Construction Manager‟s Review Sample Clauses

Construction Manager‟s Review. The Construction Manager shall review the Contract Documents, including without limitation, the Owner‟s program to determine the requirements of the Project. The Construction Manager shall commence the Work to be performed under this Agreement upon receipt of a Notice to Proceed issued by the Owner. The Construction Manager shall diligently perform all of the Work required by the Contract Documents, and reasonably inferable from industry standards and code requirements.
Sample 1
AutoNDA by SimpleDocs
Construction Manager‟s Review. Prior to its acceptance of any Construction Document Change Order tendered under Section 3, Part 2, Construction Manager shall promptly review the Construction Documents referenced therein for the purposes of recommending to the Owner and the Architect any changes or modifications thereof which will reduce the cost of the Project without reducing quality or expedite its completion or which, in the judgment of the Construction Manager, may otherwise be in the best interest of the Owner. The Owner shall not, however, be required to accept any such recommendations. The Construction Manager shall give notice to the Owner and to the Architect of any errors, inconsistencies or omissions (including non-conformance with applicable laws, statutes, building codes, rules and regulations) it may discover in the Construction Documents prior to acceptance of the proposed Construction Document Change Order. The Construction Manager will receive no additional payments or compensation for changes in the Work that result from coordination, errors or omissions in the documents for the installation of the Work. The Construction Manager shall be entitled to additional compensation pursuant to Section 3, Part 3 for changes due to unforeseen conditions at the site, changes required by governmental regulatory agencies, or scope changes requested by the Owner after the approval of the Construction Documents by the Owner. Construction Manager shall not be liable for any damages resulting from the failure of the Construction Documents to comply with said laws, statutes, building codes, rules and regulations unless it recognizes same and performs a construction activity knowing it is contrary to said laws, statutes, building codes, rules and regulations, without providing advanced notice of same to the Owner. Construction Manager shall also give notice of any inconsistencies, conflicts or omissions between said Construction Documents and either (i) the Program and revisions thereto by prior Construction Document Change Orders or (ii) the assumptions set forth in the GMP Change Order which were relied upon by Construction Manager in the preparation of the GMP Change Order, including observed inconsistencies, conflicts or omissions between the Construction Documents and any future design development of such assumptions.
Sample 1

Related to Construction Manager‟s Review

  • Construction Manager The individual, partnership, corporation, joint venture, or any combination thereof, or its authorized representative, named as such by the District. If no Construction Manager is used on the Project that is the subject of this Contract, then all references to Construction Manager herein shall be read to refer to District.

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Project Manager The term “Project Manager” refers to the employee of the State who has been assigned responsibility for overseeing and managing the proper and timely implementation of the project.

  • Contractor Project Manager The Contractor Project Manager shall serve, from the Effective Date, as the Contractor project manager and primary Contractor representative under this Agreement. The Contractor Project Manager shall (i) have overall responsibility for managing and coordinating the performance of Contractor’s obligations under this Agreement, including the performance of all Subcontractors; and (ii) be authorized to act for and bind Contractor and Subcontractors in connection with all aspects of this Agreement. The Contractor Project Manager shall respond promptly and fully to all inquiries from the JBE Project Manager.

  • County’s Project Manager Note: The written approval of substituted A-E Key Personnel is for departmental use only and shall not be used for auditing purposes outside OC Public Works or other County department.

  • Project Managers The JBE’s project manager is: [Insert name]. The JBE may change its project manager at any time upon notice to Contractor without need for an amendment to this Agreement. Contractor’s project manager is: [Insert name]. Subject to written approval by the JBE, Contractor may change its project manager without need for an amendment to this Agreement.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).

  • Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!