TRANSITION TO ANOTHER CONTRACTOR Sample Clauses

The "Transition to Another Contractor" clause outlines the procedures and responsibilities involved when the current contractor is replaced by a new one. Typically, this clause requires the outgoing contractor to cooperate with the incoming contractor, transfer relevant documents, and provide necessary information to ensure a smooth handover of services or work. It may also specify timelines, confidentiality obligations, and the handling of unfinished tasks. The core function of this clause is to minimize disruption and maintain continuity in the project or service by clearly defining the transition process between contractors.
POPULAR SAMPLE Copied 2 times
TRANSITION TO ANOTHER CONTRACTOR. 42.1 Duty to Co–operate 42.1.1 liaising with the Authority and/or any New Contractor, and providing reasonable and timely assistance and advice concerning the Services and their transfer to the Authority or to such New Contractor; 42.1.2 allowing any such New Contractor access (at reasonable times and on reasonable notice) to the New Project Facilities, but not so as to interfere with or impede the provision of the Services; 42.1.3 (without prejudice to the obligations of the Contractor pursuant to Clause 32 (Operating Manual)) providing to the Authority and/or to any New Contractor, all and any information concerning the Sites and the Services which is required for the efficient transfer of responsibility for their performance; and 42.1.4 making its sub-contractors like bound by the provision of Clause 42.1 and 42.2 with a third party right of direct enforcement by the Authority.
View Source
TRANSITION TO ANOTHER CONTRACTOR. 22.1 During the period of any termination notice pursuant to this Agreement, and in any case for a reasonable period, to be determined at the sole discretion of Mitie, thereafter, the Contractor shall act professionally and reasonably and co- operate fully with the transfer of responsibility for and knowledge of the Works to Mitie or to any new contractor(s) of such services and/or goods the same or similar to the Works, and for the purposes of this Clause 22 the meaning of the term "co-operate" shall include, without limitation: a. liaising with Mitie and/or any new contractor(s), and providing reasonable assistance and advice concerning the Works and their transfer to Mitie or to such new contractor(s); b. allowing any new contractor(s) access to its business, its records and documents relating to the Works (at reasonable times and on reasonable notice) but not so as to interfere with or impede the provision of the Works by the Contractor; and c. providing to Mitie and/or to any new contractor(s) all and any knowledge, information, stock, records or documentation concerning the Works which is reasonably required for the efficient transfer of responsibility for their performance but information which is commercially sensitive to the Contractor or subject to a legally binding confidentiality agreement shall not be provided (and for the purpose of this Clause 22, “commercially sensitive” shall mean information which would, if disclosed to a competitor of the Contractor, give that competitor a competitive advantage over the Contractor and thereby prejudice the business of the Contractor and shall not include any information relating to the employees of the Contractor. 22.2 The Contractor shall use all reasonable endeavours so as to facilitate the smooth transfer of responsibility for the Works to a new contractor and/or contractors and/or to Mitie (as the case may be) and the Contractor shall take no action at any time during the term of the Agreement or thereafter which is calculated or intended, directly or indirectly, to prejudice or frustrate or make more difficult any such transfer.
View SourceView Similar (2)
TRANSITION TO ANOTHER CONTRACTOR. 35.1 During the final six (6) months of the Agreement Term (where this expires by effluxion of time) or during the period of any termination notice, and in either case for a reasonable period thereafter, the Contractor shall co-operate fully with the transfer of responsibility for the Services (or any of the Services) to the School or any future service provider, and for the purposes of this clause 35 the meaning of the term “co-operate” shall include: 35.1.1 liaising with the School and/or any future service provider, and providing reasonable assistance and advice concerning the Services and their transfer to the School or to such future service provider; 35.1.2 providing to the School and/or to any future service provider all and any Information concerning the Services which is reasonably required for the efficient transfer of responsibility for their performance but Information which is commercially sensitive to the Contractor shall not be provided (and for the purposes of this clause, “commercially sensitive” shall mean information which would, if disclosed to a competitor of the Contractor, give that competitor a competitive advantage over the Contractor and thereby prejudice the business of the Contractor but shall not include any information referred to in clause 35.1 (TUPE)); 35.2 The Contractor shall use all reasonable endeavours so as to facilitate the smooth transfer of responsibility for the Services to a future service provider or to the School, as the case may be, and the Contractor shall take no action at any time during the Agreement Term or thereafter which is calculated or intended, directly or indirectly, to prejudice or frustrate or make more difficult such transfer.
View SourceView Similar (2)
TRANSITION TO ANOTHER CONTRACTOR. 42.1 Duty to Co–operate During the final [ ] months of the Contract Period (where this expires by effluxion of time) or during the period of any notice of termination of this Agreement or of any of the Services, and in either case for a period of [ ] months thereafter, the Contractor shall co–operate fully with the transfer of responsibility for the Services (or any of the Services) to any new Contractor of such services the same or similar to the Services (“New Contractor”), and for the purposes of this clause TRANSITION TO ANOTHER the meaning of the term “co–operate” shall include: 42.1.1 liaising with the Authority and/or any New Contractor, and providing reasonable assistance and advice concerning the Services and their transfer to the Authority or to such New Contractor; 42.1.2 allowing any such New Contractor access (at reasonable times and on reasonable notice) to the Schools but not so as to interfere with or impede the provision of the Services; and 42.1.3 (without prejudice to the obligations of the Contractor pursuant to clause OPERATING MANUAL) providing to the Authority and/or to any New Contractor all and any information concerning the Sites and the Services which is required for the efficient transfer of responsibility for their performance.
View Source
TRANSITION TO ANOTHER CONTRACTOR. 42.1 Duty to Co–operate During the final 12 months of the Contract Period (where this expires by effluxion of time) or during the period of any notice of termination of this Agreement or termination of any of the Services, and in any case for a period of 12 months thereafter, the Contractor shall co–operate fully with the transfer of responsibility for the Services (or any of the Services) to any new contractor of such services the same or similar to the Services (“New Contractor”), and for the purposes of this Clause 42 the meaning of the term “co–operate” shall include: 42.1.1 liaising with the Authority and/or any New Contractor, and providing reasonable and timely assistance and advice concerning the Services and their transfer to the Authority or to such New Contractor; 42.1.2 allowing any such New Contractor access (at reasonable times and on reasonable notice) to the New Project Facilities but not so as to interfere with or impede the provision of the Services; 42.1.3 (without prejudice to the obligations of the Contractor pursuant to Clause 32 (Operating Manual)) providing to the Authority and/or to any New Contractor, all and any information concerning the Sites and the Services which is required for the efficient transfer of responsibility for their performance; and 42.1.4 making its sub-contractors like bound by the provision of Clause 42.1 and 42.2 with a third party right of direct enforcement by the Authority.
View Source
TRANSITION TO ANOTHER CONTRACTOR. (a) During the Exit Period and for a reasonable period after the Exit Period, the Contractor shall co-operate fully with the transfer of responsibility for the Services (or any of the Services) to the Authority or a New Contractor and, for the purposes of this Clause 35.3, the meaning of the term "co-operate" shall include: (i) liaising with the Authority and/or a New Contractor, and providing reasonable assistance and advice relating to the Services and their transfer to the Authority or to that New Contractor to allow the Services to contiue without interruption or adverse effect following termination or expiry of this Agreement; (ii) allowing that New Contractor access (at reasonable times and on reasonable notice) to the Contractor Premises but not so as to interfere with or impede the provision of the Services; (iii) providing to the Authority and/or to that New Contractor all and any information relating to the Services which is reasonably required for the efficient transfer of responsibility for their performance but excluding information which would, if disclosed to a competitor of the Contractor, give that competitor a competitive advantage over the Contractor and thereby prejudice the business of the Contractor; and (iv) transferring its rights, title and interest in and to the Assets to the New Contractor with effect on and from the Termination Date in accordance with Clause 33.12(a) of this Agreement. (b) With effect from the Termination Date, the Contractor shall, at the request of the Authority, novate each Subcontract to the New Contractor or to the Authority pursuant to the terms of the relevant Subcontract.
View Source
TRANSITION TO ANOTHER CONTRACTOR. Duty to Co-operate
View Source
TRANSITION TO ANOTHER CONTRACTOR 
View SourceView Similar (2)

Related to TRANSITION TO ANOTHER CONTRACTOR

  • General Contractor A building, construction, or contracting firm with whom Borrower has contracted or may in the future contract with for the construction of the Improvements pursuant to a certain construction contract between them (the "Construction Contract").

  • Compensation to Contractor The terms related to the price of the goods and/or services to be provided under this Agreement and the terms of payment to the Contractor are described in more detail in Attachment “B” to this Agreement: Price and Payment Information.

  • Attachment A, Scope of Services The scope of services is amended as follows:

  • Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history.

  • Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.

Most Referenced Clauses

Most Referenced Definitions

AI Assistant