We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.
For more information visit our privacy policy.Remedies; Obtaining the Collateral Upon Default Each Assignor agrees that, if any Event of Default shall have occurred and be continuing, then and in every such case, the Collateral Agent, in addition to any rights now or hereafter existing under applicable law, shall have all rights as a secured creditor under the Uniform Commercial Code in all relevant jurisdictions and may: (i) personally, or by agents or attorneys, immediately take possession of the Collateral or any part thereof, from such Assignor or any other Person who then has possession of any part thereof with or without notice or process of law, and for that purpose may enter upon such Assignor's premises where any of the Collateral is located and remove the same and use in connection with such removal any and all services, supplies, aids and other facilities of such Assignor; (ii) instruct the obligor or obligors on any agreement, instrument or other obligation (including, without limitation, the Receivables and the Contracts) constituting the Collateral to make any payment required by the terms of such agreement, instrument or other obligation directly to the Collateral Agent; (iii) withdraw all monies, securities and instruments in the Cash Collateral Account for application to the Obligations in accordance with Section 7.4 hereof; (iv) sell, assign or otherwise liquidate any or all of the Collateral or any part thereof in accordance with Section 7.2 hereof, or direct the relevant Assignor to sell, assign or otherwise liquidate any or all of the Collateral or any part thereof, and, in each case, take possession of the proceeds of any such sale or liquidation; (v) take possession of the Collateral or any part thereof, by directing the relevant Assignor in writing to deliver the same to the Collateral Agent at any place or places designated by the Collateral Agent, in which event such Assignor shall at its own expense:
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Default Rights and Remedies If an Event of Default exists, the Agent shall have the following rights and remedies: (a) In addition to all other rights and remedies granted to the Agent in this Agreement or in any other Loan Document or by applicable law, the Agent shall have all of the rights and remedies of a secured party under the UCC (whether or not the UCC applies to the affected Collateral). Without limiting the generality of the foregoing, the Agent may (A) without demand or notice to it, collect, receive or take possession of the Collateral or any part thereof and for that purpose the Agent may enter upon any premises on which the Collateral is located and remove the Collateral therefrom or render it inoperable, and/or (B) sell, lease or otherwise dispose of the Collateral, or any part thereof, in one or more parcels at public or private sale or sales, at the Agent's offices or elsewhere, for cash, on credit or for future delivery, and upon such other terms as the Agent may deem commercially reasonable or otherwise as may be permitted by law. The Agent shall have the right at any public sale or sales, and, to the extent permitted by applicable law, at any private sale or sales, to bid (which bid may be, in whole or in part, in the form of cancellation of indebtedness) and become a purchaser of the Collateral or any part thereof free of any right or equity of redemption on the part of the Debtor, which right or equity of redemption is hereby expressly waived and released by the Debtor. Upon the request of the Agent, the Debtor shall assemble the Collateral and make it available to the Agent at anyplace designated by the Agent that is reasonably convenient to it and the Agent. The Debtor agrees that the Agent shall not be obligated to give more than ten (10) days prior written notice of the time and place of any public sale or of the time after which any private sale may take place and that such notice shall constitute reasonable notice of such matters. The Agent shall not be obligated to make any sale of Collateral if it shall determine not to do so, regardless of the fact that notice of sale of Collateral may have been given. The Agent may, without notice or publication, adjourn any public or private sale or cause the same to be adjourned from time to time by announcement at the time and place fixed for sale, and such sale may, without further notice, be made at the time and place to which the same was so adjourned. The Debtor shall be liable for all reasonable expenses of retaking, holding, preparing for sale or the like, and all reasonable attorneys' fees, legal expenses and other costs and expenses incurred by the Agent in connection with the collection of the Obligations and the enforcement of the Agent's rights under this Agreement. The Debtor shall remain liable for any deficiency if the Proceeds of any sale or other disposition of the Collateral applied to the Obligations are insufficient to pay the Obligations in full to the extent provided in the Loan Documents. The Agent may apply the Collateral against the Obligations as provided in the Credit Agreement. The Debtor waives all rights of marshalling, valuation and appraisal in respect of the Collateral. Any cash held by the Agent as Collateral and all cash proceeds received by the Agent in respect of any sale of, collection from or other realization upon all or any part of the Collateral may, in the discretion of the Agent, be held by the Agent as collateral for, and then or at any time thereafter applied in whole or in part by the Agent against, the Obligations in the order permitted by the Credit Agreement. Any surplus of such cash or cash proceeds and interest accrued thereon, if any, held by the Agent and remaining after payment in full of all the Obligations shall be promptly paid over to the Debtor or to whomsoever may be lawfully entitled to receive such surplus; provided that the Agent shall have no obligation to invest or otherwise pay interest on any amounts held by it in connection with or pursuant to this Agreement. (b) The Agent may cause any or all of the Collateral held by it to be transferred into the name of the Agent or the name or names of the Agent's nominee or nominees. (c) The Agent may exercise any and all of the rights and remedies of the Debtor under or in respect of the Collateral, including, without limitation, any and all rights of it to demand or otherwise require payment of any amount under, or performance of any provision of, any of the Collateral. (d) The Agent may collect or receive all money or property at any time payable or receivable on account of or in exchange for any of the Collateral, but shall be under no obligation to do so. (e) On any sale of the Collateral, the Agent is hereby authorized to comply with any limitation or restriction with which compliance is necessary, in the view of the Agent's counsel, in order to avoid any violation of applicable law or in order to obtain any required approval of the purchaser or purchasers by any applicable Governmental Authority.
Events of Default Rights and Remedies Section 7.1 Events of Default Section 7.2 Rights and Remedies Section 7.3 Certain Notices
Events of Default Rights and Remedies on Default 10.1 Events of Default 10.2 Acceleration of the Obligations
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Indemnification Obligations Net of Insurance Proceeds and Other Amounts (a) The Parties intend that any Liability subject to indemnification, contribution or reimbursement pursuant to this Article IV or Article V will be net of Insurance Proceeds or other amounts actually recovered (net of any out-of-pocket costs or expenses incurred in the collection thereof) from any Person by or on behalf of the Indemnitee in respect of any indemnifiable Liability. Accordingly, the amount which either Party (an “Indemnifying Party”) is required to pay to any Person entitled to indemnification or contribution hereunder (an “Indemnitee”) will be reduced by any Insurance Proceeds or other amounts actually recovered (net of any out-of-pocket costs or expenses incurred in the collection thereof) from any Person by or on behalf of the Indemnitee in respect of the related Liability. If an Indemnitee receives a payment (an “Indemnity Payment”) required by this Agreement from an Indemnifying Party in respect of any Liability and subsequently receives Insurance Proceeds or any other amounts in respect of such Liability, then within ten (10) calendar days of receipt of such Insurance Proceeds, the Indemnitee will pay to the Indemnifying Party an amount equal to the excess of the Indemnity Payment received over the amount of the Indemnity Payment that would have been due if the Insurance Proceeds or such other amounts (net of any out-of-pocket costs or expenses incurred in the collection thereof) had been received, realized or recovered before the Indemnity Payment was made. (b) The Parties agree that an insurer that would otherwise be obligated to pay any claim shall not be relieved of the responsibility with respect thereto or, solely by virtue of any provision contained in this Agreement or any Ancillary Agreement, have any subrogation rights with respect thereto, it being understood that no insurer or any other Third Party shall be entitled to a “windfall” (i.e., a benefit they would not be entitled to receive in the absence of the indemnification provisions) by virtue of the indemnification and contribution provisions hereof. Each Party shall, and shall cause the members of its Group to, use commercially reasonable efforts (taking into account the probability of success on the merits and the cost of expending such efforts, including attorneys’ fees and expenses) to collect or recover any Insurance Proceeds that may be collectible or recoverable respecting the Liabilities for which indemnification or contribution may be available under this Article IV. Notwithstanding the foregoing, an Indemnifying Party may not delay making any indemnification payment required under the terms of this Agreement, or otherwise satisfying any indemnification obligation, pending the outcome of any Action to collect or recover Insurance Proceeds, and an Indemnitee need not attempt to collect any Insurance Proceeds prior to making a claim for indemnification or contribution or receiving any Indemnity Payment otherwise owed to it under this Agreement or any Ancillary Agreement.
Default Remedies Substitute Collateral Section 5.1 METHOD OF REALIZING UPON THE PLEDGED PROPERTY: OTHER REMEDIES. If any Event of Default shall have occurred and be continuing: (a) The Secured Party may exercise in respect of the Pledged Property, in addition to any other rights and remedies provided for herein or otherwise available to it, all of the rights and remedies of a secured party upon default under the Uniform Commercial Code (whether or not the Uniform Commercial Code applies to the affected Pledged Property), and also may (i) take absolute control of the Pledged Property, including, without limitation, transfer into the Secured Party's name or into the name of its nominee or nominees (to the extent the Secured Party has not theretofore done so) and thereafter receive, for the benefit of the Secured Party, all payments made thereon, give all consents, waivers and ratifications in respect thereof and otherwise act with respect thereto as though it were the outright owner thereof, (ii) require the Company to assemble all or part of the Pledged Property as directed by the Secured Party and make it available to the Secured Party at a place or places to be designated by the Secured Party that is reasonably convenient to both parties, and the Secured Party may enter into and occupy any premises owned or leased by the Company where the Pledged Property or any part thereof is located or assembled for a reasonable period in order to effectuate the Secured Party's rights and remedies hereunder or under law, without obligation to the Company in respect of such occupation, and (iii) without notice except as specified below and without any obligation to prepare or process the Pledged Property for sale, (A) sell the Pledged Property or any part thereof in one or more parcels at public or private sale, at any of the Secured Party's offices or elsewhere, for cash, on credit or for future delivery, and at such price or prices and upon such other terms as the Secured Party may deem commercially reasonable and/or (B) lease, license or dispose of the Pledged Property or any part thereof upon such terms as the Secured Party may deem commercially reasonable. The Company agrees that, to the extent notice of sale or any other disposition of the Pledged Property shall be required by law, at least ten (10) days' notice to the Company of the time and place of any public sale or the time after which any private sale or other disposition of the Pledged Property is to be made shall constitute reasonable notification. The Secured Party shall not be obligated to make any sale or other disposition of any Pledged Property regardless of notice of sale having been given. The Secured Party may adjourn any public or private sale from time to time by announcement at the time and place fixed therefor, and such sale may, without further notice, be made at the time and place to which it was so adjourned. The Company hereby waives any claims against the Secured Party arising by reason of the fact that the price at which the Pledged Property may have been sold at a private sale was less than the price which might have been obtained at a public sale or was less than the aggregate amount of the Obligations, even if the Secured Party accepts the first offer received and does not offer such Pledged Property to more than one offeree, and waives all rights that the Company may have to require that all or any part of such Pledged Property be marshaled upon any sale (public or private) thereof. The Company hereby acknowledges that (i) any such sale of the Pledged Property by the Secured Party may be made without warranty, (ii) the Secured Party may specifically disclaim any warranties of title, possession, quiet enjoyment or the like, and (iii) such actions set forth in clauses (i) and (ii) above shall not adversely affect the commercial reasonableness of any such sale of Pledged Property. (b) Any cash held by the Secured Party as Pledged Property and all cash proceeds received by the Secured Party in respect of any sale of or collection from, or other realization upon, all or any part of the Pledged Property shall be applied (after payment of any amounts payable to the Secured Party pursuant to Section 8.3 hereof) by the Secured Party against, all or any part of the Obligations in such order as the Secured Party shall elect, consistent with the provisions of the Securities Purchase Agreement. Any surplus of such cash or cash proceeds held by the Secured Party and remaining after the indefeasible payment in full in cash of all of the Obligations shall be paid over to whomsoever shall be lawfully entitled to receive the same or as a court of competent jurisdiction shall direct. (c) In the event that the proceeds of any such sale, collection or realization are insufficient to pay all amounts to which the Secured Party is legally entitled, the Company shall be liable for the deficiency, together with interest thereon at the rate specified in the Convertible Debentures for interest on overdue principal thereof or such other rate as shall be fixed by applicable law, together with the costs of collection and the reasonable fees, costs, expenses and other client charges of any attorneys employed by the Secured Party to collect such deficiency. (d) The Company hereby acknowledges that if the Secured Party complies with any applicable state, provincial, or federal law requirements in connection with a disposition of the Pledged Property, such compliance will not adversely affect the commercial reasonableness of any sale or other disposition of the Pledged Property. (e) The Secured Party shall not be required to marshal any present or future collateral security (including, but not limited to, this Agreement and the Pledged Property) for, or other assurances of payment of, the Obligations or any of them or to resort to such collateral security or other assurances of payment in any particular order, and all of the Secured Party's rights hereunder and in respect of such collateral security and other assurances of payment shall be cumulative and in addition to all other rights, however existing or arising. To the extent that the Company lawfully may, the Company hereby agrees that it will not invoke any law relating to the marshaling of collateral which might cause delay in or impede the enforcement of the Secured Party's rights under this Agreement or under any other instrument creating or evidencing any of the Obligations or under which any of the Obligations is outstanding or by which any of the Obligations is secured or payment thereof is otherwise assured, and, to the extent that it lawfully may, the Company hereby irrevocably waives the benefits of all such laws.
The Lender Groups Rights and Remedies 9.1 Rights and Remedies. 9.2 Remedies Cumulative.
Powers and Remedies Cumulative; Delay or Omission Not Waiver of Default Except as provided in Section 5.6, no right or remedy herein conferred upon or reserved to the Trustee or to the Holders of Securities or Coupons is intended to be exclusive of any other right or remedy, and every right and remedy shall, to the extent permitted by law, be cumulative and in addition to every other right and remedy given hereunder or now or hereafter existing at law or in equity or otherwise. The assertion or employment of any right or remedy hereunder, or otherwise, shall not prevent the concurrent assertion or employment of any other appropriate right or remedy. No delay or omission of the Trustee or of any Holder of Securities or Coupons to exercise any right or power accruing upon any Event of Default occurring and continuing as aforesaid shall impair any such right or power or shall be construed to be a waiver of any such Event of Default or an acquiescence therein; and, subject to Section 5.6, every power and remedy given by this Indenture or by law to the Trustee or to the Holders of Securities or Coupons may be exercised from time to time, and as often as shall be deemed expedient, by the Trustee or by the Holders of Securities or Coupons.