Force Majeure Delay, Extension of Times of Performance Sample Clauses

Force Majeure Delay, Extension of Times of Performance. (a) Performance by any Party hereunder shall be excused, waived or deemed not to be in default where delays or defaults are due to acts beyond a Party's control such as war, insurrection, strikes, walkouts, riots, floods, earthquakes, fires, casualties, acts of God, unexpected acts of governmental entities other than City, including revisions to capacity ratings of the wastewater plant by the Regional Water Quality Control Board, the State Water Resources Board, enactment of conflicting State or Federal laws or regulations, or litigation (including without limitation litigation contesting the validity, or seeking the enforcement or clarification of this Agreement whether instituted by the Developer, City, or any other person or entity) (each a "Force Majeure Event").
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Force Majeure Delay, Extension of Times of Performance. (a) In addition to specific provisions of this Agreement, performance by either Party hereunder shall not be deemed to be in default where delays or defaults are due to war, insurrection, strikes, walkouts, riots, floods, earthquakes, fires, casualties, acts of God, governmental entities other than City, its departments, agencies, boards and commissions, enactment of conflicting State or Federal laws or regulations, or litigation (including without limitation litigation contesting the validity, or seeking the enforcement or clarification of this Agreement whether instituted by Owner, City, or any other person or entity) (each a "Force Majeure Event").
Sample 1
Force Majeure Delay, Extension of Times of Performance. Subject to the limitations set forth below, the Term of this Agreement and the time within which either Party shall be required to perform any act under this Agreement shall be extended by a period of time equal to the number of days during which performance of such act is delayed unavoidably and beyond the reasonable control of the Party seeking the delay by strikes, lock outs, and other labor difficulties; Acts of God; unusually severe weather, but only to the extent that such weather or its effects (including, without limitation, dry out time) result in delays that cumulatively exceed twenty (20) days for any winter season occurring after commencement of construction of the Project; failure or inability to secure materials or labor by reason of priority or similar regulations or order of any governmental or regulatory body; changes in local, state, or federal laws or regulations; any development moratorium or any action of other public agencies that regulate land use, development, or the provision of services that prevents, prohibits, or delays construction of the Project, including without limitation any extension authorized by Government Code Section 66463.5(d); enemy action; civil disturbances; wars; terrorist acts; fire; unavoidable casualties; mediation, arbitration, litigation, or other administrative or judicial proceeding involving the Project Approvals or this Agreement, including without limitation any extension authorized by Government Code Section 66463.5(e); or a Severe Economic Recession (each a “Force Majeure Delay”). An extension of time for any such cause other than a Severe Economic Recession shall be for the period of the enforced delay and shall commence to run from the time of the commencement of the cause, if Notice (as defined in Section 14.5) by the Party claiming such extension is sent to the other Party within sixty (60) days of the commencement of the cause. If Notice is sent after such sixty (60) day period, then the extension shall commence to run no sooner than sixty (60) days prior to the giving of such Notice. Times of performance under this Agreement may also be extended in writing by the mutual agreement of the City Manager and Developer. Developer’s inability or failure to obtain financing shall not be deemed to be a cause outside the reasonable control of the Developer and shall not be the basis for an excused delay unless such inability, failure, or delay is a direct result of a Severe Economic Recession. “Severe Eco...
Sample 1

Related to Force Majeure Delay, Extension of Times of Performance

  • Suspension of Performance Notwithstanding any other provision hereof, if an Event of Default or a Potential Event of Default has occurred and is continuing, the Non-Defaulting Party, upon written notice to the Defaulting Party, has the right (i) to suspend performance under any or all Transactions and (ii) to the extent an Event of Default has occurred and is continuing, to exercise any remedy available at law or in equity, except as limited be Section 5.7.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • EXCUSE OF PERFORMANCE Seller shall not be liable for delays in performance or for non-performance due to failure or interruption of computer or telecommunication systems, acts of God, war, riot, fire, terrorism, labor trouble, unavailability of materials or components, explosion, accident, compliance with governmental requests, laws, regulations, orders or actions, or other unforeseen circumstances or causes beyond Seller's reasonable control. In the event of such delay, the time for performance or delivery shall be extended by a period of time reasonably necessary to overcome the effect of the delay.

  • Commencement of Performance This Agreement is of no force and effect until signed by both parties and all JBE-required approvals are secured. Any commencement of performance prior to Agreement approval shall be at Contractor's own risk.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • Resumption of Performance During the period that a Force Majeure Event is subsisting, the Affected Party shall, in consultation with the other Parties, make all reasonable efforts to limit or mitigate the effects of such Force Majeure Event on the performance of its obligations under the PPA. The Affected Party shall also make efforts to resume performance of its obligations under this Agreement as soon as possible and upon resumption, shall notify other Parties of the same in writing. The other Parties shall afford all reasonable assistance to the Affected Party in this regard.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Timeliness of Performance Contractor must provide the Services and Deliverables within the term and within the time limits required under this Contract, pursuant to Detailed Specifications or as specified in the applicable Task Order or Purchase Order. Further, Contractor acknowledges that TIME IS OF THE ESSENCE and that the failure of Contractor to comply with the time limits may result in economic or other losses to the City. Neither Contractor nor its agents, employees or Subcontractors are entitled to any damages from the City, nor is any party entitled to be reimbursed by the City, for damages, charges or other losses or expenses incurred by Contractor by reason of delays or hindrances in the performance of the Services, whether or not caused by the City.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!