Change Order Claims and Disputes Sample Clauses

Change Order Claims and Disputes. Notwithstanding the dispute resolution terms of Paragraph 45, for any unresolved issue between the parties pertaining to Additional Work, the Contract Price and/or the Contract Time, including issues where the parties are continuing negotiations on rejected Change Orders (“Change Order Claim”), Contractor shall have the burden of establishing entitlement to any Additional Work and increases in the Contract Price and/or the Contract Time. Contractor shall submit a notice of claim (“Notice of Claim”) to Owner within ten (10) days of Contractor’s receipt of Owner’s rejection of a Change Order. Contractor shall submit all such documentation required by Owner in support of such Change Order Claim within twenty (20) days of Contractor’s submittal of the corresponding Notice of Claim. Contractor’s failure to submit a Notice of Claim within the required time frame shall constitute a waiver of Contractor’s Change Order Claim. All increases or decreases in the Contract Price shall be determined by applying the provisions of Paragraph 7.2.a, to Contractor’s direct, actual cost for the Additional Work and shall be limited strictly to those amounts which are solely attributable to the corresponding Change Order Claim. Contractor shall substantiate any Change Order Claim for a change in the Contract Time with a CPM delay analysis. Any Change Order Claim not resolved by the parties within thirty (30) days after Owner’s receipt of the Notice of Claim shall be set aside pending completion of the Work or earlier termination of this Agreement and the provisions of Paragraph 45 shall apply. However, both parties expressly acknowledge and agree that the requirements and limitations set forth in this Paragraph 7.3 exclusively govern the final determination of the extent of Contractor’s damages for any Change Order Claim during any legal proceeding. Under no circumstances shall Contractor be entitled to recover any amounts for lost productivity, inefficiency, out-of-sequence work, stacking of trades, idle equipment, lost profits, extended home office overhead, interest or any other indirect costs and Contractor hereby waives any right to claim such costs for a Change Order Claim under this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to Change Order Claims and Disputes

  • Claims and Disputes A. Claims by the CONTRACTOR must be made in writing to the COUNTY within two (2) business days, unless another provision of this Agreement sets forth a different time frame, after the commencement of the event giving rise to such claim or the CONTRACTOR will be deemed to have waived the claim. All claims will be priced in accordance with the section in this document entitled “Changes in the Scope of Services”. B. The CONTRACTOR shall proceed diligently with its performance as directed by the COUNTY, regardless of any pending claim, action, suit, or administrative proceeding, unless otherwise agreed to by the COUNTY in writing. The COUNTY shall continue to make payments on the undisputed portion of the contract in accordance with the contract documents during the pendency of any claim. C. Claims by the CONTRACTOR will be resolved in the following manner: (1) Upon receiving the claim and supporting data, the COUNTY will within fifteen (15) calendar days respond to the claim in writing stating that the claim is either approved or denied. If denied, the COUNTY will specify the grounds for denial. The CONTRACTOR will then have fifteen (15) calendar days in which to provide additional supporting documentation, or to notify the COUNTY that the original claim stands as is.

  • Complaints and Disputes 28.1. If the Client wishes to report a complaint, he must send an email to the Company with the completed “Complaints Form” found on the Website. The Company will try to resolve it without undue delay and according to the Company’s Complaints Procedure for Clients. 28.2. If a situation arises which is not expressly covered by this Agreement, the Parties agree to try to resolve the matter on the basis of good faith and fairness and by taking such action as is consistent with market practice. 28.3. The Client’s right to take legal action remains unaffected by the existence or use of any complaints procedures referred to above.

  • Complaints and Dispute Resolution 16.1 Where a dispute arises in connection with any aspect of this Agreement, the parties acting with good faith, will use all reasonable endeavours to bring any such issue to the attention of the other party in a timely fashion and in any event within 60 days of any such dispute coming to their attention. 16.2 Notification by one party to the other must be in writing and include the nature of the dispute and the desired resolution. 16.3 If a Supplier wishes to notify ACM of a dispute in connection with this Agreement, any such notification should be made by email to xxxxxxxxxx@xxxxxx.xxx.xx. 16.4 Within seven days of receipt of a notification in accordance with clause 16.2, a party will provide a response in writing including setting out steps it intends to take to resolve the dispute. 16.5 If, after attempting to resolve the dispute for a period of at least 60 days, the parties are not reconciled, they agree to then participate in a mediation to be conducted in accordance with the Code. 16.6 If, after undertaking mediation in accordance with the Code, the parties are still not reconciled, they may then submit to an arbitration to be conducted in accordance with the Code. 16.7 Unless otherwise agreed in writing, the parties shall each bear their own legal costs associated with any mediation and/or arbitration pursuant to this Agreement. 16.8 Nothing in this clause will prevent a party from seeking an injunction.

  • Applicable Laws and Dispute Resolution a. The formation, validity, interpretation and performance of and settlement of disputes under this Agreement shall be governed by the laws of the PRC. b. Any dispute, conflict, or claim arising in connection with the interpretation and performance of the provisions of this Agreement (including any issue relating to the existence, validity, and termination of this Agreement) shall be resolved by the Parties in good faith through negotiations. In case no resolution can be reached by the Parties within thirty (30) days after a Party makes a request for dispute resolution through negotiations, any Party may refer such dispute to a competent court having legal jurisdiction over the registration place of Party A. The Parties agree to submit to the jurisdiction of such court. The Parties agree that the dispute and any court proceedings shall be kept confidential and that the existence of the proceedings and any element of it (including but not limited to any pleadings, briefs or other documents submitted or exchanged, any testimony or other oral submissions, and any awards) shall not be disclosed beyond the court, the Parties, their counsels and any person necessary to the conduct of the proceeding, except as may be lawfully required in judicial proceedings or as required by the rules of the U.S. Securities and Exchange Commission, the NASDAQ stock market rules or the rules of any other quotation system or exchange on which the securities of the disclosing Parties or their affiliates are listed or as otherwise required by applicable law. The Parties further agree to request that the court conduct any proceedings in closed session and to keep the existence of the proceedings and any element of it, including the decision of the court, confidential and refrain from publishing or otherwise disclosing any of the foregoing information to the public, except as may be lawfully required in judicial proceedings or as otherwise required by applicable law.

  • LAW AND DISPUTES This agreement is governed by Federal law. (i) Any language purporting to subject the U.S. Government to the laws of a U.S. state, U.S. territory, district, or municipality, or foreign nation, except where Federal law expressly provides for the application of such laws, is hereby deleted. (ii) Any language requiring dispute resolution in a specific forum or venue that is different from that prescribed by applicable Federal law is hereby deleted. (iii) Any language prescribing a different time period for bringing an action than that prescribed by applicable Federal law in relation to a dispute is hereby deleted.

  • Settlement of Disputes between the contracting parties 1. Any dispute between the Contracting Parties concerning the interpretation or application of this Agreement shall, if possible, be settled through diplomatic channels. 2. If any dispute between the Contracting Parties cannot be settled within six months (6) It shall upon the request of either Contracting Party, be submitted to an arbitral tribunal. 3. Such an arbitral tribunal shall be constituted for each individual case in the following way. Within two (2) months of the receipt of the request for arbitration, each Contracting Party shall appoint one member of the Tribunal. The two members shall then select a national of a third State, who on approval by the two Contracting Parties shall be appointed Chairman of the Tribunal. The Chairman shall be appointed within two (2) months from the date of appointment of the other two members. 4. If within the periods specified in paragraph 3 of this article the necessary appointments have not been made, either Contracting Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make the necessary appointments. If the President is a national of either Contracting Party or if he is otherwise prevented from discharging the said function, the Vice-President shall be invited to make the necessary appointments. if the Vice- President is a national of either Contracting Party or if he is also prevented from discharging the function, the said member of the International Court of Justice the oldest who is not a national of either Contracting Party shall be invited to make the necessary appointments. 5. The arbitral tribunal shall reach its decisions by a majority of votes and shall be binding on both contracting parties. each Contracting Party shall assume the costs of its own member of the Tribunal and of its representation in the arbitral proceedings; the cost of the Chairman and the remaining costs shall be borne in equal parts by the contracting parties. The Tribunal may, however, in its decision that a higher proportion of direct costs shall be borne by one of the two contracting parties, and this decision shall be binding on both contracting parties. the tribunal shall determine its own rules of procedure for all other matters. 6. The arbitral tribunal shall make its decision on the basis of this Agreement and any agreement in force between the two parties and international law in general and take into account, as appropriate, the domestic law of the Contracting Party where the investment concerned is located.

  • Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

  • Labour Disputes 15.01 If employees are prevented from performing their duties because of a strike or lock-out on the premises of another employer, the employees shall report the matter to the Employer, and the Employer will make reasonable efforts to ensure that such employees are employed elsewhere, so that they shall receive their regular pay and benefits to which they would normally be entitled.

  • Applicable law and disputes The contract is governed by, and shall be construed in accordance with the laws of the Contracting Authority’s country. Any dispute or breach of contract arising under this contract shall be solved amicably if at all possible. If not possible and unless provided in the Service Contract, it shall be settled finally by court decision, which shall be held under the law of the Contracting Authority’s country. Any ruling by the court will be final and directly executable in the country of the Contractor.

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!