Certificate of Recognition Sample Clauses

Certificate of Recognition. Subject to Section 1.6 [Temporary Letter of Certification] of this Schedule 11 [Construction Safety Requirements], Project Co shall, if it is eligible to obtain such:
Sample 1
AutoNDA by SimpleDocs
Certificate of Recognition. The Contractor shall provide a Letter of Good Standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association prior to commencement of any work. At anytime during the term of the Contract, when requested by the owner, the Contractor shall provide such evidence of compliance by any or all of his or her Subcontractors. The Contractors and all Subcontractors Safety Plan must be submitted to the Department before the commencement of any work. Be advised that any contractor not in good standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association should do so immediately. PRICING SCHEDULE DISTRICT 4 Western Region ITEM DESCRIPTION HOURLY RATE DAILY RATE WEEKLY RATE MONTHLY RATE APPLICABLE UNIT(S) 1 Portable Welder
Sample 1
Certificate of Recognition. The Contractor must provide to the College a copy of its Certificate of Recognition issued jointly by the Nova Scotia Department of Environment & Labour and an occupational health and safety organization approved by Nova Scotia Department of Environment & Labour, or a valid Letter of Good Standing from an occupational health and safety organization approved by NSCC, before beginning the Work. Updated Safety documents must be provided to the College during the term of the Agreement where Safety documents expire before completion date stated in the Agreement.
Sample 1
Certificate of Recognition. The contractor shall within 14 days of award of the contract, and prior to commencement of the work, provide a Letter of Good Standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association. At anytime during the Contract, when requested by the Town, the Contractor shall provide such evidence of compliance by any or all of his Subcontractors. The Town of Labrador City will strictly enforce safety requirements as per the Occupational Health & Safety Act. All items of safety apparel/equipment shall be the responsibility of the contractor.
Sample 1
Certificate of Recognition. Safety qualification shall be in the form of a Certificate of Recognition (“COR”) or its successor, which is relevant to the applicable industry and which is recognized by Alberta Labour, or its successor department of the provincial government of Alberta (“Workplace Health and Safety”). The Contractor shall obtain before the commencement of the Project and shall maintain throughout the duration of the Project and the O&M, a COR. The Contractor shall ensure the subcontractors listed in Schedule 17 to the DBFO Agreement maintain a COR at any time such subcontractor is providing services for the Project or the O&M.
Sample 1
Certificate of Recognition. The Contractor shall provide with their Tender Submission a Letter of Good Standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association. For those “In Process”, the letter of process should be submitted with the Tender Submission but all Contractors must have a Letter of Good Standing issued prior to the commencement of any work. Contractors failing to submit these documents with their Tender Submission, may result in Standing Offers not being issued. At anytime during the term of the Contract, when requested by the owner, the Contractor shall provide such evidence of compliance by any or all of his or her Subcontractors. The Contractors and all Subcontractors Safety Plan must be submitted to the Department before the commencement of any work.
Sample 1
Certificate of Recognition. Each assuming insurer which is complying with the provisions of subdivision (a), (b), (c) or (d) of section 125.2 of this Part shall be issued a certificate of recognition as an accredited reinsurer and no ceding insurer shall take credit for reinsurance recoverables from such an assuming insurer unless such assuming insurer has a valid certificate of recognition in force. Such certificate shall have a continuous term until revoked by the superintendent. 11 NYCRR 125.8 6
Sample 1
AutoNDA by SimpleDocs
Certificate of Recognition. 5.2 Metrolinx has implemented a phased-in approach for the Certificate of Recognition (CORTM) safety program for its construction projects. Throughout the Term of the Contract, the Contractor must achieve the following milestones related to CORTM certification:
Sample 1
Certificate of Recognition. Prior to the Contractor undertaking any construction work, in respect of the Project, or performing any aspect of the Existing Facilities O&M or the O&M, the Contractor shall have a valid COR for the health and safety management system(s) to be followed for the subject activity. The COR must be valid for the specific health and safety management system(s) that are to be used for the Project, the Existing Facilities O&M and the O&M, as applicable, and shall be co-signed by Alberta Human Services. The Contractor shall also ensure that any subcontractors, including those subcontractors listed in Schedule 17 of the DBFO Agreement shall have in place a valid COR for the work or services that the subcontractor is providing to the Contractor for the Project, the Existing Facilities O&M or the O&M.
Sample 1

Related to Certificate of Recognition

  • CERTIFICATE OF SERVICE I certify that I served a true and correct copy of the foregoing Consent Agreement and Final Order, docket number FIFRA-05-2023-0003 , which was filed on 1/19/23 , in the following manner to the following addressees: Copy by E-mail to Xx. Xxxxx Xxx Attorney for Complainant: xxx.xxxxx@xxx.xxx Copy by E-mail to Xx. Xxxxxxxxx X. Schmiesing Attorneys for Respondent: XXxxxxxxxxx@xxxxxxxx.xxx Copy by E-mail to Xx. Xxx Xxxxx Regional Judicial Officer: xxxxx.xxx@xxx.xxx Dated: XXXXXXX XXXXXX Digitally signed by XXXXXXX XXXXXX Date: 2023.01.19 08:57:12 -06'00' Regional Hearing Clerk

  • Certificate of Conformance At Buyer’s request, a Certificate of Conformance stating the Products conform to all Order requirements shall accompany each shipment. Seller shall have available for review all sub-tier certifications for goods and processes that support the shipment.

  • Certificate of Completion The Interconnection Customer shall provide the EDC with a completed copy of the Interconnection Agreement Certificate of Completion, including evidence of the electrical inspection performed by the local authority having jurisdiction. The evidence of completion of the electrical inspection may be provided on inspection forms used by local inspecting authorities. The Interconnection request shall not be finally approved until the EDC’s representative signs the Interconnection Agreement Certificate of Completion.

  • Certificate of Compliance The Servicer shall deliver to the Note Issuer, the Note Trustee, the Certificate Trustee and the Rating Agencies on or before March 31 of each year, commencing March 31, 2006 to and including the March 31 succeeding the Retirement of the Notes, an Officer’s Certificate substantially in the form of Exhibit A hereto (a “Certificate of Compliance”), stating that: (i) a review of the activities of the Servicer during the twelve months ended the preceding December 31 (or, in the case of the first Certificate of Compliance to be delivered on or before March 31, 2006, the period of time from the date of this Agreement until December 31, 2005) and of its performance under this Agreement has been made under such Responsible Officer’s supervision, and (ii) to the best of such Responsible Officer’s knowledge, based on such review, the Servicer has fulfilled all of its obligations under this Agreement in all material respects throughout such twelve months (or, in the case of the Certificate of Compliance to be delivered on or before March 31, 2006, the period of time from the date of this Agreement until December 31, 2005), or, if there has been a failure to fulfill any such obligation in any material respect, specifying each such failure known to such Responsible Officer and the nature and status thereof.

  • Certificate of Interested Parties Form – Form 1295 As required by Section 2252.908 of the Texas Government Code. H-GAC will not enter a Contract with Contractor unless (i) the Contractor submits a disclosure of interested parties form to H-GAC at the time the Contractor submits the contract H-GAC, or

  • Certificate of Termination On completion of the distribution of Company assets as provided herein, the Company is terminated, and the Sole Member (or such other person as the law may require or permit) shall execute, acknowledge, and cause to be filed a Certificate of Termination, at which time the Company shall cease to exist as a limited liability company.

Time is Money Join Law Insider Premium to draft better contracts faster.