Time for Completion and Extensions Sample Clauses

Time for Completion and Extensions. A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. B. Should CONTRACTOR be obstructed or delayed in the completion of the work as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to CONTRACTOR’s fault or neglect, CONTRACTOR shall notify the COUNTY in writing within twenty-four (24) hours after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. C. If CONTRACTOR complies with the twenty-four (24) hour notice requirement, the COUNTY shall ascertain the facts and the extent of the delay being claimed and recommend an extension to the contract time when, in the COUNTY’s sole judgment, the findings of fact justify such an extension. CONTRACTOR shall cooperate with the COUNTY’s investigation of the delays by providing any schedules, correspondence or other data that may be required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.
Sample 1Sample 2Sample 3See All (52)
AutoNDA by SimpleDocs
Time for Completion and Extensions. A. Purchase orders will be issued for Services to the CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written Notice to Proceed is required for the CONTRACTOR to schedule or begin work. Email notice is acceptable. B. The CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Service by its subcontractors and material suppliers, as well as coordinate the CONTRACTOR’s work with the work of other contractors so that the CONTRACTOR’s work or the work of others will not be delayed or impaired. The CONTRACTOR will be solely responsible for all construction means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. The time for completion requirements are contained in Article
Sample 1Sample 2Sample 3See All (34)
Time for Completion and Extensions. A written notice to proceed or a Purchase Order with instruction is required for CONTRACTOR to schedule or begin work. CONTRACTOR will diligently pursue the completion of the work and coordinate the work being done by its subcontractors and material suppliers, as well as coordinate CONTRACTOR'S work with the work of other contractors so that CONTRACTOR'S work or the work of others will not be delayed or impaired. CONTRACTOR will be solely responsible for all means, methods, techniques, sequences, and procedures, as well as coordination of all portions of the work under the agreement documents.
Sample 1
Time for Completion and Extensions. ‌ A. Purchase orders shall be issued for Project/Services to CONTRACTOR. Issuance of a purchase order is not a directive to begin work unless otherwise specified. A written notice to proceed is required for the CONTRACTOR to schedule or begin work. CONTRACTOR shall diligently pursue the completion of the work and coordinate the work being done on the Project/Service by its subcontractors and material suppliers, as well as coordinate CONTRACTOR’s work with the work of other contractors so that CONTRACTOR’s work or the work of others shall not be delayed or impaired. CONTRACTOR shall be solely responsible for all means, methods, techniques, sequences and procedures, as well as coordination of all portions of the work under the contract documents. SAMPLE required to complete the findings of fact. Extensions to the contract time may be granted only for those delays which impact CONTRACTOR’s construction schedule. Extensions of contract time, if approved by the COUNTY, must be authorized by written change order.‌‌
Sample 1

Related to Time for Completion and Extensions

  • Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

  • Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.

  • Modification, Extension and Renewal of Options The Board or a duly appointed committee thereof, may modify, extend or renew this Option or accept the surrender thereof (to the extent not theretofore exercised) and authorize the granting of a new option in substitution therefore (to the extent not theretofore exercised), subject at all times to the Code and applicable securities laws. Notwithstanding the foregoing provisions of this Section 12, no modification shall, without the consent of the Recipient, alter to the Recipient’s detriment or impair any rights of Recipient hereunder.

  • Waivers and Extensions Any party to this Agreement may waive any right, breach or default which such party has the right to waive, provided that such waiver will not be effective against the waiving party unless it is in writing, is signed by such party, and specifically refers to this Agreement. Waivers may be made in advance or after the right waived has arisen or the breach or default waived has occurred. Any waiver may be conditional. No waiver of any breach of any agreement or provision herein contained shall be deemed a waiver of any preceding or succeeding breach thereof nor of any other agreement or provision herein contained. No waiver or extension of time for performance of any obligations or acts shall be deemed a waiver or extension of the time for performance of any other obligations or acts.

  • COMPLETION OF AGREEMENT This document comprises the entire agreement between the District and the Association in the matters lawfully within the scope of negotiation. Neither party shall have any obligation to meet and negotiate during the term of this agreement.

  • COMPLETION OF MEET AND NEGOTIATION 24.1 During the term of this Agreement, the Association expressly waives and relinquishes the right to meet and negotiate and agrees that the District shall not be obligated to meet and negotiate with respect to any subject or matter whether referred to or covered in this Agreement or not, even though each subject or matters may not have been within the knowledge or contemplation of either or both the District or the Association at the time they met and negotiated on and executed this Agreement, and even though such subjects or matters were proposed and later withdrawn.

  • Completion of Negotiations This Agreement represents complete collective bargaining and full agreement by the District and the Federation with respect to wages, hours of employment, and all other terms and conditions of employment which shall prevail during the term or terms hereof. This Agreement expresses the entire understanding between the parties and supersedes all previous agreements between them, written or oral. Any matter or subject not herein covered has been satisfactorily adjusted, compromised, or waived by the parties for the life of this Agreement.

  • Expiration and Extension of the Offer (i) Unless the Offer is extended pursuant to and in accordance with this Agreement, the Offer shall expire at midnight, New York Time, on the date that is twenty (20) Business Days after the date the Offer is first commenced (within the meaning of Rule 14d-2 promulgated under the Exchange Act) (as such date and time may be extended, the “Expiration Time”). In the event that the Offer is extended pursuant to and in accordance with this Agreement, then the Offer shall expire on the date and at the time to which the Offer has been so extended. (ii) Notwithstanding the provisions of Section 2.1(d)(i) or anything to the contrary set forth in this Agreement: (A) Acquisition Sub shall extend the Offer for any period required by any Law or Order, or any rule, regulation, interpretation or position of the SEC or its staff or NASDAQ, in any such case that is applicable to the Offer; (B) in the event that any of the conditions to the Offer set forth on Annex A, other than the Minimum Condition, are not satisfied or waived (if permitted hereunder) as of any then scheduled expiration of the Offer, Acquisition Sub shall extend the Offer for successive extension periods of ten (10) Business Days each (or any longer period as may be approved in advance by the Company) in order to permit the satisfaction of all of the conditions to the Offer; and (C) in the event that all of the conditions to the Offer set forth on Annex A have been satisfied or waived (if permitted hereunder), except that the Minimum Condition has not been satisfied, as of any then scheduled expiration of the Offer, Acquisition Sub shall extend the Offer for an extension period of ten (10) Business Days (or any longer period as may be approved in advance by the Company), it being understood and agreed that Acquisition Sub shall not be required to extend the Offer pursuant to this clause (C) on more than two (2) occasions, but may, in its sole discretion, elect to do so; provided, however, that the foregoing clauses (A), (B) or (C) of this Section 2.1(d)(ii) shall not be deemed to impair, limit or otherwise restrict in any manner the right of the parties to terminate this Agreement pursuant to the terms of Article IX, and in no event shall Acquisition Sub be required to extend the Offer beyond the Termination Date. (iii) Neither Parent nor Acquisition Sub shall extend the Offer in any manner other than pursuant to and in accordance with the provisions of Section 2.1(d)(ii) without the prior written consent of the Company. (iv) Neither Parent nor Acquisition Sub shall terminate or withdraw the Offer prior to the then scheduled expiration of the Offer unless this Agreement is validly terminated in accordance with Article IX, in which case Acquisition Sub shall (and Parent shall cause Acquisition Sub to) irrevocably and unconditionally terminate the Offer promptly (but in no event more than one (1) Business Day) after such termination of this Agreement.

  • Commencement and Completion of Work The professional services to be performed pursuant to this Agreement shall commence within five (5) days from the Effective Date of this Agreement. Failure to commence work in a timely manner and/or diligently pursue work to completion may be grounds for termination of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!