Replacement of Committee Members. (a) Contracting Authority shall be entitled to replace any of its respective representatives on the Works Committee by written Notice to Project Co. Contracting Authority will use commercially reasonable efforts to deliver prior written Notice of any such replacement to Project Co. Project Co may replace any of its representatives on the Works Committee with the prior written consent of Contracting Authority.
Replacement of Committee Members. (a) Infrastructure Ontario and Owner shall be entitled to replace any of their respective representatives on the Work Committee by written notice to the other and to Project Co. Project Co may replace any of is representatives on the Work Committee with the prior written consent of Owner, not to be unreasonably withheld or delayed.
Replacement of Committee Members. (a) Each Committee Member may resign at any time by giving written notice thereof to the Company specifying a date when such resignation will take effect, which notice will be sent at least sixty (60) days prior to the date so specified.
(b) The Company has the right to remove the Company Committee Member at any time by a board resolution specifying a date when such removal will take effect. Acting Holders have the right to remove the Holder Committee Member at any time for Due Cause by written consent or board resolution, as applicable, specifying a date when such removal will take effect. Notice of such removal will be given by the Company to the Company Committee Member or the Holder Committee Member. The Holder Committee Member and the Company Committee Member, acting together, shall have the right to remove the Independent Committee Member at any time by providing written notice to the Independent Committee Member and specifying a date when such removal will take effect.
(c) If the Company Committee Member shall resign, be removed or become incapable of acting, the Company shall promptly appoint a qualified successor Company Committee Member, which may be an officer of the Company or Parent; provided, however, that if a successor Company Committee Member is not appointed by the Company, the vacated Company Committee Member position shall remain vacant until such time as the Company appoints a successor Company Committee Member to such position. If the Holder Committee Member shall resign, be removed, or become incapable of acting, a successor Holder Committee Member shall be appointed in accordance with Exhibit B hereto. If the Independent Committee Member shall resign, be removed, or become incapable of acting, his or her successor shall be appointed by the current Committee Members within thirty (30) days of such resignation, removal or incapacitation. If, within sixty (60) days after such resignation, removal or incapacitation, a successor Independent Committee Member shall not have been appointed, any Holder may, on behalf of himself, herself or itself and all others similarly situated, petition any court of competent jurisdiction for the appointment of a successor Independent Committee Member. The successor Committee Member so appointed shall under the provisions of this Section 2.05(c), forthwith upon his or her acceptance of such appointment in accordance with this Section 2.05(c), become a successor Committee Member.
(d) Every successor appoin...
Replacement of Committee Members. (a) The City shall be entitled to replace any of its respective representatives on the Works Committee by written Notice to Project Co. The City will use commercially reasonable efforts to deliver prior written Notice of any such replacements to Project Co. Project Co may replace any of its representatives on the Works Committee with the prior written consent of the City.
Replacement of Committee Members. (a) HMQ and MAG shall be entitled to replace any of their respective representatives on the Works Committee by written notice to Project Co. HMQ will use commercially reasonable efforts to deliver prior written notice of any such replacements to Project Co. Project Co may replace any of its representatives on the Works Committee with the prior written consent of HMQ, not to be unreasonably withheld or delayed.
Replacement of Committee Members. (a) The College shall be entitled to replace any of its representatives on the Works Committee by written notice to Project Co. The College will use commercially reasonable efforts to deliver prior written notice of any such replacement to Project Co. Project Co may replace any of its representatives on the Works Committee with the prior written consent of the College, not to be unreasonably withheld or delayed.
Replacement of Committee Members. (a) HMQ shall be entitled to replace any of its representatives on the Works Committee by written notice to Project Co. HMQ will use commercially reasonable efforts to deliver prior written notice of any such replacement to Project Co. Project Co may replace any of its representatives on the Works Committee with the prior written consent of HMQ, not to be unreasonably withheld or delayed.
Replacement of Committee Members. (a) IO and HRRH shall be entitled to replace any of their respective representatives on the Facilities Management Committee by written notice to Project Co. HRRH will use commercially reasonable efforts to deliver prior written notice of any such replacement to Project Co. Project Co may replace any of its representatives on the Facilities Management Committee with the prior written consent of HRRH, not to be unreasonably withheld or delayed.
Replacement of Committee Members. (a) IO and the CTC shall be entitled to replace any of their respective representatives on the Works Committee by written notice to Project Co. The CTC will use commercially reasonable efforts to deliver prior written notice of any such replacement to Project Co. Project Co may replace any of its representatives on the Works Committee with the prior written consent of the CTC, not to be unreasonably withheld or delayed.
Replacement of Committee Members. Either Party may remove and replace its designee on the Committee at any time by providing written notice to the other Party.
