Services to Other Clients; Certain Affiliated Activities (a) The relationship between the Asset Manager and the Series is as described in this Agreement and nothing in this Agreement, none of the services to be provided pursuant to this Agreement, nor any other matter, shall oblige the Asset Manager to accept responsibilities that are more extensive than those set forth in this Agreement.
(b) The Asset Manager’s services to the Series are not exclusive. The Asset Manager may engage in other activities on behalf of itself, any other Managing Party and other clients (which, for the avoidance of doubt, may include other series of the Company). The Series acknowledges and agrees that the Asset Manager may, without prior notice to the Series, give advice to such other clients. The Asset Manager shall not be liable to account to the Series for any profits, commission or remuneration made or received in respect of transactions effected pursuant to the Asset Manager’s advice to another client and nor will the Asset Manager’s fees be abated as a result.
Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).
Program Changes Contractor agrees to inform the County of any alteration in program or service delivery at least thirty (30) days prior to the implementation of the change, or as soon as reasonably feasible.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.
Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.
Coordination of Services Consultant agrees to work closely with City staff in the performance of Services and shall be available to City’s staff, consultants and other staff at all reasonable times.
Project Changes 1.8.1. All changes shall be administered per the UGC.
1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders.
1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal.
1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form.
1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date".
1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order.
1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order.
1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Authorized Activities In carrying out the purposes of the Partnership, but subject to all other provisions of this Agreement, the Partnership is authorized to engage in any kind of lawful activity, and perform and carry out contracts of any kind, necessary or advisable in connection with the accomplishment of the purposes and business of the Partnership described herein and for the protection and benefit of the Partnership; provided that the General Partner shall not be obligated to cause the Partnership to take, or refraining from taking, any action which, in the judgment of the General Partner, (i) could adversely affect the ability of the General Partner to qualify and continue to qualify as a REIT, (ii) could subject the General Partner to additional taxes under Code Section 857 or 4981 or (iii) could violate any law or regulation of any governmental body or agency having jurisdiction over the General Partner or its securities.
Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.
