Project Change Procedures Sample Clauses

Project Change Procedures. Any proposed changes in the scope of the Project, the Project objectives, key Project personnel, time period, or Budget must be requested in writing and approved by Agency. Grantee shall not perform any Project changes without a Grant Adjustment Form, submitted in the form provided by ODOT, and signed by Agency and Grantee. Any extension of the time period for completion or performance of the Project must be requested at least six weeks prior to the end of the stated time period and may need approval of the funding agency (identified in Section 8 of this Agreement) if the end of the grant award year is involved.
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Project Change Procedures i. If Recipient anticipates a change in scope, Key Milestone Dates, or Availability Termination Date, Recipient shall submit a written request to XXXXXxxxxxxXxxxxxx@xxxx.xxxxxx.xxx. The request for change must be submitted before the change occurs.
Sample 1Sample 2Sample 3See All (9)
Project Change Procedures i. If Recipient anticipates Project key milestones will be delayed by more than ninety (90) days from the key milestones shown in Exhibit A, Recipient shall submit a Request for Change Order (Form 734-2648), the form of which is hereby incorporated by reference, to ODOT’s Project Liaison as soon as Recipient becomes aware of any possible delay. The Request for Change Order must be submitted prior to the milestone completion date shown in Exhibit A. The fillable form can be downloaded on-line at the following address: xxxxx://xxx.xxxxxx.xxx/ODOT/LocalGov/Pages/Forms-Apps.aspx
Sample 1Sample 2
Project Change Procedures i. If Recipient anticipates that a Milestone (as that capitalized term is defined in subsection B(i) of Exhibit A) will be delayed, Recipient shall submit a Request for Change Order (Form 734- 2648), the form of which is hereby incorporated by reference, to ODOT’s Connect Oregon Program Manager as soon as Recipient becomes aware of any possible delay. The Request for Change Order must be submitted before the Milestone’s completion date shown in Table 1 of Exhibit A. The fillable form can be downloaded on-line at the following address: xxxxx://xxx.xxxxxx.xxx/ODOT/Forms/2ODOT/7342648.doc
Sample 1Sample 2
Project Change Procedures i. If Recipient anticipates a change in scope or Availability Termination Date, Recipient shall submit a written request to their ODOT Contact. The request for change must be submitted before the change occurs.
Sample 1
Project Change Procedures. Project change orders are only for changes to the schedule. Recipient shall submit a Request for Change Order (Form 109-009), the form of which is hereby incorporated by reference to ODA’s Program Coordinators:
Sample 1
Project Change Procedures. All travel outside the Project Director (described below) shall be responsible for implementing this Agreement and establishing and maintaining procedures that will ensure the effective administration of the Project.
Sample 1
AutoNDA by SimpleDocs
Project Change Procedures a. If Recipient either seeks a change in Project scope or anticipates that a Project milestone will be delayed by more than ninety (90) days from the milestones shown in Exhibit A, Recipient shall submit a Request for Change Order (Form 109-009) to ODA’s Project Coordinators as soon as Recipient becomes aware of any possible change in Project scope or delay. The Request for Change Order must be submitted prior to the milestone completion date shown in Table 1 of Exhibit A.
Sample 1
Project Change Procedures. Project changes are permitted only to the Scope of Work and only with the prior written permission of ODOT. If Recipient anticipates a need for project change, Recipient shall submit a request via email to the ODOT Project Manager. ODOT Project Manager may authorize changes to Scope of Work via email.
Sample 1

Related to Project Change Procedures

  • Exchange Procedures Promptly after the Merger I Effective Time, Parent shall instruct the Exchange Agent to mail to each record holder, as of the Merger I Effective Time, of an outstanding Certificate that immediately prior to the Merger I Effective Time represented shares of Company Common Shares (i) a letter of transmittal (which shall specify that delivery shall be effected, and risk of loss and title to the Certificates shall pass, only upon proper delivery of the Certificates to the Exchange Agent, and shall be in customary form and agreed to by Parent and the Company prior to the Merger I Effective Time) and (ii) instructions for use in effecting the surrender of the Certificates in exchange for the Merger Consideration payable in respect of the shares of Company Common Stock represented by such Certificates. Promptly after the Merger I Effective Time, upon surrender of Certificates for cancellation to the Exchange Agent together with such letters of transmittal, properly completed and duly executed, and such other documents as may be required pursuant to such instructions, the holders of such Certificates and the holders of Certificates who previously surrendered Certificates to the Exchange Agent with properly completed and duly executed Election Forms shall be entitled to receive in exchange therefor (A) shares of Parent Common Stock representing, in the aggregate, the whole number of shares of Parent Common Stock that such holder has the right to receive pursuant to Section 2.3 (after taking into account all shares of Company Common Stock then held by such holder) and (B) a check in the amount equal to the aggregate amount of cash that such holder has the right to receive pursuant to Section 2.3 and this Article II, including cash payable in lieu of any fractional Parent Common Stock pursuant to Section 2.6(e) and dividends and other distributions pursuant to Section 2.6(c). No interest shall be paid or accrued on any Merger Consideration, cash in lieu of fractional shares or on any unpaid dividends and distributions payable to holders of Certificates. In the event of a transfer of ownership of shares of Company Common Stock which is not registered in the transfer records of the Company, the Merger Consideration payable in respect of such shares of Company Common Stock may be paid to a transferee if the Certificate representing such shares of Company Common Stock is presented to the Exchange Agent, accompanied by all documents required to evidence and effect such transfer and the Person requesting such exchange shall pay to the Exchange Agent in advance any transfer or other Taxes required by reason of the delivery of the Merger Consideration in any name other than that of the registered holder of the Certificate surrendered, or shall establish to the satisfaction of the Exchange Agent that such Taxes have been paid or are not payable. Until surrendered as contemplated by this Section 2.6, each Certificate other than Certificates representing Appraisal Shares shall be deemed at any time after the Merger I Effective Time to represent only the right to receive upon such surrender the Merger Consideration payable in respect of the shares of Company Common Stock represented by such Certificate, cash in lieu of any fractional Parent Common Stock to which such holder is entitled pursuant to Section 2.6(e) and any dividends or other distributions to which such holder is entitled pursuant to Section 2.6(c).

  • Impasse Procedures The Parties shall seek to reach agreement relative to the appointment of a mediator not later than the sixtieth (60) day preceding the budget submission date. The Parties shall seek to reach agreement relative to the appointment of a fact finder not later than the forty-fifth (45) day preceding the budget submission date. The Parties shall consider but not be limited to the service of the Federal Mediation and Conciliation Service and the American Arbitration Association for a mediator and fact finder respectively. If the Parties fail to reach an agreement on the choice of a mediator or fact finder, the PELRB shall be petitioned under the provisions of 273-A: 12.

  • Dispute Procedures Contact Think with any questions concerning this Agreement or the Services by calling 0- 000-000-0000 (toll-free), Monday - Friday 8AM – 8PM ET (note these hours may change); by sending a letter to Think, P. O. Box 1288, Greens Farms, Connecticut 06838; or by sending an email to: xxxx@xxxxxxxxxxx.xxx. Think will refer all complaints and inquiries to a representative who will attempt to reach a mutually satisfactory resolution. If your complaint or inquiry is not resolved after you have called Think and/or the EDC, or for general information, you may contact the DPU for assistance toll-free at (000) 000-0000, or at XXXXxxxxxxx.Xxxxxxxxxx@xxxx.xxx, or by sending a letter to the DPU at: 0 Xxxxx Xxxxxxx, 0xx Xxxxx Xxxxxx, XX 00000. You have a right to make a formal or informal complaint to the DPU or any regulatory body with authority to review your complaint. In addition, mediation is available for disputes greater than $100. Nothing in the Arbitration, Waiver of Jury Trial, and Class Action Waiver Section below is intended to bar your right to make a complaint or request mediation. Arbitration, Waiver of Jury Trial, and Class Action Waiver. TO THE FULLEST EXTENT PERMITTED BY LAW, ANY DISPUTE ARISING OUT OF OR RELATING TO THIS AGREEMENT, INCLUDING CLAIMS ARISING IN CONTRACT, TORT, STATUTORY OR OTHERWISE, SHALL BE SETTLED EXCLUSIVELY AND FINALLY BY ARBITRATION IN ACCORDANCE WITH THE CONSUMER ARBITRATION RULES AND PROCEDURES OF THE AMERICAN ARBITRATION ASSOCIATION. ANY ARBITRATION PROCEEDING HEREUNDER SHALL BE CONDUCTED EXCLUSIVELY IN MASSACHUSETTS. BY ENTERING INTO THIS AGREEMENT, CUSTOMER AGREES TO BINDING ARBITRATION AND WILL NOT PURSUE ANY FURTHER ACTION IN A COURT OF LAW. CUSTOMER WILL NOT HAVE THE RIGHT TO PARTICIPATE IN A REPRESENTATIVE CAPACITY OR AS A MEMBER OF ANY CLASS OF CLAIMANTS PERTAINING TO ANY CLAIM SUBJECT TO ARBITRATION. Think’s Arbitration and Class Action Wavier Policy Addendum, which is available and provided to you during the enrollment process is incorporated herein and made a part hereof, contains additional details and a complete description of the terms and conditions of the Arbitration and Class Action Waiver Policy, including your ability to opt out. Warranties. THINK MAKES NO EXPRESS REPRESENTATION OR WARRANTIES WITH REGARD TO THE PROVISION OF ELECTRIC SERVICE AND DISCLAIMS ANY AND ALL WARRANTIES, EXPRESSED OR IMPLIED, OR ARISING OUT OF ANY COURSE OF DEALING OR USAGE OF TRADE EXCEPT WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Limitation of Liability. You will be deemed to be in exclusive control (and responsible for any damages or injury caused thereby) of the electric power after receipt at the delivery point(s). TO THE FULLEST EXTENT PERMITTED BY LAW, THINK WILL NOT BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, PUNITIVE, EXEMPLARY, OR INDIRECT DAMAGES (INCLUDING LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES), WHETHER BY STATUTE, IN CONTRACT OR TORT, EVEN IF THE RESULT OF NEGLIGENCE (WHETHER SOLE, JOINT, CONCURRENT, ACTIVE, OR PASSIVE). ALL OTHER LIABILITY WILL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, AND SUCH DIRECT ACTUAL DAMAGES WILL BE THE SOLE AND EXCLUSIVE REMEDY. YOU HEREBY WAIVE ALL OTHER REMEDIES AT LAW OR IN EQUITY. THERE ARE NO THIRD-PARTY BENEFICIARIES TO THIS AGREEMENT. To the extent any damages required to be paid hereunder are liquidated, the Parties acknowledge that the damages are not intended and shall not be construed as a penalty, such damages are difficult or impossible to determine, that otherwise obtaining an adequate remedy is inconvenient or impossible, and that the liquidated damages constitute a reasonable approximation of the harm or loss.

  • AUDIT REVIEW PROCEDURES A. Any dispute concerning a question of fact arising under an interim or post audit of this AGREEMENT that is not disposed of by AGREEMENT, shall be reviewed by LOCAL AGENCY’S Chief Financial Officer.

  • NEGOTIATING PROCEDURES 4.01 A request for professional negotiations shall be submitted in writing by the SHTA to the Board or its designated representative or by the Board’s designated representative to SHTA before April 1 of the year (approximately 90 calendar days) of the expiration of the existing Agreement. A copy of the notice shall be filed with the State Employment Relations Board. A mutually convenient meeting shall be held by April 15th in which both parties shall exchange negotiation packages which shall include additions to, deletions from or revisions of the existing agreement. No new items shall be introduced for negotiations during said negotiations except what may be mutually agreed upon by both negotiation teams.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!