Rent Abatement Except for the negligence or willful act of Tenant or its agents, employees, contractors or invitees, if all or any part of the Premises are rendered untenantable by fire or other casualty and this Lease is not terminated, Monthly Base Rent and Rent Adjustments shall xxxxx for that part of the Premises which is untenantable on a per diem basis from the date of the casualty until Landlord has Substantially Completed the repair and restoration work in the Premises which it is required to perform, provided, that as a result of such casualty, Tenant does not occupy the portion of the Premises which is untenantable during such period.
Base Rent Abatement Provided that Tenant is not then in Default, and subject to the terms of this Section 3.2 below, then (i) during the last six (6) full calendar months of the Lease Term with respect to the Phase I Premises and (ii) during the last ten (10) full calendar months of the Lease Term with respect to the Phase II Premises (collectively, the “Base Rent Abatement Period”), Tenant shall not be obligated to pay any Base Rent otherwise attributable to the Premises or the Phase II Premises, as applicable, during such Base Rent Abatement Period (collectively, the “Rent Abatement Amount”). Tenant acknowledges and agrees that the foregoing Base Rent Abatement has been granted to Tenant as additional consideration for entering into this Lease, and for agreeing to pay the rental and perform the terms and conditions otherwise required under this Lease. Notwithstanding the foregoing, Landlord shall have the right, at Landlord’s option, on a month by month basis commencing on the Lease Commencement Date, to accelerate any remaining Base Rent Abatement Amount relating to a full month during the Base Rent Abatement Period for a particular phase of the Premises (the “Phase”) forward, to apply to the Base Rent that would otherwise be due with respect to the next occurring month of the Lease Term for such Phase (the “Landlord Base Rent Abatement Acceleration Election”), in which case Tenant shall have no obligation to pay Base Rent attributable to such next occurring month of the Lease Term for such Phase, and the Base Rent Abatement Amount that is accelerated forward shall no longer be applicable during the Base Rent Abatement Period. Landlord may make such election on a month by month basis with respect to each of the months of the Base Rent Abatement Period. In addition, commencing on the Lease Commencement Date, if Landlord has not exercised the Landlord Base Rent Abatement Acceleration Election on or before the date that the next installment of Base Rent is due under the Lease, and provided that the Lease has not been terminated as a result of any Default of Tenant or rejection of the Lease in bankruptcy (the “Abatement Condition”), then Tenant shall have the right, at Tenant’s option, on a month by month basis commencing on the Lease Commencement Date, to accelerate any Base Rent Abatement Amount relating to a full month during the Base Rent Abatement Period for a Phase forward to apply to the Base Rent that would otherwise be due with respect to the next occurring month of the Lease Term for such Phase (the “Tenant Base Rent Abatement Acceleration Election”), in which case Tenant shall have no obligation to pay Base Rent attributable in such next occurring month of the Lease Term for such Phase, and the Base Rent Abatement Amount that is accelerated forward shall no longer be applicable during the Base Rent Abatement Period. Tenant may not elect to accelerate more than one (1) month of such Base Rent Abatement at any particular time. Notwithstanding the foregoing, as long as the Abatement Condition is satisfied, if Tenant fails to deliver notice to Landlord exercising the Tenant Base Rent Abatement Acceleration Election for a particular month of the Lease Term, then Tenant shall be deemed to have elected to exercise the Tenant Base Rent Abatement Acceleration Election for such month without the requirement of providing notice to Landlord. Notwithstanding the different monetary amount of one (1) full calendar month at the end of the Lease Term from the monetary amount of one (1) full calendar month at the beginning of the Lease Term, the value of any full month of Base Rent Abatement, whether accelerated by Landlord or by Tenant, shall be equal to one (1) full month of Base Rent at the time it is applied.
Sublease Rent Limitation Anything contained in this Lease to the contrary notwithstanding, Lessee shall not sublet the Leased Property on any basis such that the rental to be paid by the sublessee thereunder would be based, in whole or in part, on either (a) the income or profits derived by the business activities of the sublessee, or (b) any other formula such that any portion of the Rent would fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Code, or any similar or successor provision thereto.
Rental Abatement If (a) the Property is damaged by fire or other casualty thereby causing the Premises to be inaccessible or (b) the Premises are partially damaged by fire or other casualty, the Rent shall be proportionally abated to the extent of any actual loss of use of the Premises by Tenant.
Damage; Strike; Casualty Any material damage to, or loss, theft or destruction of, any Property, whether or not insured, or any strike, lockout, labor dispute, embargo, condemnation, act of God or public enemy, or other casualty which causes, for more than 30 consecutive days beyond the coverage period of any applicable business interruption insurance, the cessation or substantial curtailment of revenue producing activities of the Borrower and its Subsidiaries, taken as a whole, and only if any such event or circumstance could reasonably be expected to have a Material Adverse Effect.
Landlords Right to Cure Default Payments by Tenant All covenants and agreements to be kept or performed by Tenant under this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any reduction of rent. If Tenant shall fail to perform any of its obligations under this Lease, within a reasonable time after such performance is required by the terms of this Lease, Landlord may, but shall not be obligated to, after three (3) days prior written notice to Tenant, make any such payment or perform any such act on Tenant’s behalf without waiving its rights based upon any default of Tenant and without releasing Tenant from any obligations hereunder. Tenant shall pay to Landlord, within ten (10) days after delivery by Landlord to Tenant of statements therefore, an amount equal to the expenditures reasonably made by Landlord in connection with the remedying by Landlord of Tenant’s defaults pursuant to the provisions of this Section 14.
Landlord Delay As used herein, (x) “Force Majeure Construction Delay” shall mean acts of God, casualties, natural disasters, strikes, war, terrorist attacks, lockouts, labor disputes or civil commotion, and (y) “Landlord Delay” shall mean a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Lease Termination Except as provided in this Section 9.04, upon expiration or earlier termination of this Lease Tenant shall surrender the Premises to Landlord in the same condition as existed on the date Tenant first occupied the Premises, (whether pursuant to this Lease or an earlier lease), subject to reasonable wear and tear. All Alterations shall become a part of the Premises and shall become the property of Landlord upon the expiration or earlier termination of this Lease, unless Landlord shall, by written notice given to Tenant, require Tenant to remove some or all of Tenant’s Alterations, in which event Tenant shall promptly remove the designated Alterations and shall promptly repair any resulting damage, all at Tenant’s sole expense. All business and trade fixtures, machinery and equipment, furniture, movable partitions and items of personal property owned by Tenant or installed by Tenant at its expense in the Premises shall be and remain the property of Tenant; upon the expiration or earlier termination of this Lease, Tenant shall, at its sole expense, remove all such items and repair any damage to the Premises or the Building caused by such removal. If Tenant fails to remove any such items (“Abandoned Items”) or repair such damage promptly after the expiration or earlier termination of the Lease, Landlord may, but need not, do so with no liability to Tenant, and Tenant shall pay Landlord the cost thereof upon demand. Tenant agrees to indemnify Landlord for any and all loss, cost, damage, liability or expense as incurred (including but not limited to reasonable attorneys’ fees and legal costs) arising out of or related to any claim, suit or judgment brought by or in favor of any person or persons for damage, loss or expense which arises out of, is occasioned by or is in any way attributable to the Abandoned Items. Notwithstanding the foregoing to the contrary, in the event that Landlord gives its consent, pursuant to the provisions of Section 9.01 of this Lease, to allow Tenant to make an Alteration in the Premises, Landlord agrees, upon Tenant’s written request, to notify Tenant in writing at the time of the giving of such consent whether Landlord will require Tenant, at Tenant’s cost, to remove such Alteration at the end of the Lease Term.
Damage by Casualty If during the Term or previous thereto, the Premises shall be destroyed or so damaged by fire or another casualty as to become un-leasable, then, at the option of the Lessor, this Agreement shall terminate from the date of such damage or destruction. The Lessor shall exercise this option to so terminate this Agreement by notice in writing delivered to the Lessee within [#] days after such casualty. Upon such notice, the Lessee shall immediately surrender said Premises and all interest therein to the Lessor, and the Lessee shall pay Rent up until the date of casualty. If the Lessor does not elect to terminate this Agreement, this Agreement shall continue in full force and effect, and the Lessor shall expeditiously repair the Premises, placing the same in as good a condition as they were at the time of the damage or destruction. Rent shall be prorated, taking into account the amount of time the Lessee is unable to occupy the Premises. If the Premises are slightly damaged by fire or another casualty but are still leasable, the Lessor shall expeditiously repair the same with no rent proration. The Lessee may not make a claim for compensation because of any inconvenience or loss of business arising from the necessity of repairing any portion of the building or the Premises.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.