Definition of General Education Courses and Pre-major Courses Sample Clauses

Definition of General Education Courses and Pre-major Courses. The Associate in Arts (AA) and Associate in Science (AS) degree programs in the North Carolina Community College System require a total of sixty or sixty-one semester hours credit for graduation (see Appendix F) and are transferable to any UNC institution. The overall total is comprised of both lower-division general education and pre-major courses. This curriculum reflects the distribution of discipline areas commonly included in institution-wide, lower-division general education requirements for the baccalaureate degree. The Associate in Arts (AA) and Associate in Science (AS) degree programs include general education requirements that represent the fundamental foundation for success and include study in the areas of English composition, communications, humanities and fine arts, natural sciences and mathematics, and social and behavioral sciences. Within these discipline areas, community colleges must include opportunities for the achievement of competence in reading, writing, oral communication, fundamental mathematical skills, and basic computer use. Students must meet the receiving university's foreign language and/or health and physical education requirements, if applicable, prior to or after transfer to the senior institution. The AA and AS degree programs of study are structured to include two components: –Universal General Education Transfer Component comprises a minimum of 30 semester hours of credit, and –Additional general education, pre-major, and elective courses that prepare students for successful transfer into selected majors at UNC institutions and bring the total number of hours in the degree programs to 60-61 semester hours. To ensure maximum transferability of credits, students should select a transfer major and preferred transfer university before completing 30 semester hours of credit. Additional general education, pre- major, and elective courses should be selected based on a student’s intended major and transfer institution. Each receiving institution will identify community college course equivalencies and publicize an equivalency course crosswalk to ensure transfer of credit uniformity and transparency. The specific number and distribution of courses used to fulfill the requirement in each of these areas will be identified by each community college as meeting its own general education requirements. The Universal General Education Transfer Component and Other Required General Education courses will be drawn from those courses desi...
Sample 1Sample 2Sample 3See All (21)
AutoNDA by SimpleDocs
Definition of General Education Courses and Pre-major Courses. The Associate in Arts (AA) and Associate in Science (AS) degree programs in the North Carolina Community College System require a total of sixty or sixty-one semester hours credit for graduation (see Appendix F) and are transferable to any UNC institution. The overall total is comprised of both lower- division general education and pre-major courses. This curriculum reflects the distribution of discipline areas commonly included in institution-wide, lower-division general education requirements for the baccalaureate degree. The AA and AS degree programs include general education requirements that represent the fundamental foundation for success and include study in the areas of English composition, communications, humanities and fine arts, natural sciences and mathematics, and social and behavioral sciences. Within these discipline areas, community colleges must include opportunities for the achievement of competence in reading, writing, oral communication, fundamental mathematical skills, and basic computer use. Students must meet the receiving university's foreign language and/or health and physical education requirements, if applicable, prior to or after transfer to a UNC System institution. The AA and AS degree programs of study are structured to include two components: –Universal General Education Transfer Component courses comprise a minimum of 30 semester hours of credit, and –Additional general education, pre-major, and elective courses that prepare students for successful transfer into selected majors at UNC System institutions will bring the total number of hours in the degree programs to 60-61 semester hours. To ensure maximum transferability of credits, students should select a transfer major and follow preferred transfer university options known as Baccalaureate Degree Plans (BDPs, see section V.A.7.) before completing 30 semester hours of credit. Additional general education, pre-major, and elective courses should be selected based on a student’s intended major and transfer institution options. Students will receive instruction, guidance, and assistance in making these selections when enrolled in the NCCCS course ACA 122 – College Transfer Success. NCCCS institutions are encouraged to require ACA 122 of all AA and AS program enrollees during their first semester of enrollment to promote effective and efficient transfer. Each receiving institution will identify community college course equivalencies and publicize an equivalency course crosswal...
Sample 1Sample 2
Definition of General Education Courses and Pre-major Courses. The Associate in Arts (AA) and Associate in Science (AS) degree programs in the North Carolina Community College System require a total of sixty or sixty-one semester hours credit for graduation (see Appendix D) and are transferable to Signatory Institution of North Carolina Independent Colleges and Universities. The degrees are comprised of both lower-division general education and pre-major courses. The curricula reflect the distribution of discipline areas commonly included in institution- wide, lower-division general education requirements for the baccalaureate degree. The Associate in Arts (AA) and Associate in Science (AS) degree programs include general education requirements that represent the fundamental foundation for success and include study in the areas of English composition, communications, humanities and fine arts, natural sciences and mathematics, and social and behavioral sciences. Within these discipline areas, community colleges must include opportunities for the achievement of competence in reading, writing, oral communication, fundamental mathematical skills, and basic computer use. Students must meet the receiving senior institution’s foreign language and/or health and physical education requirements, if applicable, prior to or after transfer to the senior institution. The AA and AS degree programs of study are structured to include: – the Universal General Education Transfer Component (UGETC) which includes a minimum of 30 semester hours of credit, and –additional general education, pre-major, and elective courses that prepare students for successful transfer into selected majors at the senior institution and bring the total number of hours in the degree programs to 60-61 semester hours. To ensure maximum transferability of credits, students should select a transfer major and preferred transfer institution before completing 30 semester hours of credit at the community college. Each receiving senior institution will identify community college course equivalencies and publicize an equivalency course crosswalk to ensure transfer of credit uniformity and transparency. Additional general education, pre-major, and elective courses in the associate degree should be selected based on a student’s intended major and the baccalaureate degree plan published by the senior institution. The specific number and distribution of courses used to fulfill the requirement in each of these areas will be identified by each community college as meeting its ...
Sample 1
Definition of General Education Courses and Pre-major Courses. The Associate in Arts (AA) and Associate in Science (AS) degree programs at Louisburg College require a total of sixty or sixty-one semester hours credit for graduation (see Appendix F) and are transferable to any UNC institution. The overall total is comprised of both lower-division general education and pre- major courses. This curriculum reflects the distribution of discipline areas commonly included in institution-wide, lower-division general education requirements for the baccalaureate degree. The Associate in Arts (AA) and Associate in Science (AS) degree programs include general education requirements that represent the fundamental foundation for success and include study in the areas of English composition, communications, humanities and fine arts, natural sciences and mathematics, and social and behavioral sciences. Within these discipline areas, Louisburg College must include opportunities for the achievement of competence in reading, writing, oral communication, fundamental mathematical skills, and basic computer use. Students must meet the receiving university's foreign language and/or health and physical education requirements, if applicable, prior to or after transfer to the senior institution. The AA and AS degree programs of study are structured to include two components: –Universal General Education Transfer Component comprises a minimum of 30 semester hours of credit, and –Additional general education, pre-major, and elective courses that prepare students for successful transfer into selected majors at UNC institutions and bring the total number of hours in the degree programs to 60-61 semester hours. To ensure maximum transferability of credits, students should select a transfer major and preferred transfer university before completing 30 semester hours of credit. Additional general education, pre- major, and elective courses should be selected based on a student’s intended major and transfer institution. Each receiving institution will identify Louisburg College course equivalencies and publicize an equivalency course crosswalk to ensure transfer of credit uniformity and transparency. The specific number and distribution of courses used to fulfill the requirement in each of these areas will be identified by Louisburg College as meeting its own general education requirements. The Universal General Education Transfer Component and Other Required General Education courses will be drawn from those courses designated in the North Carolina Co...
Sample 1

Related to Definition of General Education Courses and Pre-major Courses

  • Definitions of General Application For purposes of this Agreement, unless otherwise specified: Agreement means the Free Trade Agreement between the Government of the People's Republic of China and the Government of the Republic of Peru; Commission means the Free Trade Commission established under Article 170 (Free Trade Commission) of Chapter 14 (Administration of the Agreement);

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements

  • Provisions of General Application (a) All accounting terms not specifically defined herein shall be construed in accordance with GAAP. (b) The terms defined in this Article include the plural as well as the singular. (c) The words "herein," "hereof" and "hereunder" and other words of similar import refer to this Agreement as a whole. All references to Articles and Sections shall be deemed to refer to Articles and Sections of this Agreement.

  • Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.

  • Additional Wet Weather Procedure 14.15.1 Remaining On Site a) for more than an accumulated total of four hours of ordinary time in any one day; or b) after the meal break, as provided for in clause 17.1 of the Award, for more than an accumulated total of 50% of the normal afternoon work time; or c) during the final two hours of the normal work day for more than an accumulated total of one hour, the Enterprise will not be entitled to require the employees to remain on site beyond the expiration of any of the above circumstances.

  • Other Provisions of General Application Section 7.1 Notices to the Rights Agent, Parent and the Stockholders’ Representative. Any notice, request, instruction or other document to be given hereunder by any party to the others shall be in writing and delivered personally or sent by registered or certified mail, postage prepaid, by electronic mail (except with respect to the Rights Agent), by facsimile transmission only with respect to the Rights Agent or overnight courier, provided that with respect to notices deliverable to the Stockholders’ Representative, such notices shall be delivered solely via electronic mail or facsimile: If to Parent or the Company: Eros International Plc First Names House Victoria Road Xxxxxxx Isle of Man IM2 4DF British Isles Attention: Xxxx Xxxxxxx, Chief Corporate and Strategy Officer Email: xxxx.xxxxxxx@xxxxxxxx.xxx with a copy (which shall not constitute notice) to: Xxxxxx, Xxxx & Xxxxxxxx LLP 000 Xxxxx Xxxxx Xxxxxx Xxx Xxxxxxx, Xxxxxxxxxx 00000-0000 Attention: Xxxxx Xxxxxx Xxxxx Xxxxxx Email: xxxxxxx@xxxxxxxxxx.xxx xxxxxxx@xxxxxxxxxx.xxx If to the Rights Agent: Computershare Trust Company, N.A., Computershare Inc. 000 Xxxxxx Xxxxxx Canton, MA 02021 Attention: Client Services Facsimile: (000) 000-0000 If to the Stockholders’ Representative: Fortis Advisors LLC Attention: Notices Department (Project World Cup) Email: xxxxxxx@xxxxxxxxx.xxx Facsimile: (000) 000-0000 with a copy (which shall not constitute notice) to: Xxxxxxxx & Xxxxx LLP 000 Xxxxx Xxxxxx Xxxxxx, Xxxxx 0000 Xxx Xxxxxxx, Xxxxxxxxxx 00000 Attention: Xxxx X. Xxxxxx, P.C. Email: xxxx.xxxxxx@xxxxxxxx.xxx or to such other persons or addresses as may be designated in writing by the party to receive such notice as provided above. Any notice, request, instruction or other document given as provided above shall be deemed given to the receiving party upon actual receipt, if delivered personally; three (3) business days after deposit in the mail, if sent by registered or certified mail; upon confirmation of successful transmission if sent by electronic mail; or on the next business day after deposit with an overnight courier, if sent by an overnight courier.

  • Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Review by the Association of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the Association’s Prior Review. All other contracts shall be subject to Post Review by the Association.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!