Project Budgets; Construction Cost Estimates Sample Clauses

Project Budgets; Construction Cost Estimates. 2.10.1 CM shall develop the Project Budget and its components including all Project Costs, including soft and hard costs. CM shall review and reconcile each Project Construction Cost Estimate made by the Architect, Developer/Builder and other members of the Project Team, as determined by the CM, throughout the design process and construction. CM shall develop and present for Board Approval the Project Budget and each component thereof. CM shall revise these until the Board accepts a final Project Budget and all the components thereof. 2.10.2 CM accepts and acknowledges that it is primarily responsible for developing each component of the Project Budget, including contingencies. CM shall specify all pre-design and pre-construction investigations and analyses necessary to prevent cost overruns, differing site conditions claims, other construction claims, design omissions, and budget overruns, including allowances, contingences and other reserves deemed appropriate for a Lease-Leaseback projects, or any other type of project delivery method used. 2.10.3 CM shall work cooperatively with the Project Team so that the construction cost of the work designed by the Design Team will not exceed the Construction Cost Estimate, as may be adjusted subsequently with the District’s written approval. CM shall notify the District immediately if it believes the construction cost of a Project will exceed the Construction Cost Estimate for that Project. 2.10.4 CM shall prepare evaluations of the District’s Project Budget, and review and reconciliation of the preliminary and detailed cost estimates prepared by the Architect, represent the CM’s best judgment as a professional familiar with the construction industry in the geographic area of the District. 2.10.5 CM acknowledges that the District is relying on CM to monitor, review, and verify each Project Construction Cost Estimate by the Architect, Developer/Builder or other member of the Project Team, at multiple instances throughout the Program and to cause the Construction Cost Estimate to be within the established Project Budget prior to approval by the Board of Trustees of the Guaranteed Maximum Price or Contract Price, whichever is applicable.
Sample 1
AutoNDA by SimpleDocs

Related to Project Budgets; Construction Cost Estimates

  • Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.

  • Project Budget A Project Budget shall be prepared and maintained by Grantee. The Project Budget shall detail all costs for which the Grant will be used during the Term. The Project Budget must be approved in writing by the Project Monitor. Grantee shall carry out the Project and shall incur costs and make disbursements of funds provided hereunder by the Sponsor only in conformity with the Project Budget. The current approved Project Budget is contained in Attachment “C”. Said Project Budget may be revised from time to time, but no Project Budget or revision thereof shall be effective unless and until the same is approved in writing by Project Monitor. The funds granted under this Grant Contract cannot be used to supplant (replace) other existing funds.

  • Construction Costs Under no circumstances shall the Consultant be liable for extra costs or other consequences due to unknown conditions or related to the failure of contractors to perform work in accordance with the plans and specifications. Consultant shall have no liability whatsoever for any costs arising out of the Client’s decision to obtain bids or proceed with construction before the Consultant has issued final, fully-approved plans and specifications. The Client acknowledges that all preliminary plans are subject to substantial revision until plans are fully approved and all permits obtained.

  • Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise. 3.2. Labor furnished by the State for the Project, however, with respect only to the construction of such components thereof as have been designed by the ARCHITECT/ENGINEER, shall be included in the Construction Cost at current market rates. Materials and equipment furnished by the State shall be included at current market prices, except that used materials and equipment shall be included as if purchased new for the Project.

  • Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!