Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
Operation of the Business Except as set forth on Section 10.1 of the Sentech Disclosure Schedule, as contemplated by this Agreement or as expressly agreed to in writing by Sensec and Ensec, during the period from the date of this Agreement to the Effective Time, Sentech and its Subsidiaries will conduct their operations only in the ordinary course of business consistent with sound financial, operational and regulatory practice, and will take no action which would materially adversely affect their ability to consummate the Transactions. Without limiting the generality of the foregoing, except as otherwise expressly provided in this Agreement or except as disclosed in the Sentech Disclosure Schedule, prior to the Effective Time, neither Sentech nor any of its Subsidiaries will, without the prior written consent of Sensec and Ensec:
(a) amend its Charter Documents or bylaws (or similar organizational documents);
(b) authorize for issuance, issue, sell, deliver, grant any options for, or otherwise agree or commit to issue, sell or deliver any shares of its capital stock or any other securities, other than pursuant to and in accordance with the terms of any Existing Options or Sentech Warrants listed on the Sentech Disclosure Schedule;
(c) recapitalize, split, combine or reclassify any shares of its capital stock; declare, set aside or pay any dividend or other distribution (whether in cash, stock or property or any combination thereof) in respect of its capital stock; or purchase, redeem or otherwise acquire any of its or its Subsidiaries' securities or modify any of the terms of any such securities;
(d) (i) create, incur, assume or permit to exist any long-term debt or any short-term debt for borrowed money other than under existing notes payable, lines of credit or other credit facilities or in the ordinary course of business, or with respect to its Wholly-Owned Subsidiaries in the ordinary course of business; (ii) assume, guarantee, endorse or otherwise become liable or responsible (whether directly, contingently or otherwise) for the obligations of any other Person except its Wholly-Owned Subsidiaries in the ordinary course of business or as otherwise may be contractually required and disclosed in the Sentech Disclosure Schedule; or (iii) make any loans, advances or capital contributions to, or investments in, any other Person except its Wholly-Owned Subsidiaries;
(i) amend any Sentech Benefit Plan or (ii) except in the ordinary course of business consistent with usual practice or established policy (a) increase in any manner the rate of compensation of any of its directors, officers or other employees everywhere, except for increases in the ordinary course of business; (b) pay or agree to pay any bonus, pension, retirement allowance, severance or other employee benefit except as required under currently existing Sentech Benefit Plans disclosed in the Sentech Disclosure Schedule or in the ordinary course of business; or (c) amend, terminate or enter into any employment, consulting, severance, change in control or similar agreements or arrangements with any of its directors, officers or other employees;
(f) enter into any material agreement, commitment or contract, except agreements, commitments or contracts for the purchase, sale or lease of goods or services in the ordinary course of business;
(g) other than in the ordinary course of business, authorize, recommend, propose or announce an intention to authorize, recommend or propose, or enter into any Contract with respect to, any (i) plan of liquidation or dissolution, (ii) acquisition of a material amount of assets or securities, (iii) disposition or Encumbrance of a material amount of assets or securities, (iv) merger or consolidation or (v) material change in its capitalization;
(h) change any material accounting or Tax procedure or practice;
(i) take any action the taking of which, or knowingly omit to take any action the omission of which, would cause any of the representations and warranties herein to fail to be true and correct in all material respects as of the date of such action or omission as though made at and as of the date of such action or omission;
(j) compromise, settle or otherwise modify any material claim or litigation not identified in the Sentech Disclosure Schedule; or
(k) commit or agree to do any of the foregoing.
Operation and Use So long as the Aircraft, Airframe or any Engine is subject to the Lien of this Trust Indenture, the Owner shall not operate, use or locate the Aircraft, Airframe or any Engine, or allow the Aircraft, Airframe or any Engine to be operated, used or located, (i) in any area excluded from coverage by any insurance required by the terms of Section 4.06, except in the case of a requisition by the U.S. Government where the Owner obtains indemnity in lieu of such insurance from the U.S. Government, or insurance from the U.S. Government, against substantially the same risks and for at least the amounts of the insurance required by Section 4.06 covering such area, or (ii) in any recognized area of hostilities unless covered in accordance with Section 4.06 by war risk insurance, or in either case unless the Aircraft, the Airframe or any Engine is only temporarily operated, used or located in such area as a result of an emergency, equipment malfunction, navigational error, hijacking, weather condition or other similar unforeseen circumstance, so long as Owner diligently and in good faith proceeds to remove the Aircraft from such area. So long as the Aircraft, the Airframe or any Engine is subject to the Lien of this Trust Indenture, the Owner shall not permit such Aircraft, Airframe or any Engine, as the case may be, to be used, operated, maintained, serviced, repaired or overhauled (x) in violation of any Law binding on or applicable to such Aircraft, Airframe or Engine or (y) in violation of any airworthiness certificate, license or registration of any Government Entity relating to the Aircraft, the Airframe or any Engine, except (i) immaterial or non-recurring violations with respect to which corrective measures are taken promptly by Owner or Permitted Lessee, as the case may be, upon discovery thereof, or (ii) to the extent the validity or application of any such Law or requirement relating to any such certificate, license or registration is being contested in good faith by Owner or Permitted Lessee in any reasonable manner which does not involve any material risk of the sale, forfeiture or loss of the Aircraft, Airframe or any Engine, any material risk of criminal liability or material civil penalty against Mortgagee or impair the Mortgagee's security interest in the Aircraft, Airframe or any Engine.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Condition of the Business (a) Notwithstanding anything contained in this Agreement to the contrary, Purchaser acknowledges and agrees that Seller is not making any representations or warranties whatsoever, express or implied, beyond those expressly given by Seller in Article V hereof (as modified by the Seller Schedules as supplemented or amended), and Purchaser acknowledges and agrees that, except for the representations and warranties contained therein, the Purchased Assets and the Business are being transferred on a “where is” and, as to condition, “as is” basis. Any claims Purchaser may have for breach of representation or warranty shall be based solely on the representations and warranties of Seller set forth in Article V hereof (as modified by the Seller Schedules as supplemented or amended). Purchaser further represents that neither Seller nor any of its Affiliates nor any other Person has made any representation or warranty, express or implied, regarding Seller, the Purchased Assets, the Business or the transactions contemplated by this Agreement or as to the accuracy or completeness of any information not expressly set forth in this Agreement and neither Purchaser nor any of its Affiliates has relied on any such express or implied representation or warranty. Purchaser further agrees that none of Seller, any of its Affiliates or any other Person will have or be subject to any liability to Purchaser or any other Person resulting from the distribution to Purchaser or its representatives or Purchaser’s use of, any such information, including any confidential memoranda distributed on behalf of Seller relating to the Business or other publications or data room information provided to Purchaser or its representatives, or any other document or information in any form provided to Purchaser or its representatives in connection with the sale of the Business and the transactions contemplated hereby. Purchaser acknowledges that it has conducted to its satisfaction, its own independent investigation of the Business and, in making the determination to proceed with the transactions contemplated by this Agreement, Purchaser has relied on the results of its own independent investigation.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
Operation of the Company’s Business (a) During the Pre-Closing Period:
(i) the Company shall ensure that each of the Company Entities conducts its business and operations: (A) in the ordinary course and in accordance with past practices; and (B) in material compliance with all applicable Laws and with the requirements of all Contracts of Company Entities that constitute Material Contracts;
(ii) the Company shall use commercially reasonable efforts to ensure that each of the Company Entities preserves intact its current business organization, keeps available the services of its current officers and other key employees and maintains its relations and goodwill with all suppliers, customers, landlords, creditors, licensors, licensees, distributors, resellers, employees and other Persons having material business relationships with the respective Company Entities;
(iii) the Company shall promptly notify Parent in writing of (A) any notice from any Person alleging that the Consent of such Person is or may be required in connection with any of the Transactions and (B) any Legal Proceeding commenced, or, to the Knowledge of the Company, threatened against, relating to, involving or otherwise affecting any of the Company Entities that relates to the Merger or any of the other Transactions;
(iv) use commercially reasonable efforts to keep in full force all insurance policies referred to in Section 3.26 (other than any such policies that are immediately replaced with substantially similar policies), provided that if it is unable to do so, it shall notify Parent at least 20 days before such policies terminate or otherwise lapse; and
(v) the Company shall (to the extent requested by Parent and permitted under applicable Law) cause the officers and other key employees of the Company Entities to freely communicate (without limitation) with Parent regarding the Company Entities’ results of operations and material developments.
(b) Without limiting the generality of the foregoing, during the Pre-Closing Period, except as set forth in Schedule 5.2(b) or with Parent’s prior written consent and except as permitted by Section 6.2(d), the Company (A) shall not, and (B) shall not permit any of the other Company Entities to:
(i) amend its certificate of incorporation or bylaws or comparable organizational documents or create any new Subsidiaries;
(ii) issue, sell, deliver or agree or commit to issue, sell or deliver (whether through the issuance or granting of options, warrants, commitments, subscriptions, rights to purchase or otherwise) any security of any Company Entity, except for the issuance and sale of shares of Company Common Stock pursuant to Company Equity Awards outstanding as of the date of this Agreement upon the exercise or vesting thereof, as applicable;
(iii) directly or indirectly acquire, repurchase or redeem any security of any Company Entity, except in connection with Tax withholdings and exercise price settlements upon the exercise, vesting or issuance of shares under Company Equity Awards;
(iv) (A) split, combine, subdivide or reclassify any shares of capital stock, or (B) declare, set aside or pay any dividend or other distribution (whether in cash, shares or property or any combination thereof) in respect of any shares of capital stock, or make any other actual, constructive or deemed distribution in respect of the shares of capital stock, except for cash dividends made by any direct or indirect wholly-owned Subsidiary of the Company to the Company or one of its wholly-owned Subsidiaries;
(v) propose or adopt a plan of complete or partial liquidation, dissolution, merger, consolidation, restructuring, recapitalization or other reorganization of any Company Entity, except for this Agreement and the Transactions;
(vi) (A) redeem, repurchase, prepay, defease, cancel, incur, create, assume or otherwise acquire or modify in any material respect any long-term or short-term debt for borrowed monies or issue or sell any debt securities or calls, options, warrants or other rights to acquire any debt securities of any Company Entity or enter into any agreement having the economic effect of any of the foregoing, except for (1) debt incurred in the ordinary course of business under letters of credit, lines of credit or other credit facilities or arrangements in effect on the date hereof, (2) loans or advances between the Company and any direct or indirect Subsidiaries, or between any direct or indirect Subsidiaries of the Company in the ordinary course of business consistent with past practices, and (3) the issuance of credit to new customers for the purchase of products or services of the Company Entities in the ordinary course of business consistent with past practices, (B) assume, guarantee, endorse or otherwise become liable or responsible (whether directly, contingently or otherwise) for the obligations of any other Person, except with respect to obligations of direct or indirect wholly-owned Subsidiaries of the Company in place on the date of this Agreement, (C) make any loans, advances (other than any retainer for legal services) or capital contributions to or investments in any other Person (other than the Company or any direct or indirect wholly-owned Subsidiaries), except for travel advances or business expenses in the ordinary course of business consistent with past practice to employees of the Company Entities, or (D) mortgage or pledge any asset owned or used by any Company Entity, or create or suffer to exist any Encumbrance thereupon (other than Permitted Encumbrances), except pursuant to the terms of any letters of credit, lines of credit or other credit facilities or arrangements, in effect on the date hereof;
(vii) except as may be required by applicable Law or the terms of this Agreement or of any Company Employee Plan as in effect on the date of this Agreement, (A) enter into, adopt, amend (including acceleration of vesting), modify or terminate any bonus, profit sharing, incentive, compensation, severance, retention, termination, option, appreciation right, performance unit, stock equivalent, share purchase agreement, pension, retirement, deferred compensation, employment, change in control, pension, retirement, collective bargaining or other employee benefit agreement, trust, plan, fund or other arrangement for the compensation, benefit or welfare of any Company Associate, (B) increase the compensation payable or to become payable to any Company Associate, pay or agree to pay any special bonus or special remuneration to any Company Associate, or pay or agree to pay any benefit not required by any Company Employee Plan as in effect as of the date hereof, except in the ordinary course of business consistent with past practice with respect to any Company Associate who is not a member of the board of directors or officer, (C) hire any employee with an annual base salary in excess of $100,000 or at the level of Vice President, (D) grant or pay any severance or termination pay to (or amend any such existing arrangement with) any current or former member of the board of directors, officer, employee or independent contractor of any Company Entity, except in the ordinary course of business with respect to any employee or independent contractor who is not a member of the board of directors or officer, (E) increase benefits payable under any existing severance or termination pay policies or similar employment agreements, or (F) accelerate the vesting or payment of, or fund or in any other way secure the payment, compensation or benefits under, any Company Employee Plan to the extent not required by the terms of this Agreement or such Company Employee Plan as in effect on the date of this Agreement;
(viii) commence any Legal Proceeding or settle any pending or threatened Legal Proceeding, except for the settlement of any Legal Proceeding solely for money damages not in excess of $250,000 in the aggregate and as would not be reasonably likely to have any adverse impact on any other Legal Proceeding;
(ix) except as may be required as a result of a change in applicable Law or in GAAP, make any material change in any of the accounting methods, principles or practices used by it or change an annual accounting period;
(x) (A) make or change any material Tax election, (B) settle or compromise any material federal, state, local or foreign income Tax liability, (C) consent to any extension or waiver of any limitation period with respect to any claim or assessment for material Taxes, (D) change any annual Tax accounting period or method of Tax accounting, (E) file any materially amended Tax Return, (F) enter into any closing agreement with respect to any Tax or (G) surrender any right to claim a material Tax refund;
(xi) (A) acquire (by merger, consolidation or acquisition of stock or assets or otherwise) any other Entity or any material equity interest therein, (B) sell or otherwise dispose of, lease or license any properties or assets of any Company Entity (other than in the ordinary course of business), which are material to the Company Entities, taken as a whole, (C) acquire, lease or license any material right or other asset from any Person (other than in the ordinary course of business consistent with past practice);
(xii) make any capital expenditures in excess of $50,000 individually or $200,000 in the aggregate;
(xiii) make any material changes or modifications to any investment or risk management policy or other similar policies (including with respect to hedging), or any cash management policy;
(xiv) other than in the ordinary course of business, enter into, or amend in any material respect, terminate or fail to renew, any Material Contract;
(xv) change any of its product return policies, product maintenance polices, service policies, product modification or upgrade policies in any material respect;
(xvi) enter into any material transaction with any of its Affiliates (other than a Company Entity) other than pursuant to written arrangements in effect on the date of this Agreement and excluding any employment, compensation or similar arrangements otherwise expressly permitted pursuant to this Section 5.2(b);
(xvii) abandon or permit to lapse any right to any material patent or patent application;
(xviii) take any action that is intended or is reasonably likely to result in the conditions set forth in Sections 7.1, 7.2, 7.3 (except after compliance with Section 6.2(d)), 7.5, 7.7, 7.11, 7.12, 7.13, 7.15 and 7.16 not being satisfied; or
(xix) agree or commit to take any of the actions described in clauses above in this Section 5.2(b).
(c) During the Pre-Closing Period, the Company shall promptly notify Parent in writing of any event, condition, fact or circumstance that would make the timely satisfaction of any of the conditions set forth in ARTICLE 7 impossible or unlikely or that has had or could reasonably be expected to have or result in a Material Adverse Effect. Without limiting the generality of the foregoing, the Company shall promptly advise Parent in writing of any Legal Proceeding or material claim commenced or, to the Company’s Knowledge, threatened against or with respect to any of the Company Entities. No notification given to Parent pursuant to this Section 5.2(c) or any information or knowledge obtained pursuant to Section 5.1 shall limit or otherwise affect any of the representations, warranties, covenants or obligations of the Company contained in this Agreement or any of the remedies available to Parent under this Agreement.
(d) During the Pre-Closing Period, the Company shall promptly notify Parent in writing if the Company has the right to exercise any right or option to repurchase shares of its capital stock from any Company Associate or other Person upon termination of such Person’s service to any of the Company Entities. The Company shall not exercise any such repurchase right except to the extent directed by Parent in writing.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
Operation of the Agreement The Parties recognize that it is impractical in this Agreement to provide for every contingency which may arise during the life of the Agreement, and the Parties hereby agree that it is their intention that this Agreement shall operate fairly as between them, and without detriment to the interest of either of them, and that, if during the term of this Agreement either Party believes that this Agreement is operating unfairly, the Parties will use their best efforts to agree on such action as may be necessary to remove the cause or causes of such unfairness, but failure to agree on any action pursuant to this Clause 8.2 shall not give rise to a dispute subject to arbitration in accordance with Clause 9 hereof.
Execution of the Project (a) The Recipient declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project through its MoE with due diligence and efficiency and in conformity with appropriate financial, economic, environmental and administrative practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project.
(b) Without limitation upon the provisions of paragraph (a) of this Section and except as the Recipient and the Association shall otherwise agree, the Recipient shall carry out the Project in accordance with the Implementation Program set forth in Schedule 4 to this Agreement.
(a) Except as the Association shall otherwise agree, procurement of the goods, works and consultants’ services required for the Project and to be financed out of the proceeds of the Grant shall be governed by the provisions of Schedule 3 to this Agreement, as said provisions may be further elaborated in the Procurement Plan.
(b) The Recipient shall update the Procurement Plan in accordance with terms of reference acceptable to the Association, and furnish such update to the Association not later than twelve (12) months after the date of the preceding Procurement Plan, for the Association’s approval.
Section 3.03. Without limitation upon any of its obligations under paragraph (a) of Section 3.01 of this Agreement and except as the Recipient and the Association shall otherwise agree, the Recipient shall: (i) not later than by the effectiveness of this Agreement open a separate project account (the Project Account) in a commercial bank acceptable to the Association; (ii) thereafter maintain the Project Account during the entire Project implementation period, and replenish said Account regularly with funds sufficient to ensure the Recipient’s Project co-financing obligations; and (iii) use the amount in the Project Account exclusively for financing the Recipient’s contribution to Project expenditures.
Section 3.04. For the purposes of Section 6.09 of the General Conditions and without limitation thereto, the Recipient shall:
(a) prepare, on the basis of guidelines acceptable to the Association, and furnish to the Association not later than six (6) months after the Closing Date or such later date as may be agreed for this purpose between the Recipient and the Association, a plan designed to ensure the continued achievement of the Project’s objectives; and
(b) afford the Association a reasonable opportunity to exchange views with the Recipient on said plan.
