Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.
Maintenance Scheduling The NTO shall schedule maintenance of its facilities designated as NTO Transmission Facilities Under ISO Operational Control and schedule any outages (other than forced transmission outages) of said transmission system facilities in accordance with outage schedules approved by the ISO. The NTO shall comply with maintenance schedules coordinated by the ISO, pursuant to this Agreement, for NTO Transmission Facilities Under ISO Operational Control. The NTO shall be responsible for providing notification of maintenance schedules to the ISO for NTO Transmission Facilities Requiring ISO Notification. The NTO shall provide notification of maintenance schedules to affected Transmission Owners for NTO Transmission Facilities Requiring ISO Notification and Local Area Transmission Facilities pursuant to Section 3.5.3 of the ISO Services Tariff.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Account Maintenance Trade Allocations Trade Reporting; (Futures) Daily Trade Checkout Daily Statement Reconciliation
Maintenance, Etc The Company will maintain, preserve and keep, and will cause each Consolidated Subsidiary to maintain, preserve and keep, its properties which are used in the conduct of its business (whether owned in fee or a leasehold interest) in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements and renewals as the Company may determine to be appropriate to the conduct of its business.
Maintenance Services Subject to Client’s timely payment of the applicable maintenance fees, Accenture will make available the following maintenance services (“Maintenance Services”):
Maintenance of Services A. Reseller will adopt and adhere to the standards contained in the applicable BellSouth Work Center Interface Agreement regarding maintenance and installation of service.
B. Services resold under the Company’s Tariffs and facilities and equipment provided by the Company shall be maintained by the Company.
C. Reseller or its end users may not rearrange, move, disconnect, remove or attempt to repair any facilities owned by the Company, other than by connection or disconnection to any interface means used, except with the written consent of the Company.
D. Reseller accepts responsibility to notify the Company of situations that arise that may result in a service problem.
E. Reseller will be the Company's single point of contact for all repair calls on behalf of Reseller’s end users. The parties agree to provide one another with toll-free contact numbers for such purposes.
F. Reseller will contact the appropriate repair centers in accordance with procedures established by the Company.
G. For all repair requests, Reseller accepts responsibility for adhering to the Company's prescreening guidelines prior to referring the trouble to the Company.
H. The Company will xxxx Reseller for handling troubles that are found not to be in the Company's network pursuant to its standard time and material charges. The standard time and material charges will be no more than what BellSouth charges to its retail customers for the same services.
I. The Company reserves the right to contact Reseller’s customers, if deemed necessary, for maintenance purposes.
Servicing and Maintenance Standards On behalf of the Issuer, the Servicer shall (a) manage, service, administer, bill, collect and calculate Securitized Utility Tariff Charges in accordance with the Securitization Law and post collections in respect of the Securitized Utility Tariff Property with reasonable care and in material compliance with applicable Requirements of Law, including all applicable MPSC Regulations and guidelines, using the same degree of care and diligence that the Servicer exercises with respect to similar assets for its own account and, if applicable, for others; (b) follow customary standards, policies and procedures for the industry in Missouri in performing its duties as Servicer; (c) use all reasonable efforts, consistent with its customary servicing procedures, to enforce, and maintain rights in respect of, the Securitized Utility Tariff Property and to bill and collect the Securitized Utility Tariff Charges; (d) comply with all Requirements of Law, including all applicable MPSC Regulations and guidelines, applicable to and binding on it relating to the Securitized Utility Tariff Property; (e) file all MPSC notices described in the Securitization Law and file and maintain the effectiveness of UCC financing statements with respect to the property transferred under the Sale Agreement, and (f) take such other action on behalf of the Issuer to ensure that the Lien of the Indenture Trustee on the Securitized Utility Tariff Collateral remains perfected and of first priority. The Servicer shall follow such customary and usual practices and procedures as it shall deem necessary or advisable in its servicing of all or any portion of the Securitized Utility Tariff Property, which, in the Servicer’s judgment, may include the taking of legal action, at the Issuer’s expense but subject to the priority of payments set forth in Section 8.02(e) of the Indenture.
Maintenance of Business The Borrower shall, and shall cause each Subsidiary to, preserve and maintain its existence, except as otherwise provided in Section 8.10(c)
