Extra Work means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.
Contract Work means everything required to be furnished and done by the Contractor by any one or more of the parts of the Contract referred to in Article 1, except Extra Work as hereinafter defined.
Project Work means the work required to complete the Project.
Project Improvements means site improvements and facilities that are:
Project Plans mean the plans for the Project that are attached to this Agreement as Exhibit “B.”
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Permanent Work means the permanent works including equipment to be supplied, executed, erected and maintained in accordance with the Contract.
Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Permanent Works means the permanent works to be executed by the Contractor under the Contract.
The Work means the work or works to be executed or done under this contract.
audiovisual work means a work that consists of a series of related images which impart the impression of motion, with or without accompanying sounds, susceptible of being made visible and, where accompanied by sounds, susceptible of being made audible;
aerial work means an aircraft operation in which an aircraft is used for specialised services such as agriculture, construction, photography, surveying, observation and patrol, search and rescue, and aerial advertisement;
Shift Work is defined as the same work performed by two or more employees or two or more successive sets or groups of employees working successive periods.
Development Plans means a coherent set of operations defined and financed exclusively by the OCTs in the framework of their own policies and strategies of development, and those agreed upon between an OCT and the Member State to which it is linked;
Project Commissioning means the Project will be considered as commissioned if all equipment as per rated project capacity has been installed and energy has flown into grid, in line with the Commissioning procedures defined in the RfS/PPA.
Project Completion Date means the date on which the Completion Certificate is issued;
Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.
Task(s) means one or more functions, if specified in the Contract Documents, to be performed by the Contractor for the State.
Development Work means any work carried out in relation to the physical construction of a mine;
Work means all Services to be performed, goods to be delivered, and any appurtenant actions performed, and items produced, conceived, or developed, including Deliverables.
Construction Plans means plans, drawings, specifications and related documents, and construction schedules for the construction of the Project, together with all supplements, amendments or corrections, submitted by the Developer and approved by the City in accordance with this Agreement.
Complete application means a document prepared in
Final Approval Order means the proposed Order Granting Final Approval to the Settlement, to be entered by the Court with terms to be agreed upon by the Parties and consistent with this Agreement.
Target Completion Date has the meaning given such term in Section 3.3(b).
Preliminary Approval Order means the order preliminarily approving the Settlement Agreement, certifying the Settlement Class for settlement purposes, and directing notice thereof to the Settlement Class, which will be agreed upon by the Parties and submitted to the Court in conjunction with Plaintiffs’ motion for preliminary approval of the Agreement.