Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.
Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.
Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.
Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each and clearly allocate requested grant funding and match contributions to each.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:
Development Schedule shall have the meaning set forth in Section 1.1.
The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.
Project Work means the work required to complete the Project.
Project Implementation Unit or “PIU” means the unit referred to in Section I.A.2 of Schedule 2 to this Agreement.
Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;
Unilateral Change Order (ULCO means a Change Order issued by Owner without the complete agreement of Contractor, as to cost and/or time.
Project Implementation Manual or “PIM” means the manual containing details of financial and accounting procedures, procurement arrangements, environmental and social monitoring and mitigation arrangements, and other administrative and organizational arrangements, as shall have been agreed with the Association for purposes of Project implementation, as the same may be amended from time to time, and such term includes any schedules to the PIM;
Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Project Scope means the description or activity of work to be accomplished on the Project.
Project Plans mean the plans for the Project that are attached to this Agreement as Exhibit “B.”
Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.
Project Improvements means site improvements and facilities that are:
Construction Change Directive means a written order prepared by Owner Parties and signed by Owner directing Contractor to perform a change in the Work prior to agreeing to a change, if any, to the Contract Time, schedule of performance of the Work, Contract Sum, or Contractor’s compensation.
Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.
Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.
Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.