Construction of the Seller Interconnection Facilities Sample Clauses

Construction of the Seller Interconnection Facilities. (a) The Seller shall carry out or cause to be carried out the Seller Interconnection Works with all proper skill and care and in all material respects in accordance with: (i) this Agreement; (ii) the Laws of Pakistan and the applicable Seller Consents; (iii) the Generation Licence, if applicable; (iv) Prudent Utility Practices and Prudent Electrical Practices; and (v) Schedule 3, so that the Seller Interconnection Facilities can reasonably be expected to provide a useful life of not less than the Term. (b) The design, scope and specification of the Seller Interconnection Works are set out in Schedule 3. The Seller shall give the Purchaser in the Construction Reports not less than thirty (30) Days’ prior notice of the date from which it or its Contractor will commence the Seller Interconnection Works and shall complete the Seller Interconnection Works in accordance with the Interconnection Works Schedule. Subject to Section 2.3(b) and Section 5.1 of the Implementation Agreement, the Seller shall procure (or shall cause its Contractor in respect of the Seller Interconnection Works to procure) all Seller Consents necessary for carrying out the Seller Interconnection Works.
Sample 1See All (4)
AutoNDA by SimpleDocs
Construction of the Seller Interconnection Facilities. (a) The Seller, at its cost, shall carry out or cause to be carried out the Seller Interconnection Works with all proper skill, diligence and care, and in all material respects in accordance with: (i) this Agreement; (ii) the Laws of Pakistan and the applicable Seller Consents; (iii) the Grid Code; (iv) the Generation Licence; (v) Prudent Utility Practices and Prudent Electrical Practices; and (vi) Schedule 3, so that the Seller Interconnection Facilities can reasonably be expected to provide a useful life of not less than the Term. (b) The design, scope and Specification of the Seller Interconnection Works are set out in Schedule 3. The Seller shall give the Purchaser in the Construction Reports not less than thirty (30) Days’ prior notice of the date from which it or its Contractor will commence the Seller Interconnection Works and shall complete the Seller Interconnection Works in accordance with the Interconnection Works Schedule. The Seller shall ensure that the Construction Reports provided to the Purchaser in accordance with this Agreement also contains a progress report in respect of the completion of the Seller Interconnection Works Schedule. The Seller shall procure (or shall cause the EPC Contractor to procure) all Seller Consents necessary for carrying out the Seller Interconnection Works. (c) Not applicable. (d) The Seller shall undertake the following works on behalf of the Purchaser, if required by the Purchaser, at the Purchaser’s Interconnection Facilities at the Purchaser’s cost and time: (i) Replacement and/or upgradation of power line carrier, SCADA, remote terminal unit interface; (ii) Signal parameterization from the Complex to the Grid System and the main Control Centre; (iii) Procurement and installation of relevant SCADA and/or remote terminal unit hardware at Purchaser’s Grid system(s) and Control Centre; (iv) Augmentation of SCADA / remote terminal unit communication at Control Centre; and (e) Any costs incurred by the Seller on behalf of the Purchaser in respect of works set out in Section 6.1(d) above shall be reimbursed by the first invoice raised by the Seller following the Commercial Operations Date, provided the amount of such invoice is less than USD 100,000. For any works required to be undertaken by the Seller on behalf of the Purchaser, for which the estimated cost exceeds USD 100,000, the Purchaser may elect to undertake the work itself upon submission of the supporting documents by the Seller evidencing such estimate,...
Sample 1
Construction of the Seller Interconnection Facilities. (a) The Seller, at its cost, shall carry out or cause to be carried out the Seller Interconnection Works with all proper skill, diligence and care, and in all material respects in accordance with: (i) this Agreement; (ii) the Laws of Pakistan and the applicable Seller Consents; (iii) the Grid Code; (iv) the Generation Licence; (v) Prudent Utility Practices and Prudent Electrical Practices; and (vi) Schedule 3, so that the Seller Interconnection Facilities can reasonably be expected to provide a useful life of not less than the Term.
Sample 1
Construction of the Seller Interconnection Facilities. ‌ (a) To the extent not provided for in Schedule 3, the construction and completion of the Seller Interconnection Facilities shall be governed by this section 6. 1. In case of any conflict or inconsistency between the provisions of this Article 6 and Schedule 3, the provisions of Schedule 3 shall prevail. The Seller shall, at its cost, carry out or cause to be carried out the Seller Interconnection Works with all proper skill and care and in all material respects in accordance with — (i) this Agreement, (ii) the Laws of Pakistan and the applicable Seller Consents, (iii) the Grid Code, (iv) the Generation Licence, (v) Prudent Utility Practices and Prudent Electrical Practices, and (vi) Schedule 3 — so that the Seller Interconnection Facilities can be reasonably expected to provide a useful life of not less than the Term. (b) The design, scope,specification and schedule of the Seller Interconnection Works are set forth in Schedule 3.The Seller shall procure (or cause its Contractors to procure) all Seller Consents necessary for carrying out the Seller Interconnection Works.
Sample 1

Related to Construction of the Seller Interconnection Facilities

  • Interconnection Facilities 4.1.1 The Interconnection Customer shall pay for the cost of the Interconnection Facilities itemized in Attachment 2 of this Agreement. The NYISO, in consultation with the Connecting Transmission Owner, shall provide a best estimate cost, including overheads, for the purchase and construction of its Interconnection Facilities and provide a detailed itemization of such costs. Costs associated with Interconnection Facilities may be shared with other entities that may benefit from such facilities by agreement of the Interconnection Customer, such other entities, the NYISO, and the Connecting Transmission Owner. 4.1.2 The Interconnection Customer shall be responsible for its share of all reasonable expenses, including overheads, associated with (1) owning, operating, maintaining, repairing, and replacing its own Interconnection Facilities, and

  • Interconnection Customer’s Interconnection Facilities The Interconnection Customer shall design, procure, construct, install, own and/or control the Interconnection Customer’s Interconnection Facilities described in Appendix A at its sole expense.

  • Participating TO’s Interconnection Facilities The Participating TO shall design, procure, construct, install, own and/or control the Participating TO’s Interconnection Facilities described in Appendix A at the sole expense of the Interconnection Customer. Unless the Participating TO elects to fund the capital for the Participating TO’s Interconnection Facilities, they shall be solely funded by the Interconnection Customer.

  • Purpose of Interconnection Facilities Except as may be required by Applicable Laws and Regulations, or as otherwise agreed to among the Parties, the Interconnection Facilities shall be constructed for the sole purpose of interconnecting the Large Generating Facility to the Participating TO’s Transmission System and shall be used for no other purpose.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Interconnection Facility Options The Intercarrier Compensation provisions of this Agreement shall apply to the exchange of Exchange Service (EAS/Local) traffic between CLEC's network and Qwest's network. Where either Party acts as an IntraLATA Toll provider, each Party shall xxxx the other the appropriate charges pursuant to its respective tariff or price lists. Where either Party interconnects and delivers traffic to the other from third parties, each Party shall xxxx such third parties the appropriate charges pursuant to its respective tariffs, price lists or contractual offerings for such third party terminations. Absent a separately negotiated agreement to the contrary, the Parties will directly exchange traffic between their respective networks without the use of third party transit providers.

  • Interconnection 2.1 This section applies to linking with suppliers providing public telecommunications transport networks or services in order to allow the users of one supplier to communicate with users of another supplier and to access services provided by another supplier, where specific commitments are undertaken.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

  • Common Facilities “Common Facilities” includes all areas, facilities, utilities, equipment and services provided by Landlord for the common use or benefit of the occupants of the Property, and their employees, agents, customers and other invitees, including without limitation building lobbies, common corridors and hallways, restrooms, pedestrian walkways, driveways and access roads, access facilities for disabled persons (including elevators), truck serviceways, loading docks, garages, driveways, parking lots, landscaped areas, stairways, elevators, retaining walls, all areas required to be maintained under the conditions of governmental approvals for the Property, comfort and first-aid stations, parcel pick-up stations and other generally understood public or common areas. All Common Facilities shall at all times be subject to the exclusive control and management of Landlord. Landlord shall have the right, without liability to Tenant, to relocate, alter, improve, or adjust the size and location of any Common Facilities from time to time, and Landlord shall have the right from time to time to establish, modify and enforce reasonable rules and regulations with respect to the Common Facilities. Landlord shall have the right to construct, maintain and operate lighting facilities on the Common Facilities; to police the same; from time to time to change the area, level, location and arrangement of parking areas and other facilities; to restrict parking by tenants, their officers, agents and employees to employee parking areas; to enforce parking charges (by operation of meters or otherwise), with appropriate provisions for free parking ticket validating by tenants; to close all or any portion of the Common Facilities to such extent as may, in the opinion of Landlord’s counsel, be legally sufficient to prevent a dedication thereof or the accrual of any rights to any person or the public therein; to close temporarily all or any portion of the Common Facilities; to discourage non-customer parking; and to do and perform such other acts in and to the Common Facilities which Landlord shall determine, using good business judgment, to be advisable to improve the convenience and use thereof by tenants, their officers, agents, employees and customers. Subject to the foregoing, Tenant may use all Common Facilities not within the Premises, under a revocable license, on a nonexclusive basis in common with other tenants. If any such license is revoked, or if the amount of such areas is diminished, Landlord shall not be subject to any liability and Tenant shall not be entitled to any compensation or abatement of rent, nor shall such revocation or diminution be deemed constructive or actual eviction.

  • Use of Interconnection Facilities by Third Parties 6551 Error! Hyperlink reference not valid.9.9.1 Purpose of Interconnection Facilities. 6551

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!