Scope, Responsibilities, and Services of Design Professional Sample Clauses

Scope, Responsibilities, and Services of Design Professional. 2.1. Design Professional shall render the Services as described in Exhibit A, commencing with receipt of a written Notice to Proceed signed by District representative. Design Professional’s Services will be completed in accordance with the schedule attached as Exhibit C. 2.2. The District intends to award the Project to a design-build entity pursuant to Education Code section 81700 et seq. Design Professional shall not be eligible to participate in the design-build competition for the Project or to perform services on the project as a subconsultant to the design-build entity. 2.3. Design Professional shall provide Services that shall comply with professional architectural or engineering standards, including the standard of care applicable to architects and engineers under California law, designing public school facilities for California community college districts in or around the same geographic area of the District, and applicable requirements of federal, state, and local law, including, but not limited to, the requirements of the California Business and Professions Code, the California Education Code, and the California Code of Regulations. All persons providing professional services hereunder shall be properly licensed as required by California law. 2.4. Design Professional shall contract for or employ at Design Professional’s expense, Consultant(s) to the extent deemed necessary for completion of Criteria Documents for the Project, licensed as such by the State of California as part of the Basic Services under this Agreement. The names of Consultant(s) shall be submitted to District for approval prior to commencement of Services, as indicated below. District reserves the right to reject Design Professional’s use of any particular Consultant. Nothing in the foregoing procedure shall create any contractual relationship between District and any Consultant employed by Design Professional under terms of the Agreement. Design Professional shall require each of the Consultants retained by it to execute agreements with standard of care and indemnity provisions commensurate with the Agreement, but Design Professional shall remain solely responsible and liable to District for all matters covered by this Agreement. 2.5. Design Professional shall coordinate with District personnel or its designated representatives as may be requested and desirable, including with other professionals employed by District for the design, coordination or management of other work rel...
Sample 1
AutoNDA by SimpleDocs

Related to Scope, Responsibilities, and Services of Design Professional

  • Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require. (b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price. (c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work. (d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • The Publisher’s Responsibilities Subject always to the other provisions of this Clause below, the Publisher will undertake the production, publication and distribution of the Contribution and the Work in print and/or electronic form at its own expense and risk within a reasonable time after acceptance of the Work unless the Publisher is prevented from or delayed in doing so due to any circumstances beyond its reasonable control. The Publisher shall have the entire control of such production, publication and distribution determined in its sole discretion in relation to any and all editions and versions of the Contribution and the Work, including in respect of all the following matters: (a) distribution channels, including determination of markets; (b) determination of the range and functions of electronic formats and/or the number of print copies produced; (c) publication and distribution of the Contribution, the Work, or parts thereof as individual content elements, in accordance with market demand or other factors; (d) determination of layout and style as well as the standards for production; (e) setting or altering the list price, and allowing for deviations from the list price (if permitted under applicable jurisdiction); (f) promotion and marketing as the Publisher considers most appropriate. All rights, title and interest, including all intellectual property or related rights in the typography, design and/or look-and-feel of the Contribution shall remain the exclusive property of and are reserved to the Publisher. All illustrations and any other material or tangible or intangible property prepared at the expense of the Publisher including any marketing materials remain, as between the Parties, the exclusive property of the Publisher. The provisions of this subclause shall continue to apply notwithstanding any termination of, and/or any reversion of rights in the Contribution to the Author, under this Agreement. Without prejudice to the Publisher's termination and other rights hereunder including under the Clause "The Author's Responsibilities", it is agreed and acknowledged by the Parties that nothing in this Agreement shall constitute an undertaking on the part of the Publisher to publish the Contribution unless and until: (i) any and all issues in relation to the Work (including all necessary revisions, consents and permissions) raised by the Publisher have been resolved to the Publisher’s satisfaction, and (ii) the Publisher has given written notice of acceptance in writing of the final manuscript of the entire Work to the Editor. If following (i) and (ii) above the Publisher has not published the Contribution in any form within a reasonable period and the Author has given written notice to the Publisher requiring it to publish within a further reasonable period and the Publisher has failed to publish in any form, then the Author may terminate this Agreement by one month's written notice to the Publisher and all rights granted by the Author to the Publisher under this Agreement shall revert to the Author (subject to the provisions regarding any third party rights under any subsisting licence or sub-licence in accordance with the Clause "Termination"). The Author may also give such written notice requiring publication on the same terms as above if the Publisher has published the Contribution but subsequently ceases publishing the Contribution in all forms so that it is no longer available. This shall be the Author's sole right and remedy in relation to such non-publication and is subject always to the Author's continuing obligations hereunder including the Clause "Warranty".

  • Patent Filing Responsibilities and Costs 1. The invention and patent rights herein apply to any patent application or patents covering an invention made under this Agreement. Each Party is responsible for its own costs of obtaining and maintaining patents covering sole inventions of its employees. The Parties may agree otherwise, upon the reporting of any invention (sole or joint) or in any license granted. 2. Partner shall include the following in patent applications for an invention made jointly between NASA employees, its Related Entity employees and Partner employees: The invention described herein may be manufactured and used by or for the U.S. Government for U.S. Government purposes without the payment of royalties thereon or therefore.

  • Licensee Responsibilities Licensee is responsible for Licensee’s Users’ compliance with this Agreement. Licensee is responsible for all of Licensee’s uses and accounts. Licensee will be responsible for maintaining the security of Licensee’s accounts, passwords and files. Licensee and Users cannot share Licensee’s accounts or passwords or allow any third party to use Licensee’s accounts or passwords. Licensee will exercise reasonable precautions to prevent unauthorized use of the Software.

  • Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.

  • Licensee’s Responsibilities Licensee will be responsible for any and all damage to or relocation of existing facilities. Further, Licensee shall reimburse the City for all costs of replacing or repairing any property of the City, or of others, that is damaged by or on behalf of Licensee as a result of activities under this Agreement.

  • Customer Responsibilities Notwithstanding the above, Customer agrees that except as provided by this DPA, Customer is responsible for its secure use of the Services, including securing its account authentication credentials, protecting the security of Customer Data when in transit to and from the Services and taking any appropriate steps to securely encrypt or backup any Customer Data uploaded to the Services.

  • Client Responsibilities You are responsible for (a) assessing each participants’ suitability for the Training, (b) enrollment in the appropriate course(s) and (c) your participants’ attendance at scheduled courses.

  • Facilities and Services The Company shall furnish the Executive with office space, secretarial and support staff, and such other facilities and services as shall be reasonably necessary for the performance of his duties under this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!