Payments to the Developer Sample Clauses

Payments to the Developer. In consideration for its work, the Developer will receive a combination of milestone payments during the construction period and monthly performance payments (availability payments) during the operating period. An illustrative example of when milestone payments and performance payments will be paid is provided in the figure below, with further detail following (actual timing of the milestone payments in the graphic below will depend on the Developer’s schedule). $50m $95m $52m $52m Financial Close Substantial Completion Date End of Concession Construction period 30-year operations period post achievement of Substantial Completion Milestone Payments: there are five milestone events, each defined by a specific scope of work, for which the Developer is entitled to compensation upon completion. Schedule 5: Milestone Payments includes a table that specifies the timing for when funding is available for the milestones. The milestone events for the Project are as set forth below. Note that the amounts to be paid for each milestone represent less than the estimated cost of the work to complete each milestone. Event Milestone Payment KMP Target Completion Date1 Milestone 1 - Sand Creek Bridge to Xxxxxxxx Road $50,000,000 November 18, 2019 Milestone 2 - Dahlia Street to Sand Creek Bridge $95,000,000 October 20, 2020 Milestone 3 - WB I-00 Xxxxxxxx Xxxxxxxxx to Dahlia Street $52,000,000 September 26, 2020 Milestone 4 - EB I-00 Xxxxxxxx Xxxxxxxxx to Dahlia Street $52,000,000 September 5, 2021 Milestone 5 - Substantial Completion $70,000,000 March 4, 2022 1 Each such date will be modified on a day for day basis to reflect any delay in achieving financial close relative to November 30, 2017 (the date assumed in the Instructions to Proposers) during construction to fund the Project (the “CPP”), which will amount to 80% of the total performance payment. The OMRP will escalate each year at the Consumer Price Index and the CPP will escalate at a fixed 2% rate per year. Toll revenues will be collected and retained by HPTE and, together with annual payments to be made by the City and County of Denver pursuant to the Intergovernmental Agreement entered into effective September 14, 2015, will be available to contribute toward payment of the OMRP. Unlike on the US36 Managed Lanes Project, where the Concessionaire bears the toll revenue risk, HPTE and CDOT will be responsible for payment of the OMRP irrespective of toll revenue collections, in accordance with the previously approve...
AutoNDA by SimpleDocs
Payments to the Developer. The Developer may request in writing a payment of the Purchase Price of any Facility or Discrete Component thereof as described in Exhibit A hereto subject to the following:
Payments to the Developer. In recognition of the Developer’s obligations set out above, the City agrees to make forty (40) semiannual economic development tax increment payments (the “Payments”) to the Developer during the Term, as hereinafter defined, pursuant to Chapters 15A and 403 of the Code of Iowa, provided however that the aggregate, total amount of the Payments (the “Maximum Aggregate Payments”) shall not exceed the lesser of (i) 1,087,000, or (ii) the aggregate amount of interest to be incurred by the Developer in financing the Non-Rise Eligible Costs as set forth on Exhibit D hereto, and all Payments under this Agreement shall be subject to annual appropriation by the City Council, as provided hereunder. The Payments shall not constitute general obligations of the City, but shall be made solely and only from Incremental Property Tax Revenues received by the City from the Xxxxxxx County Treasurer attributable to the taxable valuation of the Property. Each Payment shall not exceed an amount which represents 80% (the “Annual Percentage”) of the Incremental Property Tax Revenues available to the City with respect to the Property during the six (6) months immediately preceding each Payment date. It is assumed that the new valuation from the Project will go on the tax rolls as of January 1, 2016. Accordingly, the Payments will be made on December 1 and June 1 of each fiscal year, beginning on December 1, 2017 and continuing to, and including, June 1, 2037, or until such earlier date upon which total Payments equal to the Maximum Aggregate Payments have been made.
Payments to the Developer. The City agrees to pay to or for the account of the Developer the Developer Payments in accordance with the terms of this Agreement, upon the satisfaction of the conditions of Section 1.4 herein with respect to the Developer Improvements, the actual costs of the Developer Improvements incurred by the Developer and eligible for reimbursement as provided in this Agreement (with the costs collectively referred to herein as the "Costs"). Subject to the City receiving Available Funds and the Developer's compliance with the terms and conditions of this Agreement, the City shall pay all Available Funds to the Developer on or before the first business day following each June 15 and December 15 (each, a "Payment Date") until the Costs have been paid in full. Payments for the Costs of the Developer Improvements will be made beginning with the first Payment Date following the satisfaction of the conditions of Section 1.4. For purposes of this Agreement, "Costs" of the Developer Improvements includable in Costs include all costs incurred by the Developer, directly or indirectly, with respect to the Developer Improvements (exclusive of interest charges). These reimbursable "costs" of the Developer Improvements include, but are not limited to, costs associated with any warranties, 3 inspection and design review fees, permit fees and legal expenses incurred in connection with this Agreement. All payments to the Developer hereunder on each Payment Date must be made pursuant to written instructions provided by the Developer, or by Developer's lender(s) and any governmental entity participating through the issuance of bonds (including the Development Finance Authority of Summit County) in connection with the Developer's Improvements on the TIF Site. The City's payment obligations hereunder are limited to Available Funds and do not constitute an indebtedness of the City within the provisions and limitations of the laws and the Constitution of the State of Ohio, and the Developer does not have the right to have taxes or excises levied by the City for the payment of the Costs. The Developer hereby acknowledges and agrees that the Developer and the City currently estimate that the aggregate amount deposited to the TIF Fund during all Exemption Years will be insufficient to provide Available Funds to reimburse the Developer for all Costs of the Developer Improvements incurred by the Developer. The Developer and the City agree that title to the Developer Improvements shall at all...

Related to Payments to the Developer

  • Payments to the Distributor In consideration of the payments made by the Fund to the Distributor under this Plan, the Distributor shall provide administrative support services and distribution assistance services to the Fund. Such services include distribution assistance and administrative support services rendered in connection with Shares (1) sold in purchase transactions, (2) issued in exchange for shares of another investment company for which the Distributor serves as distributor or sub-distributor, or (3) issued pursuant to a plan of reorganization to which the Fund is a party. If the Board believes that the Distributor may not be rendering appropriate distribution assistance or administrative support services in connection with the sale of Shares, then the Distributor, at the request of the Board, shall provide the Board with a written report or other information to verify that the Distributor is providing appropriate services in this regard. For such services, the Fund will make the following payments to the Distributor:

  • Payments to the Company Except as provided in Section 3 hereof, after the Trust has become irrevocable, the Company shall have no right or power to direct the Trustee to return to the Company or to divert to others any of the Trust assets before all payments of benefits have been made to Plan participants and their beneficiaries pursuant to the terms of the Plans.

  • Payments to the Owner Allstate Life shall withdraw from the Funding Account and pay to or at the direction of the Owner amounts in accordance with the terms set forth in the Annex hereto. All payments made by Allstate Life to the Owner hereunder shall be paid in cash, in same-day, freely transferable funds on the date of payment to such account as has been specified for such purpose in writing by the Owner to Allstate Life.

  • Payments to Owner Section 4.01 Remittances...................................................29 Section 4.02 Statements to Owner...........................................29 Section 4.03 Monthly Advances by Servicer..................................30 Section 4.04 Due Dates Other Than the First of the Month...................30 ARTICLE V

  • PAYMENTS TO PURCHASER 52 ARTICLE VI....................................................................54

  • Payments to the Agent (a) On each date on which an Obligor or a Lender is required to make a payment under a Finance Document, that Obligor or Lender shall make the same available to the Agent (unless a contrary indication appears in a Finance Document) for value on the due date at the time and in such funds specified by the Agent as being customary at the time for settlement of transactions in the relevant currency in the place of payment. (b) Payment shall be made to such account in the principal financial centre of the country of that currency with such bank as the Agent specifies.

  • Payments to Recipients The Distributor is authorized under the Plan to pay Recipients (1) distribution assistance fees for rendering distribution assistance in connection with the sale of Shares and/or (2) service fees for rendering administrative support services with respect to Accounts. However, no such payments shall be made to any Recipient for any period in which its Qualified Holdings do not equal or exceed, at the end of such period, the minimum amount (“Minimum Qualified Holdings”), if any, that may be set from time to time by a majority of the Independent Trustees. All fee payments made by the Distributor hereunder are subject to reduction or chargeback so that the aggregate service fee payments and Advance Service Fee Payments do not exceed the limits on payments to Recipients that are, or may be, imposed by the FINRA Rules. The Distributor may make Plan payments to any “affiliated person” (as defined in the 0000 Xxx) of the Distributor if such affiliated person qualifies as a Recipient or retain such payments if the Distributor qualifies as a Recipient.

  • Payments to Third Parties Xxxxxxx agrees that Grantor shall have no liability to Grantee when Grantor acts in good faith to redirect all or a portion of any Grantee payment to a third party. Grantor will be deemed to have acted in good faith when it is in possession of information that indicates Grantee authorized Grantor to intercept or redirect payments to a third party or when so ordered by a court of competent jurisdiction.

  • Payments for Distribution Assistance and Administrative Support Services (a) Payments to the Distributor. In consideration of the payments made by the Fund to the Distributor under this Plan, the Distributor shall provide administrative support services and distribution services to the Fund. Such services include distribution assistance and administrative support services rendered in connection with Shares (1) sold in purchase transactions, (2) issued in exchange for shares of another investment company for which the Distributor serves as distributor or sub-distributor, or (3) issued pursuant to a plan of reorganization to which the Fund is a party. If the Board believes that the Distributor may not be rendering appropriate distribution assistance or administrative support services in connection with the sale of Shares, then the Distributor, at the request of the Board, shall provide the Board with a written report or other information to verify that the Distributor is providing appropriate services in this regard. For such services, the Fund will make the following payments to the Distributor:

  • Payments to Company Except as provided in Section 3 hereof, after the Trust has become irrevocable, Company shall have no right or power to direct Trustee to return to Company or to divert to others any of the Trust assets before all payment of benefits have been made to Plan participants and their beneficiaries pursuant to the terms of the Plan.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!