Schedule of Documents means the schedule, including all appendices, exhibits or schedules thereto, listing certain documents and information to be delivered in connection with the Sale Agreement, the Funding Agreement and the other Related Documents and the transactions contemplated thereunder, substantially in the form attached as Annex Y to the Funding Agreement and the Sale Agreement.
Schedule of Fees and Charges means the information on fees and charges that we give you when you open your Account; and amendments or replacements issued to you from time to time. An up-to-date version of this schedule is available from any of our offices and on our Website.
Schedule of Retained Causes of Action means the schedule of certain Causes of Action of the Debtors that are not released, waived, or transferred pursuant to the Plan, as the same may be amended, modified, or supplemented from time to time.
Time Schedule means the Time Schedule for final completion of the Works or Mechanical Completion of the Plant(s)/Unit(s), as the case may be, incorporated in the Contract or as may be extended by the OWNER or Engineer- in-Charge pursuant to the provisions hereof and shall include interim time schedules set up for achieving interim/phase-wise/stage-wise progress/completion/testing/commissioning/ handing over, as may be prescribed by the OWNER/Engineer-in-Charge, within the overall Time Schedule as originally envisaged or as extended.
Schedule of Performance means that schedule of performance, attached hereto as Exhibit G and incorporated herein, setting forth the timelines for Milestones in the design, development, construction, and completion of the Project (including a construction timeline in customary form) together with the dates for submission of documentation required under this Agreement, which schedule shall be attached to the Development Plan and to the Declaration.
Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.
Schedule of Work means that schedule attached to the Interconnection Construction Service Agreement setting forth the timing of work to be performed by the Constructing Entity pursuant to the Interconnection Construction Service Agreement, based upon the Facilities Study and subject to modification, as required, in accordance with Transmission Provider’s scope change process for interconnection projects set forth in the PJM Manuals.
Unique item identifier type means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at http://www.acq.osd.mil/dpap/pdi/uid/uii_types.html.
QAP shall have the meaning set forth in Clause 11.2;
Statement of Grievance shall name the employee involved, shall state the facts giving rise to the grievance, shall identify by appropriate reference all the provisions of this Master Contract alleged to be violated, shall state the contention of the employee and of the Association with respect to these provisions, and shall indicate the specific relief requested.
Prepayment Charge Schedule A data field in the Mortgage Loan Schedule attached hereto as Exhibit A which sets forth the amount or method of calculation of the Prepayment Charge and the term during which such Prepayment Charge is imposed with respect to a Mortgage Loan.
DoD item unique identification means a system of marking items delivered to DoD with unique item identifiers that have machine- readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number. For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.
Progress Assessment Report (PAR means the monthly compliance report to Owner verifying compliance with the HUB subcontracting plan (HSP).
Causes of Action means any action, claim, Claim, cause of action, controversy, demand, right, action, Lien, indemnity, Interest, guaranty, suit, obligation, liability, damage, judgment, account, defense, offset, power, privilege, license, and franchise of any kind or character whatsoever, whether known, unknown, contingent or non-contingent, matured or unmatured, suspected or unsuspected, liquidated or unliquidated, disputed or undisputed, secured or unsecured, assertable directly or derivatively, whether arising before, on, or after the Petition Date, in contract or in tort, in law, or in equity or pursuant to any other theory of law. For the avoidance of doubt, “Cause of Action” includes: (a) any right of setoff, counterclaim, or recoupment and any claim for breach of contract or for breach of duties imposed by law or in equity; (b) the right to object to Claims or Interests; (c) any Claim pursuant to section 362 or chapter 5 of the Bankruptcy Code; (d) any claim or defense including fraud, mistake, duress, and usury; and any other defenses set forth in section 558 of the Bankruptcy Code; and (e) any state or foreign law fraudulent transfer or similar claim.
Special Contract Attachments means any attachment to this Contract.
Individual subcontracting plan means a subcontracting plan that covers the entire contract period (including option periods), applies to a specific contract, and has goals that are based on the offeror’s planned subcontracting in support of the specific contract, except that indirect costs incurred for common or joint purposes may be allocated on a prorated basis to the contract.
Schedule of Fees means the published note of the School's prevailing fees notified to you from time to time and a copy of which remains available on the School's website and from the School at any time upon request;
Unique item identifier means a set of data elements marked on items that is globally unique and unambiguous. The term includes a concatenated unique item identifier or a DoD recognized unique identification equivalent.
principal contractor means an employer appointed by the client to perform construction work;
Insurance Schedule means Schedule 3 attached hereto.
Lower tier subcontractor means any party entering into an agreement with the SUBCONTRACTOR or any Lower Tier SUBCONTRACTOR for the furnishing of supplies or services required for performance of this Subcontract.
Contract Schedule means a schedule to this Contract;
Corrective Maintenance means the maintenance which is required when an item has failed or worn out, to bring it back to working order, which may also include those services necessary to partially restore, renew or strengthen an existing Department facility or system, following damage caused by use or normal wear and tear.
Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Retained Causes of Action means those Causes of Action that shall vest in the Reorganized Debtors on the Effective Date, which, for the avoidance of doubt, shall not include any of the Causes of Action that are settled, released or exculpated under the Plan.