Emergency Support Service Sample Clauses

Emergency Support Service. If any natural disaster or other emergency occurs whereby Material and Service provided in connection with this Agreement is damaged and such condition materially affects CINGULAR’s ability to provide services to its subscribers, MOTRICITY agrees, at CINGULAR’s request, to assist CINGULAR as provided in Appendix 1.2
Sample 1Sample 2
AutoNDA by SimpleDocs
Emergency Support Service. If any natural disaster or other emergency occurs whereby Material and Service provided in connection with this Agreement is damaged and such condition materially affects CINGULAR's ability to provide services to its subscribers, SUPPLIER agrees, at CINGULAR's request, to assist CINGULAR as follows: a. SUPPLIER will locate backup or replacement Material and provide any necessary Service. b. If Material is available from SUPPLIER's stock, SUPPLIER will ship replacement Material in manner specified by CINGULAR within twenty-four (24) hours of receipt of CINGULAR's request therefor. c. When Material required by CINGULAR is not available from stock for immediate shipment, SUPPLIER agrees to pursue the following alternative courses of action: 1. Assist CINGULAR in locating functionally equivalent substitute Material. 2. If requested by CINGULAR, schedule the repair or new manufacture of Material on a priority basis. CINGULAR will indemnify SUPPLIER for any financial obligations incurred by SUPPLIER as a result of such priority efforts due to contractual obligations with third parties. 3. Assist CINGULAR by providing field technical personnel to make temporary modifications and arrangements to mitigate the effects of out-of-service conditions. If requested, by CINGULAR, SUPPLIER will document such efforts and associated charges. The price for any replacement Material or Service which is not covered by SUPPLIER's warranty will be at SUPPLIER's applicable price plus cost of expedited shipment. SUPPLIER will make available the individual whose title, phone number and location are listed below to provide assistance and information on a twenty-four (24) hour basis for all of its support service described above:
Sample 1
Emergency Support Service. Emergency telephone support will be available 24/7 solely to address situations in which Customer’s Camstar Enterprise Software production installation ceases to function entirely or causes a severe disruption to the Customer’s operations. The 24 hour support hotline should only be used outside of normal business hours; please call the Camstar Support Department directly during normal business hours.
Sample 1
Emergency Support Service. 16.1 If any natural disaster or other emergency occurs whereby Service provided in connection with this Agreement is damaged and such condition materially affects Cingular’s ability to provide services to its subscribers, StarTek agrees, at Cingular’s request, to assist Cingular as follows: a. StarTek will locate backup or replacement Material and provide any necessary Service. b. If Material is available from StarTek’s stock, StarTek will ship replacement Material in manner specified by Cingular within [*] of receipt of Cingular’s request therefore. c. When Material required by Cingular is not available from stock for immediate shipment, StarTek agrees to pursue the following alternative courses of action: 1. Assist Cingular in locating functionally equivalent substitute Material. 2. If requested by Cingular, schedule the repair or new manufacture of Material on a priority basis. Cingular will indemnify StarTek for any financial obligations incurred by StarTek as a result of such priority efforts due to contractual obligations with third parties. 3. Assist Cingular by providing field technical personnel to make temporary modifications and arrangements to mitigate the effects of out-of-service conditions. If requested, by Cingular, StarTek will document such efforts and associated charges. 16.2 StarTek will make available the individual whose title, phone number and location are listed below to provide assistance and information on a [*] basis for all of its support service described above: [Contact] 40 Xxxx Xxxxxx Denver, Colorado 80206 [Contact] Wireless, [Contact] Office This obligation will survive the expiration, cancellation, or termination of this Agreement for four (4) years. Contains private and/or proprietary information. May not be used or disclosed outside Cingular or Supplier except pursuant to a written Agreement. 17.1 Neither party shall be deemed in default of this Agreement or any SOW to the extent that any delay or failure in the performance of its obligations results from any cause beyond its reasonable control and without its fault or negligence, such as acts of God, acts of civil or military authority, embargoes, epidemics, war, riots, insurrections, fires, explosions, earthquakes, floods, or strikes (“Force Majeure”). 17.2 If any Force Majeure condition affects StarTek’s ability to perform, StarTek shall give immediate notice to Cingular and Cingular may elect to either: (1) Terminate the affected SOW(s) or any part thereof, (2) suspe...
Sample 1

Related to Emergency Support Service

  • Emergency Services The parties recognize that in the event of a strike or lockout, situations may arise of an emergency nature. To this end, the Employer and the Union will agree to provide services of an emergency nature.

  • EMERGENCY SERVICE If you are unable to reach Administrator at 877.634.0964 and you require emergency repair, you may contact any manufacturer authorized service repair facility listed in Your phone book or online. Mail Administrator Your original repair bill along with the technician’s report and a copy of the Agreement to the address at the top of this Agreement for reimbursement. All coverage and exclusions in this Agreement will apply.

  • Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).

  • Emergency Service Leave Where employees' services are required for emergency operations by request from Provincial Emergency Programs or appropriate police authority, leave from work as required may be granted without loss of basic pay. If any remuneration, other than for expenses, is received, it shall be remitted to the Employer.

  • Administrative Support Services Fees Within forty-five (45) days of the end of each calendar quarter or at such other period as deemed appropriate by the Distributor, the Fund will make payments in the aggregate amount of up to 0.25% on an annual basis of the average during the period of the aggregate net asset value of the Shares computed as of the close of each business day (the “Service Fee”). Such Service Fee payments received from the Fund will compensate the Distributor for providing administrative support services with respect to Accounts. The administrative support services in connection with Accounts may include, but shall not be limited to, the administrative support services that a Recipient may render as described in Section 3(b)(i) below.

  • Technical Support Services 2.1 The technical support services (the "Services"): Party A agrees to provide to Party B the relevant services requested by Party B, which are specified in Exhibit 1 attached hereto ("Exhibit 1").

  • TAX SUPPORT SERVICES BNY Mellon shall provide the following tax support services for each Fund:  Provide various data and reports as agreed upon in the SLDs to support TRP’s tax reporting and tax filing obligations, including: · Wash sales reporting; · QDI reporting; · DRD reporting; · PFIC analysis; · Straddle analysis; · Paydown adjustments; · Equalization debit adjustments · Tax compliance under §851, §817(h); · Foreign bond sale analysis (§988); · Troubled debt analysis; · Estimation of income for excise tax purposes; · Swap analysis; · Inflation adjustments; · §1256 adjustments; · Market discount analysis; OID adjustments; · CPDI analysis; · Shareholder tax reporting information (e.g. FTC, UGG income, foreign source income by country, exempt income by state);  Provide data, and reports based on such data, maintained by BNY Mellon on its fund accounting platform as reasonably requested by TRP to support TRP’s obligations to comply with requests from tax authorities and TRP’s tax reporting and tax filing obligations.  Assist with other tax-related data needs as mutually agreed upon in writing from time-to-time.

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

  • Emergency Services Leave (a) An Employee who engages in a voluntary emergency management activity is entitled to be absent without loss of pay from his or her employment for a total of 5 days per annum commencing at the start of each calendar year. For the avoidance of doubt, any days not utilised by the Employee by the end of the calendar year, do not carry over into the subsequent year. (b) Voluntary emergency management activity has the meaning provided by the FWA.

  • Emergency Operator Access Registry Operator shall provide bulk access to the zone files for the TLD to the Emergency Operators designated by ICANN on a continuous basis in the manner ICANN may reasonably specify from time to time.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!