SCOPE OF LNTP Sample Clauses

SCOPE OF LNTP. The following activities are in Contractor’s Scope of Work during the period after issuance of the LNTP and prior to issuance of the NTP (the “LNTP Work”). These activities will focus on supporting the critical path schedule and include the following: Any such LNTP Work to be agreed by mutual Change Order. Schedule A-2 FEED Documents Contractor performed front end engineering design (“FEED”) for the Project under the Technical Services Agreement, which resulted in the submittal by Contractor to Owner of the FEED documents which are listed in this Attachment A, Schedule A-2 (“FEED Documents”) and are incorporated by reference into this Agreement and form a part of the Scope of Work. The FEED Documents are fully incorporated into this Agreement as if fully repeated herein. All other drawings, specifications and documents developed under the Technical Services Agreement are expressly excluded from the Agreement. The FEED Documents generally reflect the Work required to be performed by Contractor under the Agreement, but do not reflect all Work required to be performed under the Agreement. Contractor may change the FEED Documents (except the Basis of Design, Scope of Facilities, Codes and Standards Specification and those documents defining the Reimbursable Cost Work) as necessary to meet the MAC, Performance Guarantee and other requirements of the Agreement (including GECP); provided that, under no circumstances shall such changes involve a change in the Liquefaction Facility layout, change in the requirements of Schedule A-1, deletion of or material change to the previously Owner-approved tagged Equipment, reduction of quality in any portion of the Work, change that adversely impacts the safety, performance or materials of construction, or a change that adversely impacts the operability or maintenance of the Liquefaction Facility, the Existing Facility or any component of either facility, unless approved by Owner in writing. With respect to plans that Contractor is required to develop under Attachment A (e.g. Project Execution Plan, Project Engineering Plan, etc.), Contractor may update or deviate from such plans without Owner’s approval (except for those plans under Attachment A that are subject to the Owner’s approval (as specified under Attachment A or Attachment B), then, with respect to those plans, revisions are subject to Owner’s approval rights as may be prescribed in Attachment A or Attachment B). Any deviation in accordance with the immediately pre...
AutoNDA by SimpleDocs
SCOPE OF LNTP. The following activities are in Contractor’s Scope of Work during the period after issuance of the LNTP and prior to issuance of the NTP (the “LNTP Work”). These activities will focus on supporting the critical path schedule and include the following: LNTP No. 1
SCOPE OF LNTP. The following activities are in Contractor’s Scope of Work during the period after issuance of the LNTP and prior to issuance of the NTP (the “LNTP Work”). These activities will focus on supporting the critical path schedule and include the following: Any such LNTP Work to be agreed by mutual Change Order. ATTACHMENT I FORM OF CONTRACTOR’S INVOICES Sabine Pass Liquefaction SCHEDULE I-1 PROJECT NAME: Sabine Pass LNG Stage 3 Liquefaction Project INVOICE NUMBER: 25936- XXXXXX OWNER: Sabine Pass Liquefaction, LLC DATE OF INVOICE: MMM/DD/YYYY CONTRACTOR: Xxxxxxx Oil, Gas, and Chemical, Inc. DATE OF AGREEMENT: MMM/DD/YYYY Contractor hereby makes application for payment to Owner as shown below in connection with the above referenced Agreement between the Parties.

Related to SCOPE OF LNTP

  • Scope of License Except for such rights expressly granted to the Company herein, no license, right, title or interest in or to the Licensed Intellectual Property is granted to the Company or any other entity, either expressly or by implication, estoppel or otherwise.

  • Scope of Use The Fund will use the System and the Data Access Services only for the processing of securities transactions, the keeping of books of account for the Fund and accessing data for purposes of reporting and analysis. The Fund shall not, and shall cause its employees and agents not to (i) permit any unauthorized third party to use the System or the Data Access Services, (ii) sell, rent, license or otherwise use the System or the Data Access Services in the operation of a service bureau or for any purpose other than as expressly authorized under this Addendum, (iii) use the System or the Data Access Services for any fund, trust or other investment vehicle), other than as set forth herein, without the prior written consent of State Street, (iv) allow access to the System or the Data Access Services through terminals or any other computer or telecommunications facilities located outside the Designated Locations, (v) allow or cause any information (other than portfolio holdings, valuations of portfolio holdings, and other information reasonably necessary for the management or distribution of the assets of the Fund) transmitted from State Street’s databases, including data from third party sources, available through use of the System or the Data Access Services to be redistributed or retransmitted to another computer, terminal or other device for other than use for or on behalf of the Fund or (vi) modify the System in any way, including without limitation developing any software for or attaching any devices or computer programs to any equipment, system, software or database which forms a part of or is resident on the Designated Configuration.

  • Scope of Agreement Nothing in this Agreement shall be deemed to entitle Executive to continued employment with the Company or its Subsidiaries, and if Executive’s employment with the Company shall terminate prior to a Change in Control, Executive shall have no further rights under this Agreement (except as otherwise provided hereunder); provided, however, that any termination of Executive’s employment during the Termination Period shall be subject to all of the provisions of this Agreement.

  • Scope of Liability Neither the Servicer or any subservicer appointed by it, nor any of their respective partners, directors, officers, employees or agents, or its delegees pursuant to Section 11.2.1 hereof, shall be under any liability to the Master Servicer, the Trustee or, if applicable, the Trust Administrator for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Servicer, any subservicer or any of their respective partners, directors, officers, employees or agents, or its delegees pursuant to Section 11.2.1 hereof, against any liability which would otherwise be imposed by reason of willful misfeasance, bad faith or gross negligence in the performance of his or its duties or by reason of reckless disregard of his or its obligations and duties hereunder. The Servicer, any subservicer and any of their respective partners, directors, officers, employees or agents, or its delegees pursuant to Section 11.2.1 hereof, may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder.

  • Scope of Engagement Client hereby engages each of Arete and IndieBrokers to act as co-managers of the proposed Offering on a “Best Efforts” basis. Therefore, Client understands that there is no guarantee that the Co-Managers will be able to successfully complete the Offering or successfully assist Client in raising capital and neither Co-Manager has any obligation to purchase or sell any Securities. In addition, Client will be solely responsible for the following:

  • Scope of Cooperation 1) Party A authorizes Party B as the sole distribution agent of the “Case edition” and “Channel edition” of China Marketing and China Business and Trade in the territory of Hunan Province (not including post offices) and Party B is responsible for the distribution matter within such area. Party A will support Party B to achieve a good performance in the regional marketing and promotion and guarantee the legitimate rights and interests of Party B during the term of this agreement.

  • PROCEDURES SPECIFIC TO CUSTOM BASKETS The Fund has developed custom creation, redemption and other non-typical baskets (the “Custom Baskets”). Custom Baskets are intended to allow the Participant to transact in a Fund and other non-standard baskets using the Custom Basket process. The Custom Basket process allows for cash-in-lieu for certain securities as well as non-typical baskets and continues to settle through the standard CNS process at NSCC. It is the responsibility of the Participant to apply to the NSCC by contacting DTCC Participant Services at 000-000-0000 and the Transfer Agent at 000-000-0000 to allow them to receive Custom Baskets as well as the regular daily standard baskets (the “Standard Baskets”). To ensure proper tracking of a Fund to its benchmark index the following guidelines must be followed when transacting Custom Baskets:

  • Scope of Amendment This Amendment supersedes all proposals, oral or written, all negotiations, conversations, or discussions between or among parties relating to the subject matter of this Amendment and all past dealing or industry custom. This Amendment shall be integrated in and form part of the Agreement upon execution. All terms and conditions of the Agreement shall remain unchanged except as expressly modified in this Amendment; and the terms of the Agreement, as modified by this Amendment, are hereby ratified and confirmed. Where the terms of the Agreement conflict with those of this Amendment, however, the terms of this Amendment shall control. This Amendment may be executed in one or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same agreement.

  • Scope of Agency (a) Transfer Agent shall act solely as agent for Fund under this Agreement and owes no duties hereunder to any other person. Transfer Agent undertakes to perform the duties and only the duties that are specifically set forth in this Agreement, and no implied covenants or obligations shall be read into this Agreement against Transfer Agent.

  • Scope of the Agreement The text of this Agreement and all Exhibits, Schedules and Amendments are considered to be the entire agreement between the parties. There are no other understandings or agreements between the parties regarding the policies reinsured other than as expressed in this Agreement. The parties may make changes or additions to this Agreement, but they will not be considered to be in effect unless they are made by means of a written amendment that has been signed and dated by both parties.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!