Procedure for taking possession The Promoter, upon obtaining the occupancy certificate* from the competent authority shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within two months from the date of issue of occupancy certificate. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/association of allottees, as the case may be after the issuance of the completion certificate for the project. The promoter shall hand over the occupancy certificate of the apartment/ plot, as the case may be, to the allottee at the time of conveyance of the same.
Procedure for Claims (1) In the event the Indemnitee is named as a party in any action, claim, suit, proceeding or investigation upon which the Indemnitee intends to base a claim for indemnification hereunder, the Indemnitee shall give the Indemnitor prompt written notice of such action, claim, suit, proceeding or investigation (provided, however, that failure of the Indemnitee to provide such notice shall not relieve the Indemnitor of any liability to the Indemnitee the Indemnitor may have under this Agreement except to the extent that the Indemnitor is materially prejudiced by such failure).
(2) The Indemnitor shall participate in and, assume the defence of any such action, including for certainty any derivative action, claim, suit, proceeding or investigation all at the Indemnitor's expense provided, however, that counsel retained by the Indemnitor shall be satisfactory to the Indemnitee in the exercise of his reasonable judgement. Notwithstanding the Indemnitor's assumption of the defense of such action, claim, suit, proceeding or investigation, the Indemnitee shall have the right to employ separate counsel and to participate in, but not control, the defense of such action, claim, suit, proceeding or investigation, and the Indemnitor shall bear the reasonable fees, costs and expenses of such separate counsel as such fees, costs and expenses are incurred (provided that with respect to any single action, claim, suit, proceeding or investigation, the Indemnitor shall not be required to bear the fees, costs and expenses of more than one such counsel in any single jurisdiction) if (a) the use of counsel chosen by the Indemnitor to represent the Indemnitee would present such counsel with a conflict of interest; (b) the defendants, respondents or other parties in any such action, claim, suit, proceeding or investigation include both the Indemnitee on the one hand and the Indemnitor on the other hand, and the Indemnitee has reasonably concluded that representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them (in which case the Indemnitor shall not have the right to direct the defense of such action, claim, suit, proceeding or investigation on behalf of the Indemnitee); (c) the Indemnitor shall not have employed counsel satisfactory to the Indemnitee in the exercise of the Indemnitee's reasonable judgment to represent him, within a reasonable time after notice of the institution of such action, proceeding or investigation; or (d) the Indemnitor authorizes the Indemnitee to employ separate counsel at the Indemnitor's expense.
(3) The Indemnitee shall cooperate with the Indemnitor in the Indemnitor's defense by providing such information and other assistance which the Indemnitor may reasonably request in connection with such defense.
(4) The Indemnitor shall not, without the Indemnitee's prior written consent, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit or proceeding in respect of which indemnification may be sought hereunder (whether or not the Indemnitee is a party thereto) unless such settlement, compromise, consent or termination includes a release of the Indemnitee from any liabilities arising out of such action, claim, suit or proceeding. The Indemnitee shall not, without the Indemnitor's prior written consent, admit liability, settle, compromise, consent to the entry of any judgment in or otherwise seek to terminate any action, claim, suit, investigation or proceeding referred to in the preceding paragraph and the Indemnitee shall not disclose the existence of this Agreement unless required by law, subpoena, court order or upon the advice of counsel.
Procedure for Surrender of Rights Rights may be surrendered to the Right Agent, together with a written request for exchange or transfer, and thereupon the Right Agent shall issue in exchange therefor one or more new Rights as requested by the registered holder of the Rights so surrendered, representing an equal aggregate number of Rights; provided, however, that in the event that a Right surrendered for transfer bears a restrictive legend, the Right Agent shall not cancel such Right and issue new Rights in exchange therefor until the Right Agent has received an opinion of counsel for the Company stating that such transfer may be made and indicating whether the new Rights must also bear a restrictive legend.
How to Add or Remove Coverage for Family Members If your plan offers family coverage, you must notify your employer if you want to add or remove family members according to the Special Enrollment provisions described above. When adding or removing a family member, inform your employer in advance of the requested effective date and your employer will notify us. All requests must be made through your employer. We cannot directly add or remove coverage for you or your family members.
Limitation on Rights; No Right to Future Grants; Extraordinary Item of Compensation By entering into this Agreement and accepting the Performance Stock Units evidenced hereby, the Participant acknowledges: (i) that the Plan is discretionary in nature and may be suspended or terminated by the Company at any time; (ii) that the Award does not create any contractual or other right to receive future grants of Awards; (iii) that participation in the Plan is voluntary; (iv) that the value of the Performance Stock Units is not part of normal or expected compensation for purposes of calculating any severance, resignation, redundancy, end of service payments, bonuses, long-service awards, pension or retirement benefits or similar payments; and (v) that the future value of the Common Stock is unknown and cannot be predicted with certainty.
Preservation of Existence and Similar Matters Except as otherwise permitted under Section 9.4., the Borrower shall, and shall cause each other Loan Party and each other Subsidiary to, preserve and maintain its respective existence, rights, franchises, licenses and privileges in the jurisdiction of its incorporation or formation and qualify and remain qualified and authorized to do business in each jurisdiction in which the character of its properties or the nature of its business requires such qualification and authorization and where the failure to be so authorized and qualified could reasonably be expected to have a Material Adverse Effect.
Suspension for Convenience The School District shall have the right, at any time during the term of this Contract, to suspend all or any part of the Services, for the convenience of the School District, for the period of time that the School District, in its sole discretion, determines to be in the best interest of the School District, upon thirty (30) days’ prior written notice to the Architectural Designer (except that in the event of a public emergency, as determined by the School District, no such period of notice shall be required.).
13.2.1 If a suspension of the Services pursuant to this Paragraph 13.2 is for greater than thirty (30) days, the Architectural Designer shall have the right to submit a claim to the School District for the payment of costs for all Services performed and Reimbursable Expenses incurred in accordance with the provisions of this Contract prior to the effective date of the suspension.
13.2.2 The Architectural Designer shall be entitled to a one-day extension of the time of performance provided in this Contract for each day that it is suspended pursuant to this Paragraph 13.2.
13.2.3 The School District shall have the right, during the period of any suspension pursuant to this Paragraph 13.2, to terminate this Contract as provided in this Section 14, in Section 6, and elsewhere in this Contract.
No Limitation by Insurance The obligations under this Article 26 will not be limited in any way by any limitation of subcontractor’s insurance.
Procedure for Closing If Buyer shall not timely elect to terminate this Contract under Section 13.2 above, or if the loss, damage or condemnation is not substantial, Seller agrees to pay to Buyer at the Closing all insurance proceeds or condemnation awards which Seller has received as a result of the same, plus an amount equal to the insurance deductible, and assign to Buyer all insurance proceeds and condemnation awards payable as a result of the same, in which event the Closing shall occur without Seller replacing or repairing such damage. In the case of damage or casualty, at Buyer’s election, Seller shall repair and restore the Property to its condition immediately prior to such damage or casualty and shall assign to Buyer all excess insurance proceeds.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
