Representative of District Sample Clauses

Representative of District. The District Manager of District, or his or her designated representative, shall represent District in all matters pertaining to the services to be rendered under this Agreement, except where and if approval specifically is required by District’s Board of Directors. All requirements pertaining to services to be rendered under this Agreement shall be submitted to the District Administrator or General Manager of the District. CSDA shall consult with the District Administrator or General Manager on all matters relative to this Agreement and District shall cooperate with CSDA in all matters relative to this Agreement in such a manner as will result in the performance of the Work without delay.
Sample 1Sample 2
AutoNDA by SimpleDocs
Representative of District. The Construction Manager will be an advisor and representative of the District in providing the Services in accordance with the terms and conditions of this Agreement. The District agrees that the District will be represented by the Construction Manager in communications with the Architect and the Contractor during and in connection with the performance of the Services required by this Agreement. 2.1.1 The Construction Manager accepts the relationship of trust and confidence established by this Agreement and covenants with the District to exercise the Construction Manager’s skill and judgment in furthering the interests of the District; furnish efficient business administration and supervision; furnish at all times an adequate supply of personnel and materials; and perform the Services in an expeditious and economical manner consistent with the District’s interests. 2.1.2 In providing Services, the Construction Manager will maintain a working relationship with the Contractor and Architect on behalf of the District. However, nothing in this Agreement will be construed to mean that the Construction Manager supplants or assumes any of the Contractor’s or the Architect’s contractual or customarily assumed responsibilities. The Construction Manager will not be responsible for: construction means, methods, sequences, or procedures utilized by the Contractor, or for the Contractor’s failure to carry out the Work in accordance with the Construction Contract Documents; safety or security in connection with a Project or the performance of the Work; inspection of the Work on a Project normally carried out by the Contractor or Architect (unless otherwise specified as a Basic Service in Attachment A); acts or omissions of the Architect; or adequacy or accuracy of any part or all of a Project design. 2.1.3 Both parties to this Agreement recognize that performance under the agreement(s) between the District and the Contractor, the District and the Architect, or District and any other third party is solely the responsibility of the individual Contractor, Architect, or third party; consequently, nothing in this Agreement will be construed to mean that said performance or lack thereof by Contractor and/or Architect, or any third party, is in any way to be considered the responsibility of the Construction Manager.
Sample 1
Representative of District. No teacher shall present him/herself as a representative of the district without written district authorization to do so, provided that a teacher may state he/she is an employee of the district.
Sample 1
Representative of District. Xxxxx Xxxxx (“District’s Representative”) is hereby designated to represent District and except as otherwise provided herein authorized to act on its behalf with respect to the Services specified herein and to make all decisions in connection therewith. District may substitute District’s Representative at any time upon written notice to Consultant.
Sample 1
Representative of District is hereby designated as being the representative the District authorized to act in its behalf with respect to the work and services specified herein and make all decisions in connection therewith ("Project Coordinator").
Sample 1

Related to Representative of District

  • Liability of District 13.1. Other than as provided in this Agreement, District’s financial obligations under this Agreement shall be limited to the payment of the compensation provided in this Agreement. Notwithstanding any other provision of this Agreement, in no event shall District be liable, regardless of whether any claim is based on contract or tort, for any special, consequential, indirect or incidental damages, including, but not limited to, lost profits or revenue, arising out of or in connection with this Agreement or the Services performed in connection with this Agreement. 13.2. District shall not be responsible for any damage to persons or property as a result of the use, misuse or failure of any equipment used by Architect, or by its employees, even though such equipment be furnished or loaned to Architect by District.

  • Representative The employee or School Board may be represented during any step of the procedure by any person or agent designated by such party to act in his behalf.

  • Use of District Facilities 1 The Association shall have the right to use District facilities for Association meetings provided advance approval is granted by the District according to the District Building Use Guidelines.

  • Representative of the Borrower; Addresses Section 7.01. The Minister of Finance of the Borrower is designated as representative of the Borrower for the purposes of Section 11.03 of the General Conditions. Section 7.02. The following addresses are specified for the purposes of Section

  • REPRESENTATIVE; ADDRESSES 5.01. The Borrower’s Representative is the Minister of Finance. 5.02. The Borrower’s Address is: Ministry of Finance Sanlihe Beijing 100820 People’s Republic of China Facsimile: (00-00) 00 00 00 00 5.03. The Bank’s Address is: International Bank for Reconstruction and Development 0000 X Xxxxxx, X.X. Washington, D.C. 20433 United States of America Cable address: Telex: Facsimile: INTBAFRAD Washington, D.C. 248423(MCI) or 64145(MCI) 0-000-000-0000 AGREED at Beijing, People’s Republic of China, as of the day and year first above written. PEOPLE’S REPUBLIC OF CHINA By /s/ Xxxxx Xxxxxxxx INTERNATIONAL BANK FOR RECONSTRUCTION AND DEVELOPMENT By /s/ Xxxxx Xxxxxxx

  • Representative of the Recipient; Addresses Section 7.01. The Minister of Finance of the Recipient is designated as representative of the Recipient for the purposes of Section 11.03 of the General Conditions.

  • Chief Executive Office; Jurisdiction of Organization Seller shall not move its chief executive office from the address referred to in Section 13(a)(17) or change its jurisdiction of organization from the jurisdiction referred to in Section 13(a)(17) unless it shall have provided Buyer 30 days’ prior written notice of such change.

  • Representatives Representatives" shall mean officers, directors, employees, agents, attorneys, accountants, advisors and representatives.

  • Chief Executive Office; Change of Name; Jurisdiction of Organization (a) The exact legal name, type of organization, jurisdiction of organization, federal taxpayer identification number, organizational identification number and chief executive office of such Grantor is indicated next to its name in Sections I.A. and I.B. of the Perfection Certificate. Such Grantor shall furnish to the Collateral Agent prompt written notice of any change in (i) its corporate name, (ii) the location of its chief executive office, its principal place of business, any office in which it maintains books or records relating to Collateral owned by it or any office or facility at which Collateral owned by it is located (including the establishment of any such new office or facility), (iii) its identity or type of organization or corporate structure, (iv) its federal taxpayer identification number or organizational identification number or (v) its jurisdiction of organization (in each case, including, without limitation, by merging with or into any other entity, reorganizing, dissolving, liquidating, reincorporating or incorporating in any other jurisdiction). Such Grantor agrees (A) not to effect or permit any such change unless all filings have been made under the UCC or otherwise that are required in order for the Collateral Agent to continue at all times following such change to have a valid, legal and perfected first priority security interest in all the Collateral (subject to, with respect to priority, Permitted Encumbrances having priority by operation of law) and (B) to take all action reasonably satisfactory to the Collateral Agent to maintain the perfection and priority of the security interest of the Collateral Agent for the benefit of the Credit Parties in the Collateral intended to be granted hereunder. Each Grantor agrees to promptly provide the Collateral Agent with certified Organization Documents reflecting any of the changes described in the preceding sentence. (b) The Collateral Agent may rely on opinions of counsel as to whether any or all UCC financing statements of the Grantors need to be amended as a result of any of the changes described in SECTION 4.3(a). If any Grantor fails to provide information to the Collateral Agent about such changes on a timely basis, the Collateral Agent shall not be liable or responsible to any party for any failure to maintain a perfected security interest in such Grantor’s property constituting Collateral, for which the Collateral Agent needed to have information relating to such changes. The Collateral Agent shall have no duty to inquire about such changes if any Grantor does not inform the Collateral Agent of such changes, the parties acknowledging and agreeing that it would not be feasible or practical for the Collateral Agent to search for information on such changes if such information is not provided by any Grantor.

  • Appointment of Distributor The Client hereby appoints the Distributor as its exclusive agent for the sale and distribution of Shares of the Funds, on the terms and conditions set forth in this Agreement, and the Distributor hereby accepts such exclusive appointment and agrees to perform the services and duties set forth in this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!