Indemnification and Insurance Required of Private Contractors Sample Clauses

Indemnification and Insurance Required of Private Contractors. Developer hereby expressly agrees to indemnify and hold the City harmless from and against all claims, costs and liability related to any damage to the Property or injury or death to persons caused by Xxxxxxxxx’s performance of the Developer Improvements or any other work required of Developer under this Agreement, unless the cause is due to the willful misconduct by the City.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Indemnification and Insurance Required of Private Contractors. The Developer hereby expressly agrees to indemnify and hold the City harmless from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of, the performance of work at the development site and elsewhere pursuant to this Agreement, except to the extent caused by the willful or negligent act or omission of the City or its officers, employees or agents. The Developer further agrees to defend the City in the event that the City is named as a defendant in an action concerning the performance of work pursuant to this Agreement, except where such suit is brought by the Developer. The Developer is not an agent or employee of the City. The Developer shall require contractors engaged in the construction of this project to maintain a current Certificate of Insurance on file with the Director of Public Works in amounts which are approved by the Director of Public Works.
Sample 1Sample 2Sample 3
Indemnification and Insurance Required of Private Contractors. The DISTRICT hereby expressly agrees to indemnify and hold the VILLAGE and its agents harmless from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of the performance of work related to the PROJECT that is the subject of this AGREEMENT. The DISTRICT further agrees to aid and defend the VILLAGE or its agents (at no cost to the VILLAGE or its agents) in the event the VILLAGE or its agents are named as a defendant in an action concerning the performance of work pursuant to this AGREEMENT except where such suit is brought by the DISTRICT. The DISTRICT shall inform and require all Contractors engaged by the DISTRICT in the construction of this PROJECT to comply with the requirements of this AGREEMENT pertaining to damage claims, indemnification, and providing insurance coverage at amounts determined by the VILLAGE. The DISTRICT shall also require the DISTRICT’s contractors to maintain a current Certificate of Insurance on file with the VILLAGE CLERK. Said Certificate shall indicate that the VILLAGE and its service providers are named as insured or additional insured, to the extent that the addition of this designation is reasonably available in the commercial insurance market.
Sample 1
Indemnification and Insurance Required of Private Contractors. The Developer hereby expressly agrees to indemnify and hold the City and its agents harmless from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of the negligence of Developer or its agents or contractors in the performance of t he development and construction work o n the Project. After the any applicable warranty periods have run, the Developer will have no obligations under the prior sentence. The Developer further agrees to aid and defend the City or its agents (at no cost to the City or its agents) in the event they are named as a defendant in an action concerning the performance of work pursuant to this Agreement except where such suit is brought by the Developer or where the suit is due to the negligence of the City. The Developer is not an agent or employee of the City. Notwithstanding anything to the contrary in this paragraph, Developer shall not be obligated to indemnify or defend the City or its agents in situations in which the claims, costs and liability are the result of the City’s or its agent’s negligence, violation of applicable law, breach of a contract or agreement, or willful misconduct. The Developer shall inform and require all contractors engaged in the construction of this Project to comply with the requirements of this Agreement pertaining to damage claims, indemnification of the City and providing insurance coverage that are established by the City. The Developer shall also require contractors engaged in the construction of this Project to maintain a current Certificate of Insurance on file with the City Treasurer.
Sample 1
Indemnification and Insurance Required of Private Contractors. The Developer hereby expressly agrees to indemnify and hold the Municipality and its agents harmless in whole or in part from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of the performance of work on the Property and elsewhere including damage caused by the Municipality’s negligence as well as that of Developer or any contractor, pursuant to this Agreement. The Developer further agrees to aid and defend the Municipality or its agents (at no cost to the Municipality or its agents) in the event they are named as a defendant in an action concerning the performance of work pursuant to this Agreement except where such suit is brought by the Developer. The Developer is not an agent or employee of the Municipality. The Developer shall require all Contractors engaged in the construction of the Improvements to comply with the Municipal requirements pertaining to damage claims, indemnification of the Municipality, and providing insurance coverages that are established by the Municipality. The Developer shall also require Contractors engaged in the construction of the Improvements to provide a current Certificate of Insurance to the Municipal Clerk showing insurance for all statutorily required coverage and naming the Municipality as an additional insured.
Sample 1
Indemnification and Insurance Required of Private Contractors. The Subdivider hereby expressly agrees to indemnify and hold the Municipality and its agents harmless from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of the performance of work at the development site and elsewhere pursuant to this Agreement. The Subdivider further agrees to aid and defend the Municipality or its agents (at no cost to the Municipality or its agents) in the event they are named as a defendant in an action concerning the performance of work pursuant to this Agreement except where such suit is brought by the Subdivider. The Subdivider is not an agent or employee of the Municipality.
Sample 1
Indemnification and Insurance Required of Private Contractors. Developer hereby expressly agrees to indemnify, save and hold harmless Windsor, its engineers, employees, officers and agents from and against all claims, costs, suits, causes of actions, demands and liability of every kind and nature, for injury or damage received or sustained by any person or persons or property, whomsoever and whatsoever, in connection with, or on account of the performance of the work contemplated hereby and the construction of the Public Improvements. Developer further agrees to aid and defend Windsor in the event Windsor is named as a defendant in any action concerning the performance of the work pursuant to this Agreement, except where such suit is brought by Developer. It is hereby agreed that the Developer is not an agent or employee of Windsor. Developer shall require all Contractors engaged in the construction of the Public Improvements to comply with Windsor's contract requirements pertaining to damage claims, indemnification of Windsor and insurance. Developer shall also require contractors engaged in the construction of the Public Improvements to maintain a current certificate of insurance on file with Windsor’s Engineer. The Contractor(s) so engaged should be required to furnish comprehensive general liability insurance of not less than $1,000,000.00 aggregate for any such damage sustained by one or more persons in any one accident.
Sample 1
AutoNDA by SimpleDocs
Indemnification and Insurance Required of Private Contractors. Developer hereby expressly agrees to indemnify and hold the Village and its agents harmless from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of the performance of work at the development site and elsewhere pursuant to this Agreement. Developer further agrees to aid and defend the Village or its agents (at no cost to the Village or its agents) in the event they are named as a defendant in an action concerning the performance of work pursuant to this Agreement except where such suit is brought by Developer. Developer is not an agent or employee of the Village.
Sample 1
Indemnification and Insurance Required of Private Contractors. The Developer hereby expressly agrees to indemnify and hold the Town harmless from and against all claims, costs and liability of every kind and nature, for injury or damage received or sustained by any person or entity in connection with, or on account of the performance of work at the development site and elsewhere pursuant to this Agreement. The Developer further agrees to aid and defend the Town in the event that the Town is named as a defendant in an action concerning the Town’s performance of work pursuant to this Agreement except where such suit is brought by the Developer. The Developer is not an agent or employee of the Town. The Developer shall require all Contractors engaged in the construction of this project to comply with the Town contract requirements pertaining to damage claims, indemnification of the Town, and providing insurance coverages that are established by the Town. The Developer shall also require Contractors engaged in the construction of this project to maintain a current Certificate of Insurance on file with the Town Clerk.
Sample 1

Related to Indemnification and Insurance Required of Private Contractors

  • Indemnification and Insurance (a) From and after the Effective Time, Acquiror agrees that it shall indemnify and hold harmless each present and former director and officer of the (x) Company and each of its Subsidiaries (in each case, solely to the extent acting in their capacity as such and to the extent such activities are related to the business of the Company being acquired under this Agreement) (the “Company Indemnified Parties”) and (y) Acquiror and each of its Subsidiaries (the “Acquiror Indemnified Parties” together with the Company Indemnified Parties, the “D&O Indemnified Parties”) against any costs or expenses (including reasonable attorneys’ fees), judgments, fines, losses, claims, damages or liabilities incurred in connection with any Legal Proceeding, whether civil, criminal, administrative or investigative, arising out of or pertaining to matters existing or occurring at or prior to the Effective Time, whether asserted or claimed prior to, at or after the Effective Time, to the fullest extent that the Company, Acquiror or their respective Subsidiaries, as the case may be, would have been permitted under applicable Law and its respective certificate of incorporation, certificate of formation, bylaws, limited liability company agreement or other organizational documents in effect on the date of this Agreement to indemnify such D&O Indemnified Parties (including the advancing of expenses as incurred to the fullest extent permitted under applicable Law). Without limiting the foregoing, Acquiror shall, and shall cause its Subsidiaries to (i) maintain for a period of not less than six (6) years from the Effective Time provisions in its Governing Documents concerning the indemnification and exoneration (including provisions relating to expense advancement) of Acquiror’s and its Subsidiaries’ former and current officers, directors, employees, and agents that are no less favorable to those Persons than the provisions of the Governing Documents of the Company, Acquiror or their respective Subsidiaries, as applicable, in each case, as of the date of this Agreement, and (ii) not amend, repeal or otherwise modify such provisions in any respect that would adversely affect the rights of those Persons thereunder, in each case, except as required by Law. Acquiror shall assume, and be liable for, each of the covenants in this Section 7.8.

  • Maintenance of Insurance; Policy Provisions The Contractor, at no additional direct cost to NYSERDA, shall maintain or cause to be maintained throughout the term of this Agreement, insurance of the types and in the amounts specified in the Section hereof entitled Types of Insurance. All such insurance shall be evidenced by insurance policies, each of which shall:

  • Liability Indemnification and Insurance 9.1 Each Party's obligations and liabilities to the other arising out of or in connection with the provision of the Services and any other services provided hereunder shall be only those expressly set out in this Agreement together with those obligations which are implied by law but only to the extent that they cannot be restricted, limited or excluded;

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2

  • Insurance and Indemnification Costs of insurance in connection with the general conduct of activities are allowable, provided that the extent and cost of coverage are in accordance with the Grantee’s policy and sound business practice.

  • Indemnification and General Liability Section 10.4 Required Post-Expiration Coverage.

  • Indemnification and Save Harmless Provision The Association agrees to indemnify and hold the Board harmless against any liability which may arise by reason of any action taken by the Board in complying with the provisions of this Article.

Time is Money Join Law Insider Premium to draft better contracts faster.