Scheduling of Work Subcontractor shall provide Contractor with scheduling information and a proposed schedule for performance of the Subcontract Work consistent with the Progress Schedule and in a form acceptable to Contractor. Subcontractor shall comply with the Progress Schedule including, but not specifically limited to, commencement, duration, and sequencing of activities. Contractor shall reasonably cooperate with the Subcontractor in scheduling the Subcontract Work and shall attempt, as reasonably possible, to avoid conflicts or interference with the Subcontract Work.
CUTTING AND PATCHING OF WORK 4.14.1 The Contractor shall be responsible for all cutting, fitting or patching that may be required to complete the Work or to make its several parts fit together properly.
4.14.2 The Contractor shall not damage or endanger any portion of the Work or the work of the State or any separate contractors by cutting, patching or otherwise altering any work, or by excavation. The Contractor shall not cut or otherwise alter the work of the State or any separate contractor except with the written consent of the State and of such separate contractor. The Contractor shall not unreasonably withhold from the State or any separate contractor his consent to cutting or otherwise altering the Work.
Innovative Scheduling Schedules which are inconsistent with the Collective Agreement provisions may be developed in order to improve quality of working life, support continuity of resident care, ensure adequate staffing resources, and support cost-efficiency. The parties agree that such innovative schedules may be determined locally by the Home and the Union subject to the following principles:
(a) Such schedules shall be established by mutual agreement of the Home and the Union;
(b) These schedules may pertain to full-time and/or part-time employees;
(c) The introduction of such schedules and trial periods, if any, shall be determined by the local parties. Such schedules may be discontinued by either party with notice as determined through local negotiations;
(d) Upon written agreement of the Home and the Union, the parties may agree to amend collective agreement provisions to accommodate any innovative unit schedules;
(e) It is understood and agreed that these arrangements are based on individual circumstances and each agreement is made on a without prejudice or precedent basis.
(f) It is understood and agreed that these arrangements can be utilized for temporary job postings for seasonal coverage (e.g. weekend workers, etc.).
UNCOVERING OF WORK 13.1.1 If any portion of the Work should be covered contrary to the request of the Architect or to requirements specifically expressed in the Contract Documents, it must, if required in writing by the Architect, be uncovered for his or her observation and shall be replaced at the Contractor's expense.
13.1.2 If any other portion of the Work has been covered which the Architect has not specifically requested to observe prior to being covered, the Architect may request to see such Work and it shall be uncovered by the Contractor. If such Work is found in accordance with the Contract Documents, the cost of uncovering and replacement shall, by appropriate Change Order, be charged to the State. If such Work is found not to be in accordance with the Contract Documents, the Contractor shall pay such costs unless it is found that this condition was caused by the State or a separate contractor as provided in Article 6 of these General Conditions, in which event the State shall be responsible for the payment of such costs.
Technical Support Services 2.1 The technical support services (the "Services"): Party A agrees to provide to Party B the relevant services requested by Party B, which are specified in Exhibit 1 attached hereto ("Exhibit 1").
REVIEW OF WORK The Consultant shall permit the City, its agents and/or employees to review, at any time, all work performed pursuant to the terms of this Agreement at any stage of the work;
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor.
12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
