PROPOSAL CONTENT REQUIREMENTS Sample Clauses

PROPOSAL CONTENT REQUIREMENTS. Section L Proposal Preparation Instructions: Section L attachments:  L-1 Bidder’s Question Form  L-2 Resume Template
Sample 1Sample 2
AutoNDA by SimpleDocs
PROPOSAL CONTENT REQUIREMENTS. Include with your proposal all required forms, completed and signed as necessary. Submit your proposal in a sealed envelope clearly indicating Company Name, RFP Title and the wording, "SEALED PROPOSAL", on the outside of the envelope. The RFP documents must be completed in full, submitted in the following order and returned by the designated date and time to be considered valid. When completing the forms, please use an ink pen and print legibly or generate the forms from a computer print-out. Make sure there are no mistakes; unit pricing will be binding if a contract is awarded. ❖ Cover Sheet of RFP ➢ Complete and sign the first page of the RFP and submit as the Cover Sheet to the Contractor's Proposal ❖ Master Service Agreement – DRAFT ➢ A draft of the Master Service Agreement has been included for reference. The selected contractor will execute a final version of the Master Service Agreement after proposals are opened. ❖ Requirements & Specifications ➢ The Contractor shall perform landscape maintenance services in accordance with the Texas Department of Transportation’s (TxDOT) Standard Specifications for Construction and Maintenance of Highways, Streets and Bridges adopted November 1, 2014, except as noted or revised in the RFP. ❖ Attachment 1 - Price Form ➢ Pricing provided on these forms shall be valid for the initial 2-year contract period with an expected start date of November 1, 2017 and an expected completion date of September 30, 2019. The Authority is exempt from all federal excise, state and local taxes. Texas Limited Sales Tax Exemption Certificates will be furnished upon request. ➢ Contractor must complete all pricing line items. All prices must be written in ink or typewritten. In case of any discrepancy between unit and extended pricing, unit pricing governs.
Sample 1
PROPOSAL CONTENT REQUIREMENTS. ‌ This section describes the Companies’ expectations and requirements for the content of Proposals. Proposals that do not meet the following criteria will be deemed ineligible and not considered for further evaluation. The Companies expect Respondents to provide any information that could impact the Respondent’s ability to enter into a PPA with each of the Companies. If it appears that certain information is inadvertently omitted from a Proposal, Brattle may contact the Respondent to obtain the information. All Proposals must include a table of contents and provide concise and complete information on all of the following topics: V.1 Standard RFP Response Form‌ Respondents shall provide a completed Appendix 3 (RFP Response Form). Please note that Appendix 3 does not capture all of the information required to be provided in response to this RFP. V.2 Executive Summary‌ Proposals must include an executive summary of the Proposal’s characteristics, including any unique aspects and benefits. V.3 Name and Location‌ Respondents shall state the name of the Facility, the county and EDC service territory where the generating facility is located, the owner of the Facility, the PJM commercial pricing node associated with the Facility, and the expected commercial in-service date for the facility. The location must be in the Commonwealth of Pennsylvania and serviced by PJM. V.4 Net Capability of Generating Facility‌ Respondents shall state the net capability of the Facility that would be applicable for each month of a calendar year as well as the nameplate capacity of the Facility.
Sample 1
PROPOSAL CONTENT REQUIREMENTS. To achieve a uniform review process and obtain the maximum degree of comparability for the Selection Committee, proposals should be organized in the manner specified below. Proposal length may not exceed 10 pages.
Sample 1
PROPOSAL CONTENT REQUIREMENTS. Offerors shall provide the information requested in the following paragraphs in the volumes indicated. If additional information is provided in other volumes or sections, Offerors shall provide clear references to the location in the proposal where the information may be found. An Offeror’s proposal shall be sufficiently detailed to enable Government evaluation board members to make a thorough evaluation against specific factors established in Section M, and to arrive at a sound determination as to whether or not the prospective Offeror will be able to perform in accordance with the stated requirements. Discussions of each topic in the proposal shall exhibit continuity and logical progression. Data shall be organized to enable Government personnel to thoroughly evaluate the proposal. A concise, legible, neat, orderly and comprehensive proposal is required. The Government does not assume the duty to search for data to cure problems it finds in proposals. Failure to conform to all requirements of this solicitation may form the basis for rejection of the proposal.
Sample 1

Related to PROPOSAL CONTENT REQUIREMENTS

  • License Requirements The Hotel’s alcoholic beverage license requires that the Hotel shall: (i) request proper identification (photo ID) of any person of questionable age and refuse alcoholic beverage service if the person is either under age or proper identification cannot be produced, and (ii) refuse alcoholic beverage service to any person who, in the Hotel’s judgment, appears to be intoxicated; and (iii) instruct its personnel to avoid encouraging patrons to consume alcoholic beverages (commonly referred to as “over-pouring”).

  • Sublicense Requirements Any Sublicense: (A) is subject to this Agreement; (B) will reflect that any sublicensee will not further sublicense; (C) will prohibit sublicensee from paying royalties to an escrow or other similar account; (D) will expressly include the provisions of Sections 8, 9, and 10 for the benefit of Stanford; and (E) will include the provisions of Section 4.4 and require the transfer of all the sublicensee’s obligations to *****, including the payment of royalties specified in the Sublicense, to Stanford or its designee, if this Agreement is terminated. If the sublicensee is a spin-out from *****, ***** must guarantee the sublicensee’s performance with respect to the payment of Stanford’s share of Sublicense royalties.

  • Minimum Vendor License Requirements Vendor shall maintain, in current status, all federal, state, and local licenses, bonds and permits required for the operation of the business conducted by Vendor. Vendor shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of goods or services under the TIPS Agreement. TIPS and TIPS Members reserve the right to stop work and/or cancel a TIPS Sale or terminate this or any TIPS Sale Supplemental Agreement involving Vendor if Vendor’s license(s) required to perform under this Agreement or under the specific TIPS Sale have expired, lapsed, are suspended or terminated subject to a 30‐day cure period unless prohibited by applicable statue or regulation.

  • Agreement Requirements This agreement will be issued to cover the Janitorial Service requirements for all State Agencies and shall be accessible to any School District, Political Subdivision, or Volunteer Fire Company.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Forecasting Requirements 19.5.1 The Parties shall exchange technical descriptions and forecasts of their Interconnection and traffic requirements in sufficient detail necessary to establish the Interconnections necessary for traffic completion to and from all Customers in their respective designated service areas.

  • Minimum Vendor Legal Requirements Vendor shall remain aware of and comply with this Agreement and all local, state, and federal laws governing the sale of products/services offered by Vendor under this contract. Such applicable laws, ordinances, and policies must be complied with even if not specified herein.

  • Changes to Specifications All Specifications and any changes thereto agreed to by the parties from time to time shall be in writing, dated and signed by the parties. Any change to the Process shall be deemed a Specification change. No change in the Specifications shall be implemented by Catalent, whether requested by Client or requested or required by any Regulatory Authority, until the parties have agreed in writing to such change, the implementation date of such change, and any increase or decrease in costs, expenses or fees associated with such change (including any change to Unit Pricing). Catalent shall respond promptly to any request made by Client for a change in the Specifications, and both parties shall use commercially reasonable, good faith efforts to agree to the terms of such change in a timely manner. As soon as possible after a request is made for any change in Specifications, Catalent shall notify Client of the costs associated with such change and shall provide such supporting documentation as Client may reasonably require. Client shall pay all costs associated with such agreed upon changes. If there is a conflict between the terms of this Agreement and the terms of the Specifications, this Agreement shall control. Catalent reserves the right to postpone effecting changes to the Specifications until such time as the parties agree to and execute the required written amendment.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Licensing Requirements (a) Employer and Employee hereby covenant and agree that this Agreement and/or Employee’s employment may be subject to the approval of one or more gaming regulatory authorities (the “Authorities”) pursuant to the provisions of the relevant gaming regulatory statutes (the “Gaming Acts”) and the regulations promulgated thereunder (the “Gaming Regulations”). Employer and Employee hereby covenant and agree to use their best efforts to obtain any and all approvals required by the Gaming Acts and/or Gaming Regulations. In the event that (i) an approval of this Agreement or Employee’s employment by the Authorities is required for Employee to carry out Employee’s duties and responsibilities set forth in Section 3 of this Agreement, (ii) Employer and Employee have used their best efforts to obtain such approval, and (iii) this Agreement or Employee’s employment is not so approved by the Authorities, then this Agreement shall immediately terminate and shall be null and void, thus extinguishing any and all obligations of either party, subject to any surviving obligations of Employee under Sections 9, 10 and 21. (b) If applicable, Employer and Employee hereby covenant and agree that, in order for Employee to discharge the duties required under this Agreement, Employee must apply for or hold a license, registration, permit or other approval (the “License”) as issued by the Authorities pursuant to the terms of the relevant Gaming Act and as otherwise required by this Agreement. In the event Employee fails to apply for and secure, or the Authorities refuse to issue or renew Employee’s License, Employee, at Employer’s sole cost and expense, shall promptly defend such action and shall take such reasonable steps as may be required to either remove the objections or secure or reinstate the Authorities’ approval, respectively. The foregoing notwithstanding, if the source of the objections or the Authorities’ refusal to renew or maintain Employee’s License arise as a result of any of the acts, omissions or events described in Section 1(c) of this Agreement, then Employer’s obligations under this Section 8 also shall not be operative and Employee shall promptly reimburse Employer upon demand for any expenses incurred by Employer pursuant to this Section 8. (c) Employer and Employee hereby covenant and agree that the provisions of this Section 8 shall apply in the event Employee’s duties require that Employee also be licensed by governmental agencies other than the Authorities.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!