NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
(b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.
Absence of Labor Disputes No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, which would reasonably be expected to result in a Material Adverse Effect.
Absence of Labor Dispute No labor dispute with the employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is imminent, and the Company is not aware of any existing or imminent labor disturbance by the employees of any of its or any subsidiary’s principal suppliers, manufacturers, customers or contractors, which, in either case, would result in a Material Adverse Effect.
No Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its subsidiaries exists or, to the knowledge of the Company, is contemplated or threatened, and the Company is not aware of any existing or imminent labor disturbance by, or dispute with, the employees of any of its or its subsidiaries’ principal suppliers, contractors or customers, except as would not have a Material Adverse Effect.
Litigation, Labor Controversies, etc There is no pending or, to the knowledge of the Borrower, threatened litigation, action, proceeding, or labor controversy affecting the Borrower or any of its Subsidiaries, or any of their respective properties, businesses, assets or revenues, which could reasonably be expected to have a Material Adverse Effect, except as disclosed in Item 6.7 ("Litigation") of the Disclosure Schedule.
No Labor Dispute No labor disturbance by or dispute with the employees of any of the Partnership Entities exists or, to the knowledge of the Partnership Parties, is imminent or threatened that could reasonably be expected to have a Material Adverse Effect.
Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its Subsidiaries exists or, to the knowledge of the Company, is threatened which would reasonably be expected to result in a Material Adverse Effect.
GRIEVANCE PROCEDURE & ARBITRATION It is the mutual desire of the parties hereto that complaints of employees shall be adjusted as quickly as possible. If an employee has a complaint related to an alleged violation of the Collective Agreement may at option discuss it with immediate supervisor within three (3) days after the circumstances giving rise to the complaint (grieved action) have occurred or have or ought to have reasonably come to the attention of the employee. The Supervisor shall give a response to the complaint within three (3) days. These discussions will not establish precedent. Failing settlement, or failing a response to the complaint, it may be taken up as a grievance in the following manner and sequence: Procedure: Any employee or group of employees, for whom the Union is the bargaining agent, may refer grievances to the appropriate Union Xxxxxxx covered under this Collective Agreement. Grievances must be filed within fifteen (15) working days of grieved act or except where both parties agree to an extension of time. There is no grievance until an employee has reported complaint to the Supervisor. The grievance form shall contain a statement giving particulars of the grieved action, a statement as to the remedy sought and the provisions of the Agreement alleged to have been breached, provided that this does not preclude the or Employer from relying upon other provisions of the Agreement. Step Grievance form is completed in duplicate and signed by the employee and Union Xxxxxxx, presented to the Supervisor by the Union Xxxxxxx and (at their option). Both copies are to be returned by the Supervisor with signed comments to the Union Xxxxxxx within three (3) working days. Once a grievance has been filed no Supervisor or Employer Official shall discuss said grievance with the grieved employee except in the presence of a Xxxxxxx or Union Official. Step If satisfaction is not obtained in Step the Union Xxxxxxx, within five (5) working days, may refer the grievance to the Department Manager or designate, who will meet and discuss the grievance with the Union Xxxxxxx, (at their option) and the Human Resources Consultant then render a decision in writing on the prescribed forms within five
GRIEVANCE ARBITRATION Notwithstanding any other provision of this Agreement, for the purposes of this Article, an Employee has the right to grieve any filling of a vacancy or Assignment in the bargaining unit.
Step 4 - Arbitration a. If the Union is dissatisfied with the written decision at Step 2 or if the mediation is not successful, within twenty-five (25) days of the Step 2 meeting, the Union may advance the grievance to arbitration. Only the Union (not an individual Bargaining Unit Faculty member) may process a grievance to arbitration.
b. Within thirty (30) days of notice of proceeding to arbitration, the Union and the College shall select an impartial third party to be Arbitrator. In the event the parties cannot agree on the selection of an impartial third party, they shall request a list of Arbitrators from Federal Mediation and Conciliation Service.
c. Within five (5) days of receipt of the list, the parties shall alternately strike names from the list until one name remains. The person whose name remains shall be the Arbitrator.
d. Each party shall bear the expense of preparing and presenting its own case. The costs of the arbitration proceedings, including compensation, fees and expenses of the Arbitrator, and the cost of any hearing transcript, shall be borne equally by the College and the Union. Unless otherwise mutually agreed, each arbitration hearing shall deal with no more than one (1) grievance.
e. Subject to the availability of the Arbitrator selected, arbitration shall begin within thirty (30) days unless a delay is agreed upon by both parties.
f. The Arbitrator shall have no power to add to, subtract from, modify or disregard any of the provisions of this Agreement. The decision of the Arbitrator shall be final and binding on the parties, although each side retains whatever rights it has under state or federal law to challenge the decision and award. The Arbitrator shall have no jurisdiction or authority to issue any award changing, modifying or restricting any action taken by the College on matters committed to the College’s discretion under Article 23, Management Rights, which are not further abridged by other terms of this Agreement. Jurisdiction shall extend solely to claims of violation of specific written provisions of the Agreement and involve only the interpretation and application of the Agreement.
