further agrees that its agreement hereunder constitutes a guarantee of payment when due (whether or not any bankruptcy or similar proceeding shall have stayed the accrual or collection of any of the Obligations or operated as a discharge thereof) and not merely of collection, and waives any right to require that any resort be had by the Administrative Agent, the Issuing Bank or any Lender to any balance of any deposit account or credit on the books of the Administrative Agent, the Issuing Bank or any Lender in favor of any Borrower or any other Person. The obligations of the Company hereunder shall not be subject to any reduction, limitation, impairment or termination for any reason, and shall not be subject to any defense or set-off, counterclaim, recoupment or termination whatsoever, by reason of the invalidity, illegality or unenforceability of any of the Obligations, any impossibility in the performance of any of the Obligations or otherwise. The Company further agrees that its obligations hereunder shall continue to be effective or be reinstated, as the case may be, if at any time payment, or any part thereof, of any Obligation is rescinded or must otherwise be restored by the Administrative Agent, the Issuing Bank or any Lender upon the bankruptcy or reorganization of any Borrower or otherwise. In furtherance of the foregoing and not in limitation of any other right which the Administrative Agent, the Issuing Bank or any Lender may have at law or in equity against the Company by virtue hereof, upon the failure of any other Borrower to pay any Obligation when and as the same shall become due, whether at maturity, by acceleration, after notice of prepayment or otherwise, the Company hereby promises to and will, upon receipt of written demand by the Administrative Agent, the Issuing Bank or any Lender, forthwith pay, or cause to be paid, to the Administrative Agent, the Issuing Bank or any Lender in cash an amount equal to the unpaid principal amount of such Obligations then due, together with accrued and unpaid interest thereon. The Company further agrees that if payment in respect of any Obligation shall be due in a currency other than Dollars and/or at a place of payment other than New York, Chicago or any other Eurocurrency Payment Office and if, by reason of any Change in Law, disruption of currency or foreign exchange markets, war or civil disturbance or other event, payment of such Obligation in such currency or at such place of payment shall be impossible or, in the reasonable judgment of the Administrative Agent, the Issuing Bank or any Lender, disadvantageous to the Administrative Agent, the Issuing Bank or any Lender in any material respect, then, at the election of the Administrative Agent, the Company shall make payment of such Obligation in Dollars (based upon the applicable Equivalent Amount in effect on the date of payment) and/or in New York, Chicago or such other Eurocurrency Payment Office as is designated by the Administrative Agent and, as a separate and independent obligation, shall indemnify the Administrative Agent, the Issuing Bank and any Lender against any losses or reasonable out-of-pocket expenses that it shall sustain as a result of such alternative payment. Upon payment by the Company of any sums as provided above, all rights of the Company against any Borrower arising as a result thereof by way of right of subrogation or otherwise shall in all respects be subordinated and junior in right of payment to the prior indefeasible payment in full in cash of all the Obligations owed by such Borrower to the Administrative Agent, the Issuing Bank and the Lenders. Nothing shall discharge or satisfy the liability of the Company hereunder except the full performance and payment of the Obligations.

  • Release of Subsidiary Guarantees Notwithstanding the provisions of Section 1302, Subsidiary Guarantees will be subject to termination and discharge under the circumstances described in this Section 1303: Any Subsidiary Guarantor will automatically and unconditionally be released from all obligations under its Subsidiary Guarantee, and such Subsidiary Guarantee shall thereupon terminate and be discharged and of no further force or effect, (i) concurrently with any sale or disposition (by merger or otherwise) of any Subsidiary Guarantor or any interest therein in accordance with the terms of this Indenture (including Section 411 and Section 501) by the Company or a Restricted Subsidiary, following which such Subsidiary Guarantor is no longer a Restricted Subsidiary of the Company, (ii) at any time that such Subsidiary Guarantor is released from all of its obligations under all of its Guarantees of payment by the Company of any Bank Indebtedness of the Company (other than by reason of payment under such Guarantees of Bank Indebtedness), (iii) upon the merger or consolidation of any Subsidiary Guarantor with and into the Company or another Subsidiary Guarantor that is the surviving Person in such merger or consolidation, (iv) concurrently with any Subsidiary Guarantor becoming an Unrestricted Subsidiary, (v) upon legal or covenant defeasance of the Company’s obligations, or satisfaction and discharge of this Indenture, or (vi) subject to Section 1302(b), upon payment in full of the aggregate principal amount of all Notes then Outstanding and all other Subsidiary Guaranteed Obligations then due and owing. In addition, the Company will have the right, upon 30 days’ notice to the Trustee, to cause any Subsidiary Guarantor that has not guaranteed payment by the Company of any Bank Indebtedness of the Company to be unconditionally released from all obligations under its Subsidiary Guarantee, and such Subsidiary Guarantee shall thereupon terminate and be discharged and of no further force or effect. Upon any such occurrence specified in this paragraph, the Trustee shall execute any documents reasonably required in order to evidence such release, discharge and termination in respect of such Subsidiary Guarantee. Upon any such occurrence specified in this Section 1303, the Trustee shall execute any documents reasonably required in order to evidence such release, discharge and termination in respect of the applicable Subsidiary Guarantee.

  • The Guarantee Each Guarantor hereby jointly and severally with the other Guarantors guarantees, as a primary obligor and not merely as a surety to each Secured Party and their respective permitted successors and assigns, the prompt payment in full when due (whether at stated maturity, by required prepayment, declaration, demand, by acceleration or otherwise) of the principal of and interest (including any interest, fees, costs or charges that would accrue but for the provisions of (i) the Title 11 of the United States Code after any bankruptcy or insolvency petition under Title 11 of the United States Code and (ii) any other Debtor Relief Laws) on the Loans made by the Lenders to, and the Notes held by each Lender of, the Borrower, and all other Secured Obligations from time to time owing to the Secured Parties by any Loan Party or any Subsidiary under any Loan Document or any Secured Hedge Agreement or any Treasury Services Agreement, in each case strictly in accordance with the terms thereof (such obligations, including any future increases in the amount thereof, being herein collectively called the “Guaranteed Obligations”); provided, however, that Guaranteed Obligations shall exclude all Excluded Swap Obligations. The Guarantors hereby jointly and severally agree that if the Borrower or other Guarantor(s) shall fail to pay in full when due (whether at stated maturity, by acceleration or otherwise) any of the Guaranteed Obligations, the Guarantors will promptly pay the same in cash, without any demand or notice whatsoever, and that in the case of any extension of time of payment or renewal of any of the Guaranteed Obligations, the same will be promptly paid in full when due (whether at extended maturity, by acceleration or otherwise) in accordance with the terms of such extension or renewal.

  • Confirmation of Guarantee The Guarantor hereby confirms and agrees that (i) the Guarantee is and shall continue to be in full force and effect and is otherwise hereby ratified and confirmed in all respects; and (ii) the Guarantee is and shall continue to be an unconditional and irrevocable guarantee of all of the Obligations (as defined in the Guarantee).

  • Release of Subsidiary Guarantors from Guarantee (a) Notwithstanding any other provisions of this Indenture, the Guarantee of any Subsidiary Guarantor may be released upon the terms and subject to the conditions set forth in Section 11.02(b) and in this Section 14.04. Provided that no Default shall have occurred and shall be continuing under this Indenture, the Guarantee incurred by a Subsidiary Guarantor pursuant to this Article XIV shall be unconditionally released and discharged (i) automatically upon (A) any sale, exchange or transfer, whether by way of merger or otherwise, to any Person that is not an Affiliate of the Partnership, of all of the Partnership’s direct or indirect limited partnership or other equity interests in such Subsidiary Guarantor (provided such sale, exchange or transfer is not prohibited by this Indenture) or (B) the merger of such Subsidiary Guarantor into either of the Issuers or any other Subsidiary Guarantor or the liquidation and dissolution of such Subsidiary Guarantor (in each case to the extent not prohibited by this Indenture) or (ii) upon the Issuers’ delivery of a written notice to the Trustee of the release or discharge of all guarantees by such Subsidiary Guarantor of any Debt of the Issuers other than obligations arising under this Indenture and any Debt Securities issued hereunder, except a discharge or release by or as a result of payment under such guarantees.

  • Release of Guarantee The Note Guarantees hereunder may be released in accordance with Section 10.2 of the Indenture.

  • Subordination of Guarantee The guarantee and other liabilities and obligations of the Depositor under this Agreement shall constitute unsecured obligations of the Depositor and shall rank subordinate and junior in right of payment to all Senior Indebtedness (as defined in the Indenture) of the Depositor to the extent and in the manner set forth in the Indenture with respect to the Debentures, and the provisions of Article XIII of the Indenture will apply, mutatis mutandis, to the obligations of the Depositor hereunder. The obligations of the Depositor hereunder do not constitute Senior Indebtedness (as defined in the Indenture) of the Depositor.

  • Release of Note Guarantees (a) A Note Guarantee by a Guarantor shall be automatically and unconditionally released and discharged, and no further action by such Guarantor, the Company or the Trustee shall be required for the release of such Guarantor’s Note Guarantee, upon:

  • Limitation of Guarantee The obligations of each Guarantor will be limited to the maximum amount as will, after giving effect to all other contingent and fixed liabilities of such Guarantor and after giving effect to any collections from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under its Guarantee or pursuant to its contribution obligations under this Indenture, result in the obligations of such Guarantor under the Guarantee not constituting a fraudulent conveyance or fraudulent transfer under Federal or state law. Each Guarantor that makes a payment or distribution under a Guarantee shall be entitled to a contribution from each other Guarantor in a pro rata amount based on the Adjusted Net Assets of each Guarantor.

Time is Money Join Law Insider Premium to draft better contracts faster.