Plan Schedule Sample Clauses

Plan Schedule. As soon as practicable and in any event within 10 days after the Borrower or one of its ERISA Affiliates becomes a party to a Plan, an updated Schedule V listing all Plans of the Borrower and its ERISA Affiliates.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Plan Schedule. After mutual execution of this Lease, Landlord shall proceed to prepare construction plans and specifications (the “Working Drawings and Specifications”), which shall be consistent with the Final Space Plan. Upon completion, Landlord shall present the Working Drawings and Specifications to Tenant for approval, which approval shall not be unreasonably withheld or delayed. Landlord shall then construct Landlord’s Work in substantial accordance with the Working Drawings and Specifications, and the cost of Landlord’s Work and any other Tenant Improvement Work, shall be paid in accordance with Sections 2.1 and 2.2 above. Any changes requested by Tenant to the Final Space Plan, or to the Working Drawings and Specifications, shall be at Tenant’s sole cost and shall be paid in accordance with Section 2.2 above. If completion of Landlord’s Work (including preparation of final plans and specifications) is delayed due to Tenant’s Delay, then the date reasonably determined by Landlord as the date upon which Landlord’s Work should have been substantially complete shall be extended by the number of days caused by Tenant’s Delay as reasonably determined by Landlord, without change to the Commencement Date of this Lease. As used herein, “Tenant Delay” means (i) Tenant’s failure to approve, within the time periods specified herein, any matter requiring Tenant’s approval under this Work Letter or if no time periods are specified herein, within a reasonable time period considering the nature of the matter requiring Tenant’s approval or within the time period specified in any written notice from Landlord concerning the matter; (ii) Tenant’s request for changes in the Working Drawings and Specifications, Final Space Plan, or Scope of Work, provided that Landlord shall provide Tenant with Landlord’s good faith estimate of the length of any delay which may be caused by such changes requested by Tenant; (iii) any postponement of construction at Tenant’s request; or (iv) any intentional interference by Tenant or Tenant’s employees, agents, or contractors.
Sample 1Sample 2
Plan Schedule. Within thirty (30) calendar days after Notice to Proceed, the Contractor shall submit a Plan Schedule of Working Drawings for review by the Owner's Representative. The Plan Schedule shall list all drawings and documents required for submittal in these Technical Specifications, Contract Drawings, and Contract Guidance Drawings and as required to meet all regulatory approval requirements. The schedule shall be submitted as paper copy and electronically as an Excel spreadsheet. The Plan Schedule shall include the following: A. A document number for each document listed 190 195 200 205 210 215 220 225 B. The document title C. The scheduled date the document will be submitted by the Contractor for Owner approval D. The scheduled date the document will be submitted by the Contractor for Regulatory Body approvals X. Xxxxxxx for recording the actual date of initial submittal, approval dates, and a column showing the current letter revision of each drawing. Include dates for revision and resubmittal if required.
Sample 1

Related to Plan Schedule

  • Compensation Schedule Except as otherwise provided herein, employees shall be compensated within the pay range assigned to the classification of the position in which they are employed and in accordance with the pertinent conditions of employment enumerated in this Agreement. Sec. 503 REGULAR PAY DAY: Employees shall be paid on or about the Friday following the end of the biweekly payroll period.

  • Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement. 2. Time off, based upon service in the Industry Vacation Plan, may be granted to an employee by mutual agreement between the Employer and the employee. The Employer shall not be required to give time off based upon service under the Industry Vacation Plan. However, if such additional industry vacation time off is granted to an employee, such time off shall be counted as time worked for the purpose of computing the employee's earned vacation benefits on his next anniversary date of employment.

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.

  • Salary Schedule The salaries of employees covered by this agreement are set forth in the salary schedule in Appendix A which is attached to and incorporated into this agreement.

  • Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.

  • Budget Schedule Subrecipient agrees that the expenditures of any and all funds under this Contract will be in accordance with the Budget Schedule, a copy of which is attached hereto as Attachment C, and which by this reference is incorporated herein and made a part hereof as if fully set forth.

  • Salary Schedules (a) The salary schedules shall be incorporated into this Agreement as Appendix V. (b) Salary schedules will contain Career Enhancement/Growth steps as described in Section 45.6.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Flexible Work Schedule A flexible work schedule is any schedule that is not a regular, alternate, 9/80, or 4/10 work schedule and where the employee is not scheduled to work more than 40 hours in the "workweek" as defined in Subsections F. and H., below.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!