Construction of Base Building Improvements Sample Clauses

Construction of Base Building Improvements. Landlord shall construct, at its sole cost and expense, in a good workmanlike manner and without deduction from the Tenant Improvement Allowance, the Base Building improvements (the "Base Building Improvements"), generally as depicted in Schedule 1-A, attached hereto (the "Base Building Plans"), including the items set forth in Schedule 1-B (the "Base Building Modifications"), subject to Landlord Minor Changes, as that term is defined herein below. In the event of a conflict between Schedule 1-A and Schedule 1-B, Schedule 1-A shall prevail. Landlord hereby reserves the right to modify the Base Building Plans, provided that such modifications (A) are required to comply with Applicable Laws or as a condition of any governmental or other third-party approvals or consents that are required to be obtained in connection with the Base Building Improvements, (B) will not (i) materially and adversely affect Tenant's Permitted Use of the Premises and the Project or materially increase the cost of the Tenant Improvements or decrease the functionality of the Tenant Improvements, or (ii) result in the use of materials, systems or components which are not of a materially equivalent or better quality than the materials, systems and components set forth in the Base Building Plans, or in the Lease, or (C) pertain to portions of the Project located outside of the Buildings (provided that Landlord may not reduce the number of parking spaces available for Tenant's use) (collectively, "Landlord Minor Changes"). The Base Building Improvements, as well as the Common Areas (including the so-called "path of travel") will be constructed in a good and workmanlike manner, and in compliance with Applicable Laws for unoccupied space as of the date of Substantial Completion of the Base Building Improvements to the extent required to allow Tenant, subject to the construction of the Tenant Improvements, to obtain a certificate of occupancy or its legal equivalent allowing the legal occupancy of the Premises for the Permitted Use. Within five (5) days after the Substantial Completion of the Base Building Improvements, Landlord and Tenant shall have a "walk-through" of the delivered Premises to jointly create a punch- list setting forth any deviations between the required Base Building Improvements and the actual condition of the Premises (the "Delivery Punch List"). Landlord shall repair or correct the items set forth on the Delivery Punch List within a commercially reasonable period after...
Sample 1
AutoNDA by SimpleDocs
Construction of Base Building Improvements. Landlord shall construct, at its sole cost and expense (and not deducted from the Tenant Improvement Allowance or included in Direct Expenses), in a good workmanlike manner and without deduction from the Tenant Improvement Allowance, the Base Building improvements (the "Base Building Improvements"), in substantial conformance with the plans and specifications referred to in Schedule 1, attached hereto (the "Base Building Plans"), subject to Landlord Minor Changes, as that term is defined herein below. Landlord shall, at Landlord's expense, diligently apply for (or cause Landlord's contractor to apply for) and obtain all inspections, approvals, licenses and permits for the performance of the Base Building Improvements. The Base Building Improvements, as well as the Common Areas (including the so-called "path of travel") will be constructed in a good and workmanlike manner, and in compliance with applicable laws for unoccupied space as of the date of substantial completion of the Base Building Improvements to the extent required to allow Tenant, subject to the construction of the Tenant Improvements in accordance with applicable laws, to obtain a certificate of occupancy or its legal equivalent allowing the legal occupancy of the Premises for the Permitted Use.
Sample 1
Construction of Base Building Improvements. Promptly following finalization and approval of the Approved Tenant Improvement Working Drawings, Landlord will apply for and use diligent efforts to obtain the necessary permits and approvals to allow construction of the Base Building Improvements ("Permits"). Landlord shall execute a construction contract with Landlord's Contractor who will diligently construct and complete the Base Building Improvements substantially in accordance with Base Building Plans subject to any approved Change Orders required by the Approved Tenant Improvement Working Drawings. Landlord specifically reserves the right to make at any time and from time to time during the construction of the Base Building Improvements, any changes to the Base Building Plans necessary to obtain any Permit or to comply with all applicable regulations, laws, ordinances, codes and roles or to achieve the compatibility, as reasonably determined by Landlord, of the Base Building Plans with the shell and the core and the mechanical, plumbing, life safety and electrical systems of the Building and any third-party warranties.
Sample 1
Construction of Base Building Improvements. Landlord shall construct, at its sole cost and expense, in a good workmanlike manner and without deduction from the Tenant Improvement Allowance, the Base Building improvements (the "Base Building Improvements"), generally as depicted in Schedule 1-A, attached hereto (the "Base Building Plans"), including the items set forth in Schedule 1-B (the "Base Building Modifications"), subject to Landlord Minor Changes, as that term is defined herein below. In the event of a conflict between Schedule 1-A and Schedule 1-B, Schedule 1-A shall prevail. Landlord hereby reserves the right to modify the Base Building Plans, provided that such modifications (A) are required to comply with Applicable Laws or as a condition of any governmental or other third-party approvals or consents that are required to be obtained in connection with the Base Building Improvements, (B) will not (i) materially and adversely affect Tenant's Permitted Use of the Premises and the Project or materially increase the cost of the Tenant Improvements or decrease the functionality of the Tenant Improvements, or (ii) result in the use of materials, systems or components which are not of a materially equivalent or better quality than the materials, systems and components set forth in the Base Building Plans, or in the Lease, or
Sample 1
Construction of Base Building Improvements. (a) Landlord shall cause the Base Building Improvements to be constructed in a diligent and good and workmanlike manner, free of material defects, in accordance with all Legal Requirements and the Permitted Exceptions, and in substantial accordance with the approved Base Building Construction Documents. Landlord shall cause the Commencement of Construction to occur not later than the date that is sixty (60) days following the expiration of the Public Announcement Termination Rights. (b) Tenant shall have the right to inspect the Base Building Improvements during the course of the construction thereof, provided that no such inspection shall interfere with the construction of the Base Building Improvements. If Tenant observes that the Base Building Improvements are not being constructed in a good and workmanlike manner and/or substantially in accordance with the Tenant-approved Base Building Construction Documents, Tenant shall notify Landlord of such observation promptly, but in no event more than five (5) Business Days after Tenant makes such observation. If Landlord agrees with Tenant’s assertion that the Base Building Improvements are not being constructed substantially in accordance with the Base Building Construction Documents, Landlord shall cause such failure to be remedied. If Landlord disagrees with such assertion by Tenant, either Landlord or Tenant shall be entitled to submit such dispute to arbitration in accordance with Section 35 of this Lease. If Landlord prevails in any such arbitration, then any days on which the construction of the Base Building Improvements are not performed due to the pendency of such dispute shall constitute Tenant Delays.
Sample 1
Construction of Base Building Improvements. Landlord will apply for and use diligent efforts to obtain the necessary permits and approvals for the construction of the Base Building Improvements. Landlord shall execute a construction contract with Landlord's Contractor who will diligently construct and complete the Base Building Improvements subject to any approved Change Orders required by the Approved Tenant Improvement Working Drawings. Provided the same does not materially delay substantial completion of the Base Building Improvements, Landlord specifically reserves the right to make at any time and from time to time during the construction of the Base Building Improvements, any changes necessary to obtain any permit or to comply with all applicable regulations, laws, ordinances, codes and rules or to achieve the compatibility, as reasonably determined by Landlord, of the Base Building Improvements with the shell and the core and the mechanical, plumbing, life safety and electrical systems of the Building and any third-party warranties. Landlord shall provide timely notice of any material change to Tenant. If in the reasonable judgment of Tenant's Architect any such change will require re-design or re-engineering of the Tenant Improvements, Landlord's Construction Representative shall meet with Tenant's Architect and attempt in good faith to modify any such change to avoid such re-design or re-engineering.
Sample 1
Construction of Base Building Improvements 
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs

Related to Construction of Base Building Improvements

  • Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Lessee Improvements Lessee shall prepare final plans and ------------------- specifications for construction of the Lessee Improvements desired by Lessee and shall deliver to Lessor by July 1, 1999, two (2) copies of such plans and specifications and the names of two proposed contractors to construct the Lessee Improvements for Lessor approval. Lessor will promptly either approve of the plans and specifications and the contractors, or communicate its objections, and if Lessor has objections, the Lessor will work diligently with Lessee to resolve any objections such that approval of the plans and specifications and names of contractors is given within fifteen (15) days of receipt. Lessor shall be deemed to have approved the plans and specifications and the contractors unless Lessor shall have provided written notice to Lessee of Lessor's objections thereto within fourteen (14) days following the delivery thereof by Lessee to Lessor. The Lessor approved final plans and specifications for the Lessee Improvements are herein called the "Lessee Improvements Final Plans and Specifications". All reasonable costs involved in approving, drafting and preparing the Lessee Improvements Final Plans and Specifications shall be charged against the Improvement Allowance described below. Lessor shall apply for building permits to construct the Lessee Improvements and will submit bid requests to the two contractors selected by Lessee and the contractor for the Shell Building Improvements no later than two (2) days following approval of the Lessee Improvements Final Plans and Specifications. Contractors will be required to submit their bids no later than thirty (30) days following receipt of the bid request. Lessee shall have fifteen (15) days from receipt of all bids to select the contractor for the Lessee Improvements. Except for immaterial field changes, modifications to the Lessee Improvements Final Plans and Specifications must be made and accepted only by written change order or agreement signed by Lessor and Lessee and will constitute an amendment to this Lease. Lessee shall be responsible for payment in advance of all work and construction resulting from changes in the Lessee Improvements Final Plans and Specifications requested by Lessee if the additional cost attributable to the changes exceed the Improvement Allowance by more than $3.00 as described in subparagraph (c) below. The Lessee Improvements Final Plans and Specifications (when approved by Lessor and Lessee) are incorporated in this Lease by reference. For the purpose of this Section, an "immaterial field change" shall mean such field changes which are required by any governmental authority or changes which (i) do not affect the size, configuration, structural integrity, quality, character, architectural appearance and standard of workmanship contemplated in the Lessee Improvements Final Plans and Specifications, (ii) will not result in any default in any obligation to any person or violation of any governmental requirements, and (iii) the cost of or reduction resulting from any single field change or extra does not exceed $5,000.00.

  • Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.

  • Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above. (b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01. (c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,. (d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions: 1. Actual cost of the Landlord Improvements: $100,000.00 2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75 (e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements: (i) Replace all stained, damaged or missing ceiling tiles, (ii) Paint all walls in the Leased Premises, the color to be designated by Tenant, (iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C, (iv) Shampoo all carpets in the office areas and hallways and (v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use. (vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface (vii) Repair any existing alligator or pothole areas.

  • Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.

  • ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.

  • Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.

  • Initial Improvements Subtenant may, at its option and subject to the provisions of the Prime Lease, including, without limitation, Article 8 thereof, complete certain initial improvements to prepare the Demised Premises for Subtenant’s occupancy thereof as described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B (the “Initial Improvements”), at Subtenant’s sole cost and expense without any contribution or improvement allowance from Sublandlord described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B); provided, however, Subtenant shall not make or permit anyone to make any Initial Improvements without the prior written consent of Sublandlord, which shall not be unreasonably withheld or delayed, and of Prime Landlord in accordance with the Prime Lease. In connection with the foregoing, Subtenant shall submit to Sublandlord, for prior written approval by Sublandlord, which shall not be unreasonably withheld or delayed, and Prime Landlord, complete plans and specifications for any and all Initial Improvements; including, without limitation, schematic designs and work drawings. Any and all costs and expenses associated with the acquisition of cabling, equipment, furniture, security systems, or other personal property for Subtenant or the Demised Premises or the installation or placement of any of the foregoing within the Demised Premises or with the project management for the performance of the Initial Improvements (collectively, “Subtenant’s Personal Property and Services”), shall be paid for by and be the sole responsibility of Subtenant. Sublandlord acknowledges and agrees that Subtenant shall not be required to remove any Initial Improvements upon the expiration or earlier termination of this Sublease unless the removal is required by Prime Landlord or Sublandlord is otherwise obligated to pay Prime Landlord the costs of any removal of any Initial Improvements pursuant to Section 8(e) of the Prime Lease.

  • Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!