Inspection Period Buyer shall be under no obligation to purchase the Property or otherwise perform under this Agreement unless Buyer determines the Property to be, in all respects, suitable for its intended purposes. The decision as to whether the Property is suitable for its intended purposes shall be the sole decision of Buyer, determined in the absolute discretion of Buyer, with Buyer’s decision being final and binding upon both Parties. Buyer shall have until , 20 , at : ☐ AM ☐ PM to notify Seller of its termination of this Agreement due to Buyer's determination that the Property is unsuitable for its intended purpose ("Inspection Period"). In the event Buyer elects to terminate this Agreement, Buyer shall provide written notice of termination to Seller prior to the expiration of the Inspection Period. In the event Buyer provides said notice of termination, Seller and any Escrow Agent shall be obligated to return the Escrow Money to the Buyer as provided in Section V hereof, and neither party shall have any further rights or obligations under this Agreement. In the event Buyer does not submit written notice of termination prior to the expiration of the Inspection Period, the Buyer shall be deemed to be satisfied with its inspections of the Property and this contingency shall be deemed to be fulfilled. The Seller, at no expense, shall fully cooperate with Buyer in obtaining any and all approvals required from any Federal, State, or Local Government ("Governmental Approvals") necessary for Buyer to satisfy their needs during the Inspection Period for the suitability of the Property. Said Governmental Approvals shall be obtained during the Inspection Period unless the Parties agree otherwise. Any additional agreements related to this Section must be done in writing and attached to this Agreement.
Study Period (a) The Acquiror shall have the right, until 5:00 p.m. on the last day of the Study Period, and thereafter if the Acquiror notifies the Contributor that the Acquiror has elected to proceed to Closing in the manner described below, to enter upon the Real Property and to perform, at the Acquiror's expense, such economic, surveying, engineering, environmental, topographic and marketing tests, studies and investigations as the Acquiror may deem appropriate. If such tests, studies and investigations warrant, in the Acquiror's sole, absolute and unreviewable discretion, the acquisition of the Property for the purposes contemplated by the Acquiror, then the Acquiror may elect to proceed to Closing and shall so notify the Contributor prior to the expiration of the Study Period. If for any reason the Acquiror does not so notify the Contributor of its determination to proceed to Closing prior to the expiration of the Study Period, or if the Acquiror notifies the Contributor, in writing, prior to the expiration of the Study Period that it has determined not to proceed to Closing, this Agreement automatically shall terminate, the Acquiror shall be released from any further liability or obligation under this Agreement.
Final Inspection Contractor shall complete the list of items identified on the pre-final Punchlist prior to requesting a final inspection. Unless otherwise specified, or otherwise agreed in writing by the parties as documented on the Certificate of Substantial Completion, Contractor shall complete and/or correct all Work within thirty (30) days of the Substantial Completion date. Upon completion of the pre-final Punchlist work, Contractor shall give written notice to ODR and A/E that the Work will be ready for final inspection on a specific date. Contractor shall accompany this notice with a copy of the updated pre-final Punchlist indicating resolution of all items. On the date specified or as soon thereafter as is practicable, ODR, A/E and Contractor will inspect the Work. A/E will submit to Contractor a final Punchlist of open items that the inspection team requires corrected or completed before final acceptance of the Work.
Physical Inspection Subject to the limitations set forth in this Section 4.1(c) and notwithstanding any provision to the contrary in this Agreement, commencing on the Effective Date and continuing through the Closing or any earlier termination of this Agreement, Buyer shall have the right, at Buyer’s expense, to make inspections (including tests, surveys and other studies) of the Real Property and all matters relating thereto, including, but not limited to, soils and geologic conditions, location of property lines, utility availability and use restrictions, environmental conditions, the manner or quality of the construction of the Improvements, the habitability, merchantability, marketability, profitability or fitness for a particular purpose of the Real Property, the effect of applicable planning, zoning and subdivision statutes, ordinances, regulations, restrictions and permits, the character and amount of any fees or charges that must be paid to further develop, improve and/or occupy the Real Property and all other matters relating to the Real Property. Prior to Closing, Buyer and its agents, contractors and subcontractors shall have the right to enter upon the Real Property, at reasonable times during ordinary business hours, to make inspections and tests as Buyer deems reasonably necessary and which may be accomplished without causing any material damage to the Real Property including, without limitation, the right to conduct a phase I environmental audit and an investigation with respect to the Real Property’s compliance with the requirements of Title III of the Americans with Disabilities Act of 1990. Notwithstanding the foregoing, in no event shall Buyer, its agents, contractors or subcontractors conduct any invasive testing on the Real Property without Seller’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. Buyer shall not materially interfere with any Tenant, occupant or invitee of the Real Property in making such inspections or tests, and shall return and restore the Property to substantially its original condition prior to such inspections or tests. Buyer shall not permit any liens or encumbrances to be placed against the Real Property in connection with Buyer’s investigation and inspection of the Real Property and/or in connection with Buyer’s activities on the Real Property. Buyer hereby agrees to and shall indemnify, defend and hold harmless Seller and Seller’s members, managers, partners, officers, directors, shareholders, employees, agents, representatives, invitees, successors and assigns (each, a “Seller Group Indemnitee”), from and against any and all claims, demands, and causes of action for personal injury or property damage, and all damages, judgments, liabilities, costs, fees and expenses (including reasonable attorneys’ fees) resulting therefrom, arising out of any entry onto the Real Property by Buyer, its agents, employees, contractors and/or subcontractors, pursuant to this Section 4.1(c) hereof, provided, however, Buyer shall not be obligated to indemnify, defend or hold harmless Seller or any Seller Group Indemnitee for any such claims, demands and/or causes of action or any such damages, judgments, liabilities, costs, fees or expenses caused by: (i) the discovery of conditions that were present before Buyer or its representatives entered onto the Real Property, or the accidental or inadvertent release of any Hazardous Materials that were in, on or under the Real Property prior to such entry; or (ii) the negligent or willful misconduct of Seller or any Seller Group Indemnitee. The covenants, agreements and obligations of Buyer set forth in this Section 4.1(c) shall survive the termination of this Agreement and the Closing, as applicable.
Site Inspection Where a site inspection is required by the Bid Specifications or Project Definition, Bidder shall be required to inspect the site, including environmental or other conditions for pre-existing deficiencies that may affect the installed Product, equipment, or environment or services to be provided and, which may affect Bidder’s ability to properly deliver, install or otherwise provide the required Product. All inquiries regarding such conditions shall be made in writing. Bidder shall be deemed to have knowledge of any deficiencies or conditions which such inspection or inquiry might have disclosed. Bidder must provide a detailed explanation with its Bid if additional work is required under this clause in order to properly complete the delivery and installation of the required Product or provide the requested service.
Investigation Period The first sentence of Section 4.1 of the Purchase Agreement is hereby deleted in its entirety and the following is hereby substituted in lieu thereof: “During the time period commencing upon the Effective Date of this Agreement, and terminating at 11:59 p.m. on October 18, 2012 (the “Investigation Period”), Buyer shall have the right to conduct and complete an investigation of all matters pertaining to the Property and Buyer’s purchase thereof including, without limitation, the matters described in this Section 4.1.”
Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.
EXAMINATION NOT OPTION Submission of this Lease shall not be deemed to be a reservation of the Premises. Landlord shall not be bound by this Lease until it has received a copy of this Lease duly executed by Tenant and has delivered to Tenant a copy of this Lease duly executed by Landlord, and until such delivery Landlord reserves the right to exhibit and lease the Premises to other prospective tenants. Notwithstanding anything contained in this Lease to the contrary, Landlord may withhold delivery of possession of the Premises from Tenant until such time as Tenant has paid to Landlord any security deposit required by Article 5, the first month’s rent as set forth in Article 3 and any sum owed pursuant to this Lease.
Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.
Evaluation Period Customer’s right to use the Services on a Trial Basis are time-limited and will terminate immediately upon the earlier of (i) the trial end date as specified in an Order Form or other document executed by the parties regarding such trial, or (ii) the start date of when Customer purchases a right to use such Services on a non-Trial Basis, or (iii) the date when QuoVadis terminates Customer’s right to use the Services on a Trial Basis (which QuoVadis may do at any time in its sole discretion). Customer must cease using the Services on a Trial Basis upon any such termination.
