Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
EMINENT DOMAIN/CONDEMNATION 7.1 Lessor to notify Lessee 7.2 Whole taking, rents prorated 7.3 Taking
Casualty or Condemnation If, prior to the Closing, the Improvements or any material portion thereof (having a replacement cost equal to or in excess of $100,000 are damaged or destroyed by fire or casualty, or are taken by eminent domain by any governmental entity, and Seller is unable to restore such damage or destruction prior to the Closing Date in the case of a casualty, then Buyer shall have the option, exercisable by written notice given to Seller at or prior to the Closing, to terminate this Agreement, whereupon all obligations of all parties hereto shall cease, the Deposit shall be returned to Buyer, and this Agreement shall be void and without recourse to the parties hereto except for provisions which are expressly stated to survive such termination. If Buyer does not elect to terminate this Agreement as aforesaid or if such damage or destruction or taking has a replacement cost or is in an amount of less than $100,000, Buyer shall proceed with the consummation of the Closing (to the extent then otherwise obligated to do so) without reduction or offset of the Purchase Price, and in such case, unless the Seller shall have previously restored the Real Property to its condition prior to the occurrence of any such damage or destruction, Seller shall pay over or assign to Buyer all amounts received or due from, and all claims against, any insurance company or governmental entity as a result of such destruction or taking, and Seller shall pay the applicable deductible amount under the insurance maintained by Seller. In the event of any such casualty or condemnation, Seller agrees to (a) provide Buyer with copies of all written communications between Seller or the Partnership and their insurance carriers or the applicable governmental authorities, as applicable, the subject matter of which is the adjustment of insurance proceeds or condemnation awards, and (b) allow Buyer to review and make comments to any proposed settlement arrangement proposed to be entered into by Seller or the Partnership with any such third party; provided, that after the Inspection Period, if Buyer has not terminated this Agreement, Seller shall not enter into any settlement arrangement concerning casualty or condemnation in excess of $50,000 without obtaining the prior written consent of Buyer, which consent may be granted or withheld in Buyer’s sole discretion.
Casualty; Condemnation (a) If any condemnation or conveyance in lieu thereof of all or any portion of the Real Property occurs or is threatened prior to Closing (written notice of which shall be given to Purchaser by Seller promptly upon its receipt), Purchaser may at its option, either (i) terminate this Agreement by written notice to Seller given within twenty (20) days after Purchaser is notified of such actual or possible proceedings (but before the Closing), in which case all of the Escrow Funds shall be returned to Purchaser and all further rights and obligations of the parties under this Agreement shall terminate, except those expressly stated to survive termination, or (ii) proceed to Closing without abatement of the Purchase Price, in which case all proceeds or award (less any expenses incurred by Seller) shall be assigned to Purchaser. If any condemnation or conveyance in lieu thereof is presently pending or occurs after the date hereof, Seller shall not settle or agree to accept any compensation for same without Purchaser’s prior written consent, not to be unreasonably withheld.
(b) In the event of loss or damage to the Property or any portion thereof which is not “major” (as hereinafter defined), this Agreement shall remain in full force and effect, and neither Purchaser nor Seller shall have the right to terminate this Agreement and the parties shall nonetheless consummate this transaction in accordance with this Agreement, without any abatement of the Purchase Price or any liability or obligation on the part of Seller by reason of said damage except as set forth in the next sentence. In such event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(c) In the event of a “major” loss or damage to the Property or any portion thereof, Purchaser may terminate this Agreement by written notice to Seller, in which event the Escrow Funds shall be returned to Purchaser. If Purchaser does not give written notice of termination of this Agreement within twenty (20) days after Seller sends Purchaser written notice of the occurrence of major loss or damage, then Purchaser shall be deemed to have elected to proceed with Closing, in which event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(d) For purposes of this Section 12, “major” loss or damage refers to loss or damage to the Property or any portion thereof: (i) such that the cost of repair or restoration of the damage to a condition substantially identical to that prior to the event of damage would be, either be equal to or greater than $500,000 or require more than 120 days after the loss or damage to repair and restore, as determined by an independent appraiser chosen by Purchaser and reasonably acceptable to Seller, or (ii) having a material adverse impact upon the ability or feasibility of operating a nursing home facility on the Property, in substantially the same manner as the Property is being operated by Seller on the date hereof. Within ten (10) days after its occurrence, Seller shall give Purchaser written notice of any casualty and, if then available, an estimate of the restoration costs and time for restoration.
Casualty Damage 18.1 Tenant shall give immediate notice (by telephone, confirmed in writing) to Landlord of any damage caused to the Premises by fire or other casualty, and if Landlord does not elect to terminate this Lease as provided in Section 18.2, Landlord shall proceed with reasonable diligence and at its sole cost and expense to rebuild and repair the Building and/or the Premises, as the case may be, but Landlord shall not be obligated to expend for such rebuilding and repair any amount in excess of the amount of the insurance proceeds actually recovered by Landlord and made available by any Superior Lessor or Superior Mortgagee as a result of such loss.
18.2 If the Building or the Premises shall be destroyed or substantially damaged by a casualty not covered by Landlord’s insurance, or if 25% or more of the Premises is damaged or rendered untenantable by a casualty covered by Landlord’s insurance, or if the Premises are not affected but 25% of the Building or such portion of the Common Facilities as shall render the Premises or the Building untenantable is damaged or rendered untenantable, then in any such event Landlord may elect either to terminate this Lease or to proceed to rebuild and repair the Premises or that portion of the Building so damaged. Landlord shall give written notice to Tenant of such election within 90 days after the occurrence of such casualty, or within 30 days after the adjustment of the insurance settlement, whichever is later. In the event that such notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have commenced) with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights and remedies against Tenant under the terms of this Lease. If at any time prior to Landlord giving the aforesaid notice of termination or commencing the repair pursuant to Section 18.1, there shall be a Successor Landlord, such Successor Landlord shall have a further period of 60 days from the date of so taking possession to terminate this Lease by notice to Tenant and in the event that such a notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have been commenced) if Tenant is not occupying any portion of the Premises or otherwise as of the date provided in such notice, with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights against Tenant under the terms of this Lease.
18.3 Subject to the provisions of Section 18.1, Landlord’s obligation to rebuild and repair under this Article XVIII shall in any event be limited to restoring Landlord’s Work, as described in the Work Letter, to substantially the condition in which the same existed prior to the casualty, and to proceed, at the sole cost and expense of Tenant, to rebuild, repair and restore Tenant’s Work and any additional Improvements made by Tenant during the Term, all to substantially the condition existing prior to such casualty.
18.4 During the period from the occurrence of the casualty until Landlord’s repairs are completed, the Basic Rent payable pursuant to Article V and Additional Rent payable pursuant to Articles VI and VII shall be abated in that proportion which the Premises area rendered untenantable bears to the entire Premises area; provided, however, there shall be no abatement of any other charges or items of Additional Rent provided for herein to be paid by Tenant; and further provided, however, that should Tenant or anyone claiming through or under Tenant occupy a portion of the Premises during the period the repair work is taking place and prior to the date the Premises are no longer untenantable, the Rent allocable to such reoccupied portion, based upon the proportion which the reoccupied portion of the Premises bears to the total area of the Premises, shall be payable by Tenant from the date of such occupancy.
18.5 Landlord shall not the liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting in any way from any such damage by fire or other casualty or the repair thereof.
18.6 Notwithstanding any of the foregoing provisions of this Article, if, by reason of any negligence or willful act on the part of Tenant or any of its employees, agents, licensees, invitees or contractors, either (a) Landlord or the Superior Lessor or the Superior Mortgagee shall be unable to collect all of the insurance proceeds (including rent insurance proceeds) applicable to damage or destruction of the Premises or the Building or the Project by fire or other casualty or (b) the Premises or the Building or the Project shall be damaged or destroyed or rendered completely or partially untenantable on account of fire or other casualty then, without prejudice to any other remedy which may be available against Tenant, the abatement of rent provided for in Section 18.4 shall not be effective to the extent of the uncollected insurance proceeds.
Insurance Casualty Condemnation Restoration SECTION 8.1. INSURANCE SECTION 8.2. CASUALTY SECTION 8.3. CONDEMNATION SECTION 8.4. RESTORATION
