Implementation Services Time Frame Clause Samples
Implementation Services Time Frame. 3.9.1 During the course of planning discussions related to this Agreement, NAVITAIRE acknowledges the Target Date as requested by Customer for completion of applicable portions of the Implementation Services. The Target Date for completion of the Implementation Services is no later than *****. NAVITAIRE and Customer will detail dates and dependencies of the project plan, as summarized in the table in Section 3.9.2 below, in order to confirm the Target Date achievability.
3.9.2 Upon receipt of the Implementation Fees due at signing and subject to Section 4.1 of the Agreement, NAVITAIRE agrees to perform the Implementation Services within the time frame preceding the Target Date. NAVITAIRE further agrees to initiate, mutually with Customer, project-scope-analysis and project-planning communication to establish the final schedule for Implementation Services consistent with the Target Date. *****Confidential portions of the material have been omitted and filed separately with the Securities and Exchange Commission. Hosted Services Agreement FINAL The following table outlines the key milestone activities that will be discussed during the Strategic Business Review: ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** ***** *****Confidential portions of th...
Implementation Services Time Frame. 3.9.1 During the course of planning discussions related to this Agreement, NAVITAIRE acknowledges the Target Date as requested by the Customer for completion of applicable portions of the Implementation Services. The Target Date for completion of the Implementation Services is no later than November, 2007. NAVITAIRE and Customer will detail dependencies of the project plan, in order to confirm the Target Date achievability.
3.9.2 Beginning on the Effective Date of this Agreement, NAVITAIRE agrees to work with Customer, using commercially reasonable efforts, to plan, coordinate, and to make progress toward completion of the required Implementation Services within the time frame preceding the Target Date. NAVITAIRE further agrees to initiate, mutually with the Customer, project-scope-analysis and project-planning communication to establish the final schedule for Implementation Services.
3.9.3 Customer understands that the Target Date is subject to change, as such date is dependent on, among other matters, certain third party agreements on behalf of both the Customer and NAVITAIRE. These third party agreements may include, but are not limited to, the following: • Airport facility use agreements. • All telecommunications and data circuits. • Credit card settlement and authorization agreements. • Centralized Reservation System/Global Distribution System (CRS/GDS/ARS) agreements and host provider(s) certification process. • Data conversion systems. Customer will immediately establish a primary technical Project Manager contact that will be assigned to interact with the Project Manager appointed by NAVITAIRE. Failure to appoint this individual will jeopardize the delivery of Implementation Services by NAVITAIRE.
3.9.4 Upon completion of the Implementation Services as described in this Exhibit A, Section 3, NAVITAIRE will provide written notification to the Customer Account Liaison named in Exhibit D, Section 2.
Implementation Services Time Frame. 3.9.1 Upon receipt of the Implementation Fees due at signing, NAVITAIRE agrees to work with Customer to plan, coordinate, and to make progress toward completion of the required Implementation Services within the time frame preceding the Target Date. NAVITAIRE further agrees to initiate, mutually with Customer, project-scope-analysis and project-planning communication to establish the final schedule for Implementation Services. Depending on requirements for the loading of data included in the ***** Input files outlined as Interface Files in Section 7 below, into the Hosted Revenue Accounting Services and conversion, the project timeline and Target Date for Implementation Services of Hosted Revenue Accounting Services will be determined as part of the implementation project plan.
3.9.2 During the court of planning discussions related to this Agreement, NAVITAIRE acknowledges the Target Date as requested by Customer for completion of applicable portions of Implementation Services. For Customers who are converting to the NAVITAIRE Hosted Reservation Services, the Target Date for completion of Implementation Services is no later than ***** after the first date that passengers are checked in at the airport using the Host Reservation Services. NAVITAIRE and Customer will detail dates and dependencies of the project plan, as summarized in the table below, in order to confirm the Target Date achievability. 0 Agreement Signature and Project Start Date ü ü ***** Agreement Signed* 1 Project Start Components ***** Milestone 0 SkyLedger data collector ü Project Statement of Work signoff ü ü 2 Account Setup Complete ***** Milestones 0 and 1 SkyLedger software loaded ü Connectivity to NAVITAIRE data center ü ü 3 SkyLedger Training ***** Milestone 2 SkyLedger training complete ü Hosted Services Agreement 4 User Acceptance Testing ***** Milestone 3 Confirm business critical functionality that is available in SkyLedger release ü Approved functionality is working as documented ü 5 Go-Live Readiness Review ***** Milestone 4 Go-live walk-through ü ü Confirm go-live date with all necessary teams ü ü 6 Go-Live ***** Milestone 5 Load data ü Perform data integrity check ü Perform go-live activities ü Approve go-live ü 7 First Monthly Close ***** Milestone 6 Execute first monthly close ü Review monthly close ü Approve monthly close ü * Implementation services will not be scheduled until this Agreement is fully-executed and any implementation fees due and payable by Customer as outli...
Implementation Services Time Frame. 3.7.1 During the course of planning discussions related to this Agreement, NAVITAIRE acknowledges the Target Date for completion of the Implementation Services is *****. NAVITAIRE and Customer will detail dates and dependencies of the project plan, as summarized in the table in Exhibit A, Section 3.9.2, in order to confirm the Target Date achievability. *****Confidential portions of the material have been omitted and filed separately with the Securities and Exchange Commission. Hosted Services Agreement FINAL
3.7.2 Upon receipt of the Implementation Fees due at signing and subject to Section 4.1 of the Agreement, NAVITAIRE agrees to perform the required Implementation Services within the time frame preceding the Target Date. NAVITAIRE further agrees to initiate, mutually with Customer, project-scope-analysis and project-planning communication to establish the final schedule for Implementation Services.
3.7.3 Customer understands that the Target Date may be subject to change upon mutual agreement of the parties; as such date is dependent on, among other matters, certain third party agreements/activities on behalf of both Customer and NAVITAIRE. These third party agreements/activities may include, but are not limited to, the following: • All telecommunications and data circuits. • Web domains and certificates. • Web content creation and maintenance. Customer shall immediately establish a primary technical Project Manager contact that will be assigned to interact with the Project Manager appointed by NAVITAIRE. Failure to appoint this individual will jeopardize the delivery of Implementation Services by NAVITAIRE.
3.7.4 Upon completion of the Implementation Services as described in this Exhibit, NAVITAIRE will provide written notification to the Customer Account Liaison named in Exhibit D, Section 2.
Implementation Services Time Frame. 3.9.1 Beginning on the Effective Date of this Agreement, NAVITAIRE agrees to work with Customer, using commercially reasonable efforts, to plan, coordinate, and to make progress toward completion of the required Implementation Services within the time frame preceding the Target Date. NAVITAIRE further agrees to initiate, mutually with the Customer, project-scope-analysis and project-planning communication to establish the final schedule for Implementation Services. Depending on requirements for the loading of data included in the four XML Input files outlined as Interface Files in Section 7 below, into the Hosted Revenue Accounting Services and conversion, the project timeline and Target Date for Implementation Services of Hosted Revenue Accounting Services will be determined as part of the implementation project plan. During the course of planning discussions related to this Agreement, NAVITAIRE acknowledges the Target Date as requested by the Customer for completion of applicable portions of Implementation Services. The Target Date for completion of implementation Services is no later than four (4) weeks after the first date that passengers are checked in at the airport using the Host Reservation Services. NAVITAIRE and Customer will detail dependencies of the project plan, in order to confirm the Target Date achievability.
3.9.2 NAVITAIRE recommends at least four (4) weeks of data included in the four XML Input files outlined as Interface Flies in Section 7 below, containing Customer's open PNR data from NAVITAIRE's Hosted Reservation Services, prior to activation and initialization of the Hosted Revenue Accounting Services. Open PNR data will include future flight segments as well as any past unflown segments which still have a positive remaining balance which have not been converted to a voucher or credit shell.
3.9.3 Typical timelines for implementation average four (4) months for full project implementation. The Hosted Revenue Accounting Services implementation process will be conducted in parallel with the NAVITAIRE Hosted Reservation Services implementation (if applicable), however, the Hosted Reservation Services conversion to production will normally precede the conversion of the Hosted Revenue Accounting Services implementation.
3.9.4 The NAVITAIRE Hosted Revenue Accounting Services implementation team will have an assigned project lead and central contact point that will interface with the Customer Revenue Accounting Contact during the Impleme...
Implementation Services Time Frame. 3.9.1 Depending on requirements for historical booking and inventory history conversion, the project timeline and Target Date for Implementation Services of Hosted Revenue Management Services will be determined after the initial Scope Analysis initiative. The Target Date for completion of Implementation Services is no later than the latter of February 1, 2004 and forty-five (45) days after receipt of Customer’s current RMS database. NAVITAIRE and Customer will detail dependencies of the project plan, in order to confirm the Target Date achievability.
3.9.2 NAVITAIRE recommends at least eight (8) weeks of flown historical data prior to activation and initialization of the Hosted Revenue Management Services. Depending on the quality and amount of applicable historical data, it may also be necessary to gather additional booking activity for a period of eight (8) weeks or more of NAVITAIRE Hosted Reservation Services reservation data to provide the base for the Hosted Revenue Management Services forecast model.
3.9.3 Typical timelines for implementation average four (4) months for full project implementation. The Hosted Revenue Management Services implementation process will be conducted in parallel with the NAVITAIRE Hosted Reservation Services implementation (if applicable), however, the Hosted Reservation Services conversion to production will normally precede the conversion of the Hosted Revenue Management Services implementation.
3.9.4 The NAVITAIRE Hosted Revenue Management Services implementation team will have an assigned project lead and central contact point that will interface with the Customer Revenue Management Contact during the Implementation Services period.
Implementation Services Time Frame. 3.9.1 During the course of planning discussions related to this Agreement, NAVITAIRE acknowledges the Target Date as requested by the Customer for completion of applicable portions of the Implementation Services. The Target Date for completion of the Implementation Services is no later than November, 2007. NAVITAIRE and Customer will detail dependencies of the project plan, in order to confirm the Target Date achievability.