Required Financing Submittals; Submittal of Construction Contract Sample Clauses

Required Financing Submittals; Submittal of Construction Contract. Such evidence of financing for Phase I and readiness to commence construction of Phase I shall include all of the following: (i) An updated pro forma and Final Budget for Phase I showing the projected costs of construction of Phase I, including all onsite and offsite improvements to be constructed in connection therewith. (ii) A copy of the Lender’s binding commitment obtained by Developer for the Primary Loan for Phase I and, when available, copies of all loan documents evidencing the Primary Loan therefor. The Primary Loan commitments for financing shall be in such form and content acceptable to Authority and its financial advisor(s) and its legal advisor(s) and as such reasonably evidences a legally binding, firm and enforceable commitment, subject only to the Lender’s customary and normal conditions and terms and subject to the requirements of this Section 3.10. The commitment also shall state the specific terms and requirements, if any, by the Lender relating to subordination of the Regulatory Agreement and the Authority Subordinate Loan (but in no event the Ground Lease). Developer shall provide written certification to Authority that the loan documents submitted are correct copies of the actual loan documents to be executed by Developer concurrently with the Closing. If the Lender requires a subordination agreement between or among Lender, Authority and/or Developer, Authority shall review the form of subordination subject to the reasonable review and approval of Authority Executive Director and legal counsel(s), subject to one or more of the conditions set forth in Section 3.10.10 necessary for the Primary Loan to be a title insured first monetary lien on Phase I; provided, however, in no event shall Authority’s fee interest in the Site be subordinated to the Primary Loan or any other financing obtained by Developer or any other encumbrance or lien against the Site. All costs incurred for the review and completion of each subordination agreement (except and excluding the first subordination agreement entered into at the Closing for Phase I) and any amendment, modification or other reaffirmation thereof shall be expressly subject to Developer (or another person or entity other than Authority or City) paying all Third Party Costs (as defined in Section 716) incurred by Authority (or City) in connection therewith, with payment of such incurred costs a condition precedent to any obligation of Authority to sign such subordination or reaffirmation docume...
Sample 1See All (6)
AutoNDA by SimpleDocs

Related to Required Financing Submittals; Submittal of Construction Contract

  • Potential Conflicts and Compliance With Mixed and Shared Funding Exemptive Order 7.1. The Board of Trustees of the Fund (the “Board”) will monitor the Fund for the existence of any material irreconcilable conflict between the interests of the Contract owners of all separate accounts investing in the Fund. An irreconcilable material conflict may arise for a variety of reasons, including: (a) an action by any state insurance regulatory authority; (b) a change in applicable federal or state insurance, tax, or securities laws or regulations, or a public ruling, private letter ruling, no-action or interpretative letter, or any similar action by insurance, tax, or securities regulatory authorities; (c) an administrative or judicial decision in any relevant proceeding; (d) the manner in which the investments of any Portfolio is being managed; (e) a difference in voting instructions given by variable annuity contract and variable life insurance contract owners or by contract owners of different Participating Insurance Companies; or (f) a decision by a Participating Insurance Company to disregard the voting instructions of Contract owners. The Board shall promptly inform the Company if it determines that an irreconcilable material conflict exists and the implications thereof. 7.2. The Company will report any potential or existing conflicts of which it is aware to the Board. The Company will assist the Board in carrying out its responsibilities under the Mixed and Shared Funding Exemptive Order, by providing the Board with all information reasonably necessary for the Board to consider any issues raised. This includes, but is not limited to, an obligation by the Company to inform the Board whenever Contract owner voting instructions are to be disregarded. Such responsibilities shall be carried out by the Company with a view only to the interests of its Contract owners. 7.3. If it is determined by a majority of the Board, or a majority of its directors who are not interested persons of the Fund, the Distributor, the Adviser or any subadviser to any of the Portfolios (the “Independent Directors”), that a material irreconcilable conflict exists, the Company and other Participating Insurance Companies shall, at their expense and to the extent reasonably practicable (as determined by a majority of the Independent Directors), take whatever steps are necessary to remedy or eliminate the irreconcilable material conflict, up to and including: (1) withdrawing the assets allocable to some or all of the separate accounts from the Fund or any Portfolio and reinvesting such assets in a different investment medium, including (but not limited to) another Portfolio, or submitting the question whether such segregation should be implemented to a vote of all affected Contract owners and, as appropriate, segregating the assets of any appropriate group (i.e., annuity contract owners, life insurance contract owners, or variable contract owners of one or more Participating Insurance Companies) that votes in favor of such segregation, or offering to the affected contract owners the option of making such a change; and (2) establishing a new registered management investment company or managed separate account. The Company’s responsibility to take remedial action shall be carried out by the Company with a view only to the interests of Contract owners. 7.4. If a material irreconcilable conflict arises because of a decision by the Company to disregard Contract owner voting instructions and that decision represents a minority position or would preclude a majority vote, the Company may be required, at the Fund’s election, to withdraw the Account’s investment in the Fund and terminate this Agreement; provided, however, that such withdrawal and termination shall be limited to the extent required by the foregoing material irreconcilable conflict as determined by a majority of the Independent Directors. Any such withdrawal and termination must take place within six (6) months after the Fund gives written notice that this provision is being implemented, and until the end of that six-month period the Adviser, the Distributor and the Fund shall continue to accept and implement orders by the Company for the purchase (and redemption) of shares of the Fund, subject to the terms of the Fund’s then-current prospectus. 7.5. If a material irreconcilable conflict arises because a particular state insurance regulator’s decision applicable to the Company conflicts with the majority of other state regulators, then the Company will withdraw the Account’s investment in the Fund and terminate this Agreement within six months after the Board informs the Company in writing that it has determined that such decision has created an irreconcilable material conflict; provided, however, that such withdrawal and termination shall be limited to the extent required by the foregoing material irreconcilable conflict as determined by a majority of the Independent Directors. Until the end of the foregoing six-month period, the Fund shall continue to accept and implement orders by the Company for the purchase (and redemption) of shares of the Fund, subject to the terms of the Fund’s then-current prospectus. 7.6. For purposes of Sections 7.3 through 7.5 of this Agreement, a majority of the Independent Directors shall determine whether any proposed action adequately remedies any irreconcilable material conflict, but in no event will the Fund be required to establish a new funding medium for the Contracts. The Company shall not be required by Section 7.3 to establish a new funding medium for the Contracts if an offer to do so has been declined by vote of a majority of Contract owners affected by the irreconcilable material conflict. In the event that the Board determines that any proposed action does not adequately remedy any irreconcilable material conflict, then the Company will withdraw the Account’s investment in the Fund and terminate this Agreement within six (6) months after the Board informs the Company in writing of the foregoing determination; provided, however, that such withdrawal and termination shall be limited to the extent required by any such material irreconcilable conflict as determined by a majority of the Independent Directors. 7.7. If and to the extent that Rule 6e-2 and Rule 6e-3(T) are amended, or Rule 6e-3 is adopted, to provide exemptive relief from any provision of the 1940 Act or the rules promulgated thereunder with respect to mixed or shared funding (as defined in the Mixed and Shared Funding Exemptive Order) on terms and conditions materially different from those contained in the Mixed and Shared Funding Exemptive Order, then (a) the Fund and/or the Participating Insurance Companies, as appropriate, shall take such steps as may be necessary to comply with Rules 6e-2 and 6e-3(T), as amended, and Rule 6e-3, as adopted, to the extent such rules are applicable: and (b) Sections 3.5, 3.6, 3.7, 7.1, 7.2, 7.3, 7.4, and 7.5 of this Agreement shall continue in effect only to the extent that terms and conditions substantially identical to such Sections are contained in such Rule(s) as so amended or adopted.

  • DEFENSE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES 252.246-7000 MATERIAL INSPECTION AND RECEIVING REPORT (MAR 2008)

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following: a) drawings, designs, or specifications, where Goods to be furnished under the Contract are to be specifically manufactured for the Procuring Entity; b) the method of shipment or packing; c) the place of delivery; and d) the Related Services to be provided by the Supplier. 33.2 If any such change causes an increase or decrease in the cost of, or the time required for, the Supplier's performance of any provisions under the Contract, an equitable adjustment shall be made in the Contract Price or in the Delivery/Completion Schedule, or both, and the Contract shall accordingly be amended. Any claims by the Supplier for adjustment under this Clause must be asserted within twenty-eight (28) days from the date of the Supplier's receipt of the Procuring Entity's change order. 33.3 Prices to be charged by the Supplier for any Related Services that might be needed but which were not included in the Contract shall be agreed upon in advance by the parties and shall not exceed the prevailing rates charged to other parties by the Supplier for similar services.

  • FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) - ALTERNATE I (JUL 1985) 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) - ALTERNATE II (JUL 1985) 52.246-03 INSPECTION OF SUPPLIES -- COST-REIMBURSEMENT (MAY 2001) 52.246-04 INSPECTION OF SERVICES -- FIXED-PRICE (AUG 1996) 52.246-05 INSPECTION OF SERVICES -- COST-REIMBURSEMENT (APR 1984) 52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) 52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) - ALTERNATE I (APR 1984) 52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984) 52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

  • Certain Matters of Construction The terms “herein,” “hereof,” “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or subdivision. Any pronoun used shall be deemed to cover all genders. In the computation of periods of time from a specified date to a later specified date, “from” means “from and including,” and “to” and “until” each mean “to but excluding.” The terms “including” and “include” shall mean “including, without limitation” and, for purposes of each Loan Document, the parties agree that the rule of ejusdem generis shall not be applicable to limit any provision. Section titles appear as a matter of convenience only and shall not affect the interpretation of any Loan Document. All references to (a) laws or statutes include all related rules, regulations, interpretations, amendments and successor provisions; (b) any document, instrument or agreement include any amendments, waivers and other modifications, extensions or renewals (to the extent permitted by the Loan Documents); (c) any section mean, unless the context otherwise requires, a section of this Agreement; (d) any exhibits or schedules mean, unless the context otherwise requires, exhibits and schedules attached hereto, which are hereby incorporated by reference; (e) any Person include successors and assigns; (f) time of day mean time of day at Lenders’ notice addresses under Section 13.3.1; or (g) discretion of any Lender mean the sole and absolute discretion of such Person. All calculations of fundings of the Loans, and payments of Obligations shall be in Dollars and, unless the context otherwise requires, all determinations made from time to time under the Loan Documents shall be made in light of the circumstances existing at such time. Borrowers shall have the burden of establishing any alleged negligence, misconduct or lack of good faith by any Lender under any Loan Documents. No provision of any Loan Documents shall be construed against any party by reason of such party having, or being deemed to have, drafted the provision.

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Completion of Construction Within 60 days of the completion of construction of the Project, Project Owner shall deliver to DoD copies of the FAA form 7460-2 for each ASN, including the final coordinates for each turbine erected.

  • Waiver of Rule of Construction Each Party has had the opportunity to consult with counsel in connection with the review, drafting and negotiation of this Agreement. Accordingly, the rule of construction that any ambiguity in this Agreement shall be construed against the drafting Party shall not apply.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!