Preliminary Plans / Schematic Design Phase Sample Clauses

Preliminary Plans / Schematic Design Phase. The Services that shall be provided in the Preliminary Plans / Schematic Design Phase consist of the following: 1. Assist the Judicial Council in confirming the programming requirements based on discussions with the client representatives from the Court and the Judicial Council. The Architect shall prepare room data sheets for each space that indicate the dimensions; furniture and fixture configuration; and acoustical, HVAC, electrical, communications, and data requirements and standards. The room data sheets are to be maintained and updated through succeeding design phases by the Architect/ Engineer. 2. Provide assistance for the CEQA process to be performed by the State or the Judicial Council, such as surveying of the Project site as necessary to provide a legal description, plotting title exceptions, attending public meetings to describe and clarify proposed design, and responding to public comments on design related issues. 3. Include Energy Efficiency and Sustainable Building Measures in the design whenever possible and economically feasible. The Architect shall make recommendations and provide analysis to the Judicial Council for cost and feasibility of implementation of Energy Efficiency Measures and Sustainability Measures, within the approved Design Budget. 4. Provide a code analysis indicating how the design of the Project complies with applicable building codes, including California Code of Regulations, Title 24. 5. Prepare for the Judicial Council’s review Schematic Design studies incorporating the Project requirements and including structure and site utilization plans, floor plans, elevations, sections, perspectives, and other documents necessary to illustrate the scale and relationship of Project components. Building designs shall pay particular attention to orientation, solar consideration and passive energy techniques and shall conform to applicable energy regulations. Schematic Design studies shall be revised until a design concept has been accepted and approved by the Judicial Council. 6. Prepare for the Judicial Council’s review: (a) Outline Specifications indicating Architectural, structural, civil, mechanical, electrical, and other systems and materials proposed; (b) mounted presentation drawings and study perspectives of the Project and other graphic material necessary to convey the concept of the Architectural design; (c) a detailed room-by- room tabulation of all net assignable Floor Areas, and a summary of the gross Floor Area; (d...
Sample 1See All (5)
AutoNDA by SimpleDocs
Preliminary Plans / Schematic Design Phase is the first, preliminary Phase of design (also the first Phase of “Preliminary Plans”) in which the conceptual layout, bulk, massing and quantitative and qualitative building is identified and finalized.
Sample 1Sample 2
Preliminary Plans / Schematic Design Phase. 2.5.1. Estimated start date: May 25, 2017 2.5.2. Estimated completion date: July 30, 2017
Sample 1

Related to Preliminary Plans / Schematic Design Phase

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Plans and Specifications After Landlord receives and approves Tenant’s Space Plan as provided above, Tenant will cause Tenant’s Architect to prepare the Plans and Specifications for the Tenant Improvements. Landlord will approve or disapprove (specifically describing any reasons for disapproval) the Plans and Specifications in writing within ten (10) Business Days after receiving them. If Landlord disapproves the Plans and Specifications, Tenant will provide appropriately revised Plans and Specifications to Landlord for approval (or disapproval) within five (5) Business Days on the same basis as set forth above. After Landlord’s approval, Tenant will submit the Plans and Specifications for permits and construction bids. No deviation from the Building Standard will be permitted in the Space Plan or the Plans and Specifications, provided reasonable deviations with respect to the ceiling, lighting, painting, flooring and wall covering may be permitted with Landlord’s approval. Landlord will not approve any deviations which Landlord believes (a) do not conform to applicable codes, ordinances and other Laws or are disapproved by any governmental agency, (b) require services beyond the level normally provided to other tenants in the Building, or (c) are of a nature or quality that are inconsistent with Landlord’s overall plan or objectives for the Building. No approval by Landlord of any deviation constitutes an acknowledgment by Landlord that such deviations are in conformance with applicable codes, ordinances and other Laws. In the event that Landlord’s approval shall be required in this Tenant Improvements Agreement, then notwithstanding anything to the contrary set forth in the Lease, Landlord’s approval shall not be unreasonably withheld, conditioned, or delayed.

  • Site Plan It is Licensee’s responsibility before signing this Agreement to ensure that the Site Plan correctly shows the work that Licensee intends to perform, that the Site Plan correctly shows all improvements and equipment that Licensee intends be located on the Use Areas, that the Site Plan shows no work, improvements or equipment outside the Exclusive Areas and Shared Areas properly depicted and labeled on the Boundary Plan, and that all work, improvements and equipment is encompassed within the purposes enumerated in the Standard Terms for that particular Exclusive Area or Shared Area. Any work, improvements or equipment not conforming to all the foregoing is prohibited, even if it is clearly shown on the Site Plan or discussed in the Standard Terms. Any refinement or other change to the Site Plan after Licensor executes this Agreement is void unless Licensee obtains Licensee’s approval of the change pursuant to the plans approval processes set out in the Standard Terms and pursuant to all applicable regulatory requirements.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!