Installation Waiver Company will waive the one-time installation charges associated with the implementation of Services within the 48 contiguous States of the U.S. provided under this Agreement except for the following services: (i) eDSL, (ii) VPN, (iii) Internet Dedicated OC3, OC12, OC48, Gig-E, (iv) PTT / third party services (including International Access and Company International), (v) Data Center, (vi) Paging, (vii) Managed Services, (viii) CPE, (ix) Enhanced Call Routing, (x) Local Disaster Recovery, (xi) Audio, Video and Net Conferencing, (xii) Voice over IP Services, (xiii) Security Services, (xiv) Non-Listing/Non-Published Service, (xv) Telecommunications Service Priority, and (xvi) Services provided by Company incumbent local exchange carriers (“ILECs”) or by Cellco Partnership and its affiliates d/b/a Company Wireless. Usage charges, monthly recurring charges, expedite charges, change charges, surcharges, charges for an unlisted or non-published number, any charges imposed by third parties (including access, egress, jack, or wiring charges), taxes or tax-like surcharges, or other Governmental Charges will not be waived.
Installation Where installation is required, Contractor shall be responsible for placing and installing the equipment or parts in the required locations at no additional charge, unless otherwise specified in the Price Sheets. All materials used in the installation shall be of good quality and shall be free of defects that would diminish the appearance of the equipment or render it structurally or operationally unsound. Installation includes the furnishing of any equipment, rigging, and materials required to install or replace the equipment or parts in the proper location. Contractor shall protect the site from damage and shall repair damages or injury caused during installation by Contractor or its employees or agents. If any alteration, dismantling, excavation, etc., is required to achieve installation, the Contractor shall promptly restore the structure or site to its original condition. Contractor shall perform installation work so as to cause the least inconvenience and interference with Customers and with proper consideration of others on site. Upon completion of the installation, the location and surrounding area of work shall be left clean and in a neat and unobstructed condition, with everything in satisfactory repair and order.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Installation of Equipment You represent that there are no legal, contractual or similar restrictions on the installation of the Equipment in the location(s) you have authorized. It is your responsibility to ensure compliance with all applicable building codes, zoning ordinances, homeowners’ association rules, covenants, conditions, and restrictions related to the Service, to pay any fees or other charges, and to obtain any permits or authorizations necessary for the installation or use of the Service (collectively "Legal Requirements"). You are solely responsible for any fines or similar charges for violation of any applicable Legal Requirements. You acknowledge and agree that Viasat or its designated service provider will be required to access your premises and computer to install and maintain the Equipment, including, without limitation, the antenna and its components. Standard Equipment installations performed by Viasat-authorized installers include: (i) installation of the antenna to an outside wall or sloped roof; (ii) travel to and from your Service location within 50 miles of the installer’s office; (iii) cable routed through one exterior wall and one interior wall or floor; (iv) connection of the antenna to the modem using up to 150 feet of cable; (v) connection of the modem to one computer using up to 7 feet of cable; and (vi) required mounting and cabling hardware. Any different or additional installation services or hardware are non-standard and may result in additional charges to be agreed upon between you and the installer. All installations include attaching the Equipment to your computer, installing software on your computer and configuring your computer to optimize the performance of the Internet Service. You confirm that you have reviewed the installation plan and agreed to any associated charges. If you approved a roof mount, you acknowledge the potential risks associated with this type of installation (including, without limitation, with respect to any warranty that applies to your roof or roof membrane). By signing this Agreement, scheduling one or more service or installation visits, and permitting us or our service provider to enter your home, you are authorizing Viasat and its service provider to perform all of the above actions. You are responsible for backing up the data on your computer and we highly recommend that you do so prior to permitting access to us or one of our designated service providers. NEITHER VIASAT NOR ITS SERVICE PROVIDER SHALL HAVE ANY LIABILITY WHATSOEVER FOR ANY LOSSES RESULTING FROM THE EQUIPMENT OR ANY INSTALLATION, REPAIR OR OTHER SERVICES ASSOCIATED WITH THE EQUIPMENT, INCLUDING WITHOUT LIMITATION, DAMAGE TO YOUR PREMISES OR LOSS OF SOFTWARE, DATA OR OTHER INFORMATION FROM YOUR COMPUTER. This limitation does not apply to any damages arising from the gross negligence or willful misconduct of us or one of our designated service providers. Time frames for installation, if any, are not guaranteed and may vary depending on the types of services requested and other factors.
Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Section 8.1(a) is amended in its entirety to read as follows: Subject to the provisions of Sections 8.2, 10, and 15, Tenant shall, at Tenant's sole cost and expense and at all times, keep the Building Complex and every part thereof in good order, condition and repair (whether or not the need for such repairs occurs as a result of Tenant's use, any prior use, the elements or the age of such portion of the Building Complex), including, without limiting the generality of the foregoing, plumbing, electrical lighting facilities, boilers, fired or unfired pressure vessels, fire hose connections, fixtures, interior walls, exterior walls, roof, ceilings, floors, windows, doors, plate glass, and skylights, parking areas and lighting, driveways, sidewalks, landscaping, irrigation systems, and subject to Section 8.1(b) below, heating, air conditioning and ventilating systems, but excluding any items which are the responsibility of Landlord pursuant to Section 8.2 below. Tenant, in keeping the Building Complex in good order, condition and repair, shall exercise and perform good maintenance practices, including, without limitation, providing janitorial services to the Building Complex substantially equivalent to those attached hereto as Exhibit I and, snow, ice and trash removal service. Tenant's obligations shall include restorations, replacements or renewals when necessary to keep the Building Complex and all improvements thereon or a part thereof in good order, condition and state of repair.
(b) Section 8.1(b) is amended in its entirety to read as follows: Tenant shall procure and pay the cost of a contract for maintenance of the heating, air conditioning and ventilating systems for the Building Complex with a reputable contractor licensed in the State of Colorado and reasonably satisfactory to Landlord.
(c) Section 8.1(c) is amended to replace, in both places where it is used, the word "Premises" with the words "Building Complex" and to add the words "including, without limitation, the Premises," before the words "after twenty".
(d) Section 8.2 is amended in its entirety to read as follows:
Equipment Installation In order to meet its obligations under this Agreement, a Party that owns, rents, or leases equipment (the equipment owner) may require installation of such equipment on property owned by another Party (the property owner), provided that the property is being used for an electric utility purpose and that the property owner shall not be required to do so if it would thereby be prevented from performing its own obligations or exercising its rights under this Agreement.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Move-in; Inspection; Delay Before Resident may access or occupy the premises, any required installments or other payments then due (including any Administrative Fee, which is earned and payable upon mutual execution of this Agreement) must be paid in full with cleared funds and guaranty or prepayment requirements satisfied. The application fee (if any) is non-refundable and is not applicable toward any other payments required of Resident under this Agreement. Prior to Resident’s taking possession of the assigned bedroom space (and any re-assigned bedroom space), Resident will conduct an inspection of the assigned bedroom space and apartment and will note on the Check-In/Check-Out Inspection Report (“Inspection Report”) any defects, damage or other conditions observed, if not already identified by Owner on such report; upon completion and approval by Owner, the Inspection Report will become part of this Agreement. At the time of move-out, Resident is encouraged to inspect the bedroom space and apartment with Owner’s representative by making an appointment during business hours at least 48 hours in advance. Within three business days following Resident’s move-out (or, as applicable, following the move-out of all residents of an apartment) at the termination of this Agreement, or within a reasonable time if Resident moves out without notifying Owner, Owner will note the then-present condition of the assigned bedroom space and apartment, including all appliances and fixtures, and any damages incurred and/or extraordinary cleaning deemed necessary by Owner or extraordinary wear as determined by Owner. Resident will promptly pay all costs of restoring the bedroom space and apartment to the same condition upon move-in, less normal wear. Resident acknowledges that except as provided in the Inspection Report, each bedroom space and apartment are being delivered in "as-is" condition, and Resident’s acceptance of the assigned bedroom space and apartment at the beginning of the Term constitutes Resident’s acknowledgment that the bedroom space and apartment and all fixtures are in good repair and condition. Owner will not be responsible for any damages or consequences suffered by Resident as a result of Owner’s inability to timely deliver possession of the apartment or assigned bedroom space to Resident on the anticipated Start Date; in such event, the rent payable will be abated until Owner tenders possession and such delay will not extend or decrease the term or change the End Date. Resident acknowledges that any model apartment at the Property shown to Resident in person, online or through other means is intended to be representative of the general quality and type of construction and materials within apartments. Specific items of décor and furnishings and the actual colors, styles, materials, upholstery and other treatments in the apartment assigned to Resident may vary from those in the model apartment. The actual apartment assigned to Resident may also vary in approximate size, square footage and layout. Resident’s apartment will not include custom lighting, lamps, decorations, linens, unattached appliances or other personal property as may be shown in the model apartment.
Installations Any special carpentry, wiring, electrical or other work, gas, steam, water and drainage connection shall be installed at Exhibitor’s expense, and in accordance with the building and Management’s direction.
