ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Provider Responsibilities The Private Child-Caring Facility (PCC) (a.k.a., Provider) must comply with the following requirements:
Professional Responsibilities Other activities to support the delivery of the Xxxxxx Xxxxxx Business Plan and Xxxxxx Mission Strategic Plan, as requested by your manager • As an employee, be responsible under the Work Health & Safety Act for the health and safety of all persons they come into contact with, during employment • All hazards and injuries must be reported through the normal process as set out in Xxxxxx Mission’s Work Health, Safety and Rehabilitation Quality Management System and site procedures • Participate in the review and maintenance of industry specific and internal audit processes, as per Xxxxxx Mission’s standard policy and procedures • In relation to Xxxxxx Mission and the Uniting Church in Australia, attend such functions, meetings, seminars, training courses as directed by your supervisor • In relation to Xxxxxx Mission attend worship services as encouraged by your supervisor • Participate on a quarterly basis in Xxxxxx Mission’s Employee contribution and development process • Take responsibility for personal career development and training • Participate in Xxxxxx Mission’s Orientation program, so as to gain an understanding of, and • promote, the application of the EEO, Affirmative Action, Privacy Act, Work Health & Safety Act and other relevant legislation • Administer Xxxxxx Mission’s philosophy of care and other relevant policy documents as appropriate • Demonstrate responsible stewardship of all resources, and willingness to report impropriety in keeping with the values of Xxxxxx Mission • Ensure the reputation and integrity of Xxxxxx Mission is maintained at all times • Maintain confidentiality
Scope of Professional Services 3.1 On the terms and conditions set forth in this Agreement, COUNTY hereby engages CONTRACTOR to provide all labor, materials and equipment to complete the Project/Service in accordance with the Scope of Services, attached hereto and incorporated herein as Attachment A, as modified or clarified by Addendum(s) # , dated , attached hereto and incorporated herein by reference as Attachment B. It is understood that the Scope of Services may be modified by change order as the Project/Service progresses, but to be effective and binding, any such change order must be in writing, executed by the parties, and in accordance with the COUNTY’s Purchasing Policies and Procedures. A copy of these policies and procedures shall be made available to the CONTRACTOR upon request.
3.2 The term of this Agreement shall be as follows (please check box): The parties acknowledge that this is a project specific agreement and that the single Project/Service shall be completed by the CONTRACTOR within ( ) calendar days after the Notice to Proceed is issued. The CONTRACTOR and COUNTY acknowledge that this Agreement is for a twelve (12) month term and that the CONTRACTOR shall complete the work as specified in the Scope of Services. The COUNTY has the option to renewal this Agreement for four (4) additional one (1) year period(s). The prices set forth in this Agreement shall prevail for the full duration of the initial contract term unless otherwise indicated elsewhere in this document. Prior to completion of each exercised contract term, the COUNTY may consider an adjustment to price based on changes in the following pricing index: CPI. It is the CONTRACTOR’s responsibility to request any pricing adjustment in writing under this provision. The CONTRACTOR’s written request for adjustment should be submitted thirty (30) calendar days prior to expiration of the then current contract term and clearly substantiate the requested increase. The written request for adjustment should not be in excess of the relevant pricing index change. If no adjustment request is received from the CONTRACTOR, the COUNTY will assume that the CONTRACTOR has agreed that the optional term may be exercised without pricing adjustment. Any adjustment request received after the commencement of a new option period shall not be considered. The COUNTY reserves the right to reject any written price adjustments submitted by the CONTRACTOR and/or to not exercise any otherwise available option period based on such price adjustments. Continuation of the contract beyond the initial period, and any option subsequently exercised, is a COUNTY’s prerogative, and not a right of the CONTRACTOR. This prerogative will be exercised only when such continuation is clearly in the best interest of the COUNTY. All work shall be performed in accordance with good commercial practice. The work schedule and completion dates shall be adhered to by the CONTRACTOR except in such cases where the completion date will be delayed due to acts of God, strikes, or other causes beyond the control of the CONTRACTOR. In these cases, the CONTRACTOR shall notify the COUNTY of the delays in advance of the original completion so that a revised delivery schedule can be appropriately considered by the COUNTY. No additional days shall be granted for rain delays.
3.3 The CONTRACTOR shall be solely responsible for obtaining all necessary approvals and permits to complete the Project/Service.
3.4 The CONTRACTOR shall remain appropriately licensed and/or employ the services of a subcontractor who is appropriately licensed throughout the course of the Project/Service. Failure to maintain all required licenses shall entitle the COUNTY, at its option, to terminate this Agreement.
3.5 Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency facility may be added to this Agreement at the option of the County. When required by the pricing structure of the Agreement, the CONTRACTOR shall be invited to submit price quotes for these additional facilities. The additional site(s) shall be added to this Agreement by formal modification. The COUNTY may obtain price quotes for the additional facilities from other vendors in the event that fair and reasonable pricing is not obtained from the CONTRACTOR or for other reasons at the County’s discretion. Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency may delete service for any facility when such service is no longer required, upon fourteen (14) calendar days written notice.
3.6 The CONTRACTOR acknowledges that it has sufficient understanding of the nature and location of the work; the general and local conditions, including but not limited to, those bearing upon transportation, disposal, handling and storage of materials; availability of labor, water, electric power, and roads; and uncertainties of weather or similar physical conditions at the site; the character of equipment and facilities needed preliminary to and during the completion of the Project/Service. The CONTRACTOR further acknowledges that the CONTRACTOR has satisfied itself as to the character, quality and quantity of surface and subsurface materials, obstacles or conditions of the site. Any failure by the CONTRACTOR to acquaint itself with any aspect of the work or with any of the applicable conditions shall not relieve the CONTRACTOR from responsibility for adequately evaluating the difficulty or cost of successfully performing the work required, nor shall it be considered a basis for any claim for additional time or compensation. The COUNTY assumes no responsibility for any conclusions or interpretations made by the CONTRACTOR on the basis of the information made available by the COUNTY. The COUNTY also assumes no responsibility for any understanding or representations made by its officers or agents during or prior to the execution of this contract, unless such understanding or interpretations are made in writing and incorporated herein by reference.
3.7 If required, the Contractors shall attend a mandatory pre-bid meeting. Whether or not there is a mandatory or non-mandatory pre-bid, the contractor shall be required to carefully examine any supplied drawings and/or specifications and be thoroughly aware regarding any and all conditions that may in any manner affect the work to be performed under the contract. If a pre-bid meeting is not required the Contractor shall visit the site to familiarize themselves with the Project/Service, see existing conditions, and take measurements. No additional allowances will be made for lack of knowledge of these conditions.
3.8 In the event of any conflict between the drawings and specifications contained within this Agreement, the following shall govern:
A. Addenda shall supersede all other contract documents to the extent specified in the addenda. Subsequent addenda shall supersede prior to addenda only to the extent specified therein.
B. Drawings and specifications are intended to agree and be mutually complete. Any item not contained within the drawings, but contained in the specifications, or vice-versa, shall be provided and/or executed as shown in either the drawing or specification at no extra costs to the COUNTY. Should anything not included in either the drawing and/or the specifications be necessary for the proper construction and/or operation of the Project/Service as herein specified, or should any error or disagreement between the specifications and drawings exist or appear to exist, the CONTRACTOR shall not derive unjust benefit thereby, or use such disagreement counter to the best interests of the COUNTY. The CONTRACTOR shall immediately notify the COUNTY’s Project Manager of any discrepancy and await the Project Manager’s direction before proceeding with the work in question.
3.9 CONTRACTOR acknowledges and agrees that CONTRACTOR shall utilize the U.S. Department of Homeland Security’s E-Verify system in accordance with the terms governing use of the system to confirm the employment eligibility of:
A. All persons employed by the CONTRACTOR during the term of this Agreement to perform employment duties within Lake County; and
B. All persons, including subcontractors, assigned by the CONTRACTOR to perform work pursuant to the contract.
3.10 CONTRACTOR acknowledges and agrees that, in accordance with Section 255.099, Florida Statutes, if the Project/Service assigned to CONTRACTOR is being supported in whole or in part by State funding the CONTRACTOR shall give preference to the employment of state residents in the performance of the work on the Project/Service if state residents have substantially equal qualifications to those of non- residents. If the CONTRACTOR is required to employ state residents, the CONTRACTOR shall contact the Department of Economic Opportunity to post the employment needs in the State’s job bank system. However, in work involving the expenditure of federal aid funds, this section may not be enforced in such a manner as to conflict with or be contrary to federal law prescribing a labor preference to honorably discharged soldiers, sailors, or marines, or prohibiting as unlawful any other preference or discrimination among the citizens of the United States.
PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board of Education agrees to pay the actual tuition costs of courses taken by a teacher at accredited colleges or universities up to three courses per two (2) year fiscal periods from July 1, 2006 to June 30, 2008 and July 1, 2008 to June 30, 2010 respectively, except as follows:
1. No teacher may be reimbursed for courses taken during the first year of teaching in Vineland.
2. Teachers taking courses in the second and third years of employment in Vineland will not receive remuneration until tenure has been secured. The remuneration will then be retroactive and will be paid to the teacher in a lump sum within sixty (60) days after the teacher has secured tenure.
3. All courses must be pre-approved by the Superintendent or his designee subject to the following requirements:
(a) A teacher must provide official documentation that he/she has obtained a grade of B or better;
(b) Reimbursement shall be paid only for courses directly related to teacher’s teaching field which increase the teacher’s content knowledge and are related to the teacher’s current certification, as determined by the Superintendent or his/her designee in his/her sole discretion; no reimbursement shall be paid for courses leading to a post graduate or professional degree in a field other than education or teaching. Further, effective September 1, 2010, all newly hired teachers shall not be eligible for reimbursement until they are tenured, and they shall not be eligible for retroactive reimbursement upon gaining tenure for courses taken prior to being tenured.
(c) The maximum total payments to be made by the Board shall not exceed $130,000.00. Courses shall be applied for no earlier than the following dates: Summer Session - April 1 Fall/Winter Session - June 1 Spring Session - October 1 Courses must, as set forth hereinabove in this sub-article 18.A.3, be pre-approved by the Superintendent or his designee, prior to the teacher commencing the course(s); and
(d) Teacher taking courses shall sign a contract requiring them to reimburse the Board for all tuition paid for a course if the teacher shall voluntarily leave the employ of the Board within one (1) full school/academic year of completion of said course, except that reimbursement shall not be required when the teacher shall voluntarily leave the employ of the Board due to a significant, documented life change.
4. Tuition reimbursement costs shall be a sum not to exceed the actual cost of college credits charged in an accredited public State college/University of the State of New Jersey.
B. When the Superintendent initiates in-service training courses, workshops, conferences and programs designed to improve the quality of instruction, the cooperation of the Vineland Education Association will be solicited. Notwithstanding the above, the initiation of in-service training courses, workshops, conferences and programs shall be determined solely at the discretion of the Board.
C. One professional leave day may be granted to a teacher upon request, according to the following guidelines:
1. The professional day may be for attendance at a workshop, seminar or visit to another school for the expressed purpose of self professional improvement for the job.
2. The request shall arrive in the office of the Superintendent of Schools at least ten (10) working days prior to the date requested and shall be reviewed by the immediate supervisor prior to submission. The Board reserves the right to deny a professional leave day before or immediately following a holiday or on a day which by its nature suggests a hardship for providing a substitute.
3. No more than two teachers from any one elementary school or from any one department in the secondary schools may be granted a professional leave for a given day.
4. The teacher may be required to submit a report to the Superintendent of Schools, Assistant Superintendent, supervisor (s), principal and staff regarding the activity of the professional day.
5. Costs incurred by the teacher for the professional day authorized under this Section shall be the teacher’s responsibility.
6. A maximum of 90 professional leave days may be authorized for the school year which shall be apportioned as follows: elementary, 35; grades seven and eight, 20; and high school, 35.
D. If the Board initiates a teacher’s attendance at a professional workshop, seminar or visit, the expenses shall be the responsibility of the Board. Further, this day shall not be subtracted from the 90 professional leave days granted to teachers of the Association.
E. The Board agrees to pay the full cost of courses taken by secretaries related to skills and knowledge improvement when such courses are required and approved by the Board.
F. The Board and the Association agree that it is important to communicate when developing and implementing current and future learning technologies, including but not limited to distance and on-line learning.
Engineer Responsibilities No subcontract relieves the Engineer of any responsibilities under this contract.
Professional Responsibility 19.01 The parties agree that resident care is enhanced if concerns relating to professional practice and workload are resolved in a timely and effective manner, as set out below; In the event that the Home assigns a number of residents or a workload to an individual employee or group of employees, such that she or they have cause to believe that she or they are being asked to perform more work than is consistent with proper resident care, she or they shall:
i) At the time the workload issue occurs, discuss the issue within the Home to develop strategies to meet resident care needs using current resources. If necessary, using established lines of communication, seek immediate assistance from an individual(s) identified by the Home who has responsibility for timely resolution of workload issues.
ii) Failing resolution at the time of occurrence of the workload issue, complain in writing to the Union-Management Committee within twenty (20) calendar days of the alleged improper assignment. The chairperson of the Union-Management Committee shall convene a meeting of the Union-Management Committee within twenty (20) calendar days of the filing of the complaint. The Union-Management Committee shall hear and attempt to resolve the complaint to the satisfaction of both parties. The Employer will provide a written response to the Union, with a copy to the ONA representation within ten (10) calendar days.
iii) Prior to the complaint being forwarded to the Independent Assessment Committee, the Union may forward a written report outlining the complaint and recommendations to the Director of Resident Care and/or the Administrator.
iv) At any time during this process, the parties may agree to the use of a mediator to assist in the resolution of the Professional Practice issues.
v) Any settlement arrived at under 19.01 (a) i) – iii) shall be signed by the parties.
vi) Failing resolution of the complaint within twenty (20) calendar days of the meeting of the Union-Management Committee, the complaint shall be forwarded to an independent Assessment Committee composed of three (3) registered nurses; one chosen by the Ontario Nurses' Association, one chosen by the Home and one chosen from a panel of independent registered nurses who are well respected within the profession. The member of the Committee chosen from the panel of independent registered nurses shall act as Chairperson.
vii) The Independent Assessment Committee shall set a date to conduct a hearing into the complaint, within twenty (20) calendar days of its appointment, and shall be empowered to investigate as is necessary to properly assess the merits of the complaint. The Independent Assessment Committee shall report its findings, in writing, to the parties within twenty (20) calendar days following completion of its hearing.
(b) i) The list of Independent Assessment Committee Chairpersons is attached as Appendix “B”. The members of the panel shall sit in rotation as agreed by the parties. If a panel member is unable to sit within the time limit stipulated, the panel member next scheduled to sit will be appointed by the parties.
PROFESSIONAL RESPONSIBILITY (APPLIES TO RNS ONLY 19.01 The parties agree that resident care is enhanced if concerns relating to professional practice and workload are resolved in a timely and effective manner, as set out below; In the event that the Home assigns a number of residents or a workload to an individual employee or group of employees, such that she or they have cause to believe that she or they are being asked to perform more work than is consistent with proper resident care, she or they shall:
i) At the time the workload issue occurs, discuss the issue within the Home to develop strategies to meet resident care needs using current resources. If necessary, using established lines of communication, seek immediate assistance from an individual(s) identified by the Home who has responsibility for timely resolution of workload issues.
ii) Failing resolution at the time of occurrence of the workload issue, complain in writing to the Union-Management Committee within twenty (20) calendar days of the alleged improper assignment. The chairperson of the Union-Management Committee shall convene a meeting of the Union-Management Committee within twenty (20) calendar days of the filing of the complaint. The Union-Management Committee shall hear and attempt to resolve the complaint to the satisfaction of both parties. The Employer will provide a written response to the Union, with a copy to the ONA representation within ten (10) calendar days.
iii) Prior to the complaint being forwarded to the Independent Assessment Committee, the Union may forward a written report outlining the complaint and recommendations to the Director of Resident Care and/or the Administrator.
iv) At any time during this process, the parties may agree to the use of a mediator to assist in the resolution of the Professional Practice issues.
v) Any settlement arrived at under 19.01 (a) i) – iii) shall be signed by the parties.
vi) Failing resolution of the complaint within twenty (20) calendar days of the meeting of the Union-Management Committee, the complaint shall be forwarded to an independent Assessment Committee composed of three (3) registered nurses; one chosen by the Ontario Nurses' Association, one chosen by the Home and one chosen from a panel of independent registered nurses who are well respected within the profession. The member of the Committee chosen from the panel of independent registered nurses shall act as Chairperson.
vii) The Independent Assessment Committee shall set a date to conduct a hearing into the complaint, within twenty (20) calendar days of its appointment, and shall be empowered to investigate as is necessary to properly assess the merits of the complaint. The Independent Assessment Committee shall report its findings, in writing, to the parties within twenty (20) calendar days following completion of its hearing.
(b) i) The list of Independent Assessment Committee Chairpersons is attached as Appendix “B”. The members of the panel shall sit in rotation as agreed by the parties. If a panel member is unable to sit within the time limit stipulated, the panel member next scheduled to sit will be appointed by the parties.
Professional Services Fees You agree to pay us the professional services fees in the amounts set forth in the Investment Summary. Those amounts are payable in accordance with our Invoicing and Payment Policy. You acknowledge that the fees stated in the Investment Summary are good-faith estimates of the amount of time and materials required for your implementation. We will bill you the actual fees incurred based on the in-scope services provided to you. Any discrepancies in the total values set forth in the Investment Summary will be resolved by multiplying the applicable hourly rate by the quoted hours.
Responsibilities of Both Parties 6.1 The CLEC providing the circuit between CLEC’s office and SBC-12STATE’s office shall make such circuits available for use in connection with the DA services covered herein. When the total traffic exceeds the capability of the existing circuits, additional circuits will be provided by the CLEC.
6.2 Where applicable, if additional ADAX cards and ASN Routers (with sync and token ring cards) are necessary, they will be provided by SBC-12STATE, and CLEC will reimburse SBC-12STATE for the cost, plus Engineering, Furnish and Installation.
