Contractor’s Obligations Pursuant to this contract, the Contractor agrees to provide the specific services detailed herein and shall be responsible for the following:
Authority’s Obligations Save as otherwise expressly provided, the obligations of the Authority under the Contract are obligations of the Authority in its capacity as a contracting counterparty and nothing in the Contract shall operate as an obligation upon, or in any other way xxxxxx or constrain the Authority in any other capacity, nor shall the exercise by the Authority of its duties and powers in any other capacity lead to any liability under the Contract (howsoever arising) on the part of the Authority to the Contractor.
City’s Obligations A. Following the execution of this Agreement, the CITY shall begin efforts to implement the activities described in Article I of this Agreement. The failure by the CITY to develop and implement the activities described in Article I of this Agreement shall constitute a breach of this Agreement. The CITY understands and agrees that, in the event termination of this Agreement by CITY, or pursuant to Article V of this Agreement, the CITY shall reimburse the IDC the full amount of money paid by the IDC to the CITY.
B. In accordance with Chapter 2264 of the Texas Government Code, the CITY agrees not to knowingly employ an undocumented worker. During the term of this Agreement, the CITY shall notify the IDC of any complaint brought against CITY alleging that it has employed undocumented workers. If the CITY, or any branch, division or department of the CITY is convicted of a violation under 8 U.S.C. Section 1324a (f), the total amount of economic development grants it has received, together with interest at the rate of five percent (5%), shall be repaid by the CITY to the IDC not later than the one hundred twentieth (120th) day after the date the IDC becomes aware of and notifies the CITY of the violation. The CITY shall not be liable for a violation of Chapter 2264 by a subsidiary, affiliate, or franchisee, or by any person with whom the CITY contracts. The CITY shall reimburse the IDC the required amount within thirty (30) days of the termination of this Agreement. The CITY further certifies that CITY is following Texas Government Code Chapter 2252 (foreign terrorist organizations prohibited), Texas Government Code Chapter 2270 (boycott-Israel), and Texas Government Code Chapter 2274, (boycotts-energy company; discrimination – firearms entity or trade association).
C. The CITY shall keep and maintain complete and accurate records relating to its hiring and employment of persons, which is separate and identifiable from its other records, and shall make such records available for not less than three (3) years following termination of this Agreement. The IDC and its representatives shall be entitled to inspect said records during the term of this Agreement and for three (3) years thereafter, upon reasonable notice to the CITY. The CITY’s failure to comply with this provision will constitute a breach of the Agreement.
TRANSNET’S OBLIGATIONS 8.1 Transnet undertakes to promptly comply with any reasonable request by the Supplier/Service Provider for information, including information concerning Transnet's operations and activities, that relates to the Goods/Services as may be necessary for the Supplier/Service Provider to provide the Goods/Services, but for no other purpose. However, Transnet's compliance with any request for information is subject to any internal security rules and requirements and subject to the observance by the Supplier/Service Provider of its confidentiality obligations under this Agreement.
8.2 The Supplier/Service Provider shall give Transnet reasonable notice of any information it requires.
8.3 Transnet agrees to provide the Supplier/Service Provider or its Personnel such access to and use of its facilities as is necessary to allow the Supplier/Service Provider to perform its obligations under this Agreement.
Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis.
7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason.
7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Licensors Obligations 4.5.1. Xxxxx the Licensee the right to use the intellectual property (the Service) as in the Agreement. Ensure 24/7 availability of the Service, apart from preventive maintenance time.
4.5.2. Keep confidential any information, materials, documents which become available to the Licensee in the course of performance of this Agreement.
4.5.3. Duly publish the official messages (documents) related to the right to use the Service.
Conditions of Agent’s Obligations The obligations of the Agent hereunder are subject to (i) the accuracy of, as of the date hereof, each Bringdown Date, and each Time of Sale (in each case, as if made at such date), and compliance with, all representations, warranties and agreements of the Company contained herein, (ii) the performance by the Company of its obligations hereunder and (iii) the following additional conditions:
(a) If the filing of the Prospectus, or any amendment or supplement thereto, or any Permitted Free Writing Prospectus, is required under the Securities Act or the Rules and Regulations, the Company shall have filed the Prospectus (or such amendment or supplement) or such Permitted Free Writing Prospectus with the Commission in the manner and within the time period so required (without reliance on Rule 424(b)(8) or Rule 164(b)); the Registration Statement shall remain effective; no stop order suspending the effectiveness of the Registration Statement or any part thereof, any Rule 462(b) Registration Statement, or any amendment thereof, nor suspending or preventing the use of the Base Prospectus, the Prospectus or any Permitted Free Writing Prospectus shall have been issued; no proceedings for the issuance of such an order shall have been initiated or threatened; and any request of the Commission for additional information (to be included in the Registration Statement, the Base Prospectus, the Prospectus, any Permitted Free Writing Prospectus or otherwise) shall have been complied with to the Agent's satisfaction.
(b) The Agent shall not have advised the Company that the Registration Statement, the Base Prospectus, the Prospectus, or any amendment or supplement thereto, or any Permitted Free Writing Prospectus, contains an untrue statement of fact which, in the Agent's opinion, is material, or omits to state a fact which, in the Agent's opinion, is material and is required to be stated therein or is necessary to make the statements therein (i) with respect to the Registration Statement, not misleading and (ii) with respect to the Base Prospectus, the Prospectus or any Permitted Free Writing Prospectus, in light of the circumstances under which they were made, not misleading.
(c) Except as set forth or contemplated in the Base Prospectus, the Prospectus and any Permitted Free Writing Prospectus, subsequent to the respective dates as of which information is given therein, the Company shall not have incurred any material liabilities or obligations, direct or contingent, or entered into any material transactions, or declared or paid any dividends or made any distribution of any kind with respect to its capital stock and there shall not have been any change in the capital stock, or any issuance of options, warrants, convertible securities or other rights to purchase the capital stock (other than as a result of the exercise of any currently outstanding options or warrants that are disclosed in the Prospectus), or any material change in the short-term or long-term debt, of the Company, or any Material Adverse Effect or any development that would be reasonably likely to result in a Material Adverse Effect (whether or not arising in the ordinary course of business), or any material loss by strike, fire, flood, earthquake, accident or other calamity, whether or not covered by insurance, incurred by the Company, the effect of which, in any such case described above, in the Agent's judgment, makes it impractical or inadvisable to offer or deliver the Shares.
(d) The Company shall have performed each of its obligations under Section 4(p).
(e) The Company shall have performed each of its obligations under Section 4(q).
(f) The Company shall have performed each of its obligations under Section 4(r).
(g) FINRA shall not have raised any objection to the fairness and reasonableness of the terms and arrangements under this Agreement.
(h) All filings with the Commission required by Rule 424 under the Securities Act to have been filed by the Settlement Date shall have been made within the applicable time period prescribed for such filing by Rule 424.
(i) The Company shall have furnished to Agent and the Agent's counsel such additional documents, certificates and evidence as they may have reasonably requested.
(j) Trading in the Common Shares shall not have been suspended on the NASDAQ Capital Market. The Shares shall have been listed and authorized for trading on the NASDAQ Capital Market prior to the first Settlement Date, and satisfactory evidence of such actions shall have been provided to the Agent and its counsel, which may include oral confirmation from a representative of the NASDAQ Capital Market. All such opinions, certificates, letters and other documents will be in compliance with the provisions hereof only if they are reasonably satisfactory in form and substance to Agent and the Agent's counsel. The Company will furnish Agent with such conformed copies of such opinions, certificates, letters and other documents as Agent shall reasonably request.
Client’s Obligations 4.1 The Client shall:
(a) ensure that the terms of the Order and any other information it provides in the Order Form are complete and accurate;
(b) co-operate with the Company in all matters relating to the Services;
(c) provide the Company, its employees, agents, consultants and subcontractors, with access to the Client’s premises, office accommodation and other facilities as reasonably required by the Company to provide the Services;
(d) provide the Company with such information and materials as the Company may reasonably require in order to supply the Services, and ensure that such information is complete and accurate in all material respects;
(e) prepare the Client’s premises for the supply of the Services;
(f) obtain and maintain all necessary licences, permissions and consents which may be required for the Services before the date on which the Services are to start;
(g) comply with all applicable laws, including health and safety laws; and
(h) keep all materials, equipment, documents and other property of the Company (Company Materials) at the Client’s premises in safe custody at its own risk, maintain the Company Materials in good condition until returned to the Company, and not dispose of or use the Company Materials other than in accordance with the Company’s written instructions or authorisation; and
(i) comply with any additional obligations as set out in the Order Form.
4.2 If the Company’s performance of any of its obligations under the Contract is prevented or delayed by any act or omission by the Client or failure by the Client to perform any relevant obligation (Client Default):
(a) without limiting or affecting any other right or remedy available to it, the Company shall have the right to suspend performance of the Services until the Client remedies the Client Default, and to rely on the Client Default to relieve it from the performance of any of its obligations in each case to the extent the Client Default prevents or delays the Company’s performance of any of its obligations;
(b) the Company shall not be liable for any costs or losses sustained or incurred by the Client arising directly or indirectly from the Company’s failure or delay to perform any of its obligations as set out in this Clause 4.2; and
(c) the Client shall reimburse the Company on written demand for any costs or losses sustained or incurred by the Company arising directly or indirectly from the Client Default.
4.3 The Client shall provide any Client Requirements to the Company in a timely manner in order to enable the Company to provide the Services, including, without limitation, all materials, assets, information and/or documentation of the Client which the Client has agreed to provide or which subsequently becomes necessary to provide in order to allow the Company to provide the Services.
4.4 In the event that the Client should fail to supply the Client Requirements at the time specified or in a timely manner as set out in the above clause 4.3, the Company shall not be held responsible for any consequences of such delays, and the Clients hereby holds harmless the Company from and against all claims, liabilities, losses, costs or expenses arising out of or in connection with such delays.
Obligations of and Services to be Provided by the Sub-Advisor The Sub-Advisor will:
(a) Provide investment advisory services, including but not limited to research, advice and supervision for each Series.
(b) Furnish to the Board of Directors of the Fund for approval (or any appropriate committee of such Board), and revise from time to time as conditions require, a recommended investment program for each Series consistent with each Series investment objective and policies.
(c) Implement the approved investment program by placing orders for the purchase and sale of securities without prior consultation with the Manager and without regard to the length of time the securities have been held, the resulting rate of portfolio turnover or any tax considerations, subject always to the provisions of the Fund's registration statement, Articles of Incorporation and Bylaws and the requirements of the 1940 Act, as each of the same shall be from time to time in effect.
(d) Advise and assist the officers of the Fund, as requested by the officers, in taking such steps as are necessary or appropriate to carry out the decisions of its Board of Directors, and any appropriate committees of such Board, regarding the general conduct of the investment business of each Series.
(e) Maintain, in connection with the Sub-Advisor's investment advisory services obligations, compliance with the 1940 Act and the regulations adopted by the Securities and Exchange Commission thereunder and the Series' investment strategies and restrictions as stated in the Fund's prospectus and statement of additional information.
(f) Report to the Board of Directors of the Fund at such times and in such detail as the Board of Directors may reasonably deem appropriate in order to enable it to determine that the investment policies, procedures and approved investment program of each Series are being observed.
(g) Upon request, provide assistance and recommendations for the determination of the fair value of certain securities when reliable market quotations are not readily available for purposes of calculating net asset value in accordance with procedures and methods established by the Fund's Board of Directors.
(h) Furnish, at its own expense, (i) all necessary investment and management facilities, including salaries of clerical and other personnel required for it to execute its duties faithfully, and (ii) administrative facilities, including bookkeeping, clerical personnel and equipment necessary for the efficient conduct of the investment advisory affairs of each Series.
(i) Open accounts with broker-dealers and futures commission merchants ("broker-dealers"), select broker-dealers to effect all transactions for each Series, place all necessary orders with broker-dealers or issuers (including affiliated broker-dealers), and negotiate commissions, if applicable. To the extent consistent with applicable law, purchase or sell orders for each Series may be aggregated with contemporaneous purchase or sell orders of other clients of the Sub-Advisor. In such event allocation of securities so sold or purchased, as well as the expenses incurred in the transaction, will be made by the Sub-Advisor in the manner the Sub-Advisor considers to be the most equitable and consistent with its fiduciary obligations to the Fund and to other clients. The Sub-Advisor will report on such allocations at the request of the Manager, the Fund or the Fund's Board of Directors providing such information as the number of aggregated trades to which each Series was a party, the broker-dealers to whom such trades were directed and the basis for the allocation for the aggregated trades. The Sub-Advisor shall use its best efforts to obtain execution of transactions for each Series at prices which are advantageous to the Series and at commission rates that are reasonable in relation to the benefits received. However, the Sub-Advisor may select brokers or dealers on the basis that they provide brokerage, research or other services or products to the Sub-Advisor. To the extent consistent with applicable law, the Sub-Advisor may pay a broker or dealer an amount of commission for effecting a securities transaction in excess of the amount of commission or dealer spread another broker or dealer would have charged for effecting that transaction if the Sub-Advisor determines in good faith that such amount of commission is reasonable in relation to the value of the brokerage and research products and/or services provided by such broker or dealer. This determination, with respect to brokerage and research products and/or services, may be viewed in terms of either that particular transaction or the overall responsibilities which the Sub-Advisor and its affiliates have with respect to each Series as well as to accounts over which they exercise investment discretion. Not all such services or products need be used by the Sub-Advisor in managing the Series. In addition, joint repurchase or other accounts may not be utilized by the Series except to the extent permitted under any exemptive order obtained by the Sub-Advisor provided that all conditions of such order are complied with.
(j) Maintain all accounts, books and records with respect to each Series as are required of an investment advisor of a registered investment company pursuant to the 1940 Act and Investment Advisers Act of 1940 (the "Investment Advisers Act"), and the rules thereunder, and furnish the Fund and the Manager with such periodic and special reports as the Fund or Manager may reasonably request. In compliance with the requirements of Rule 31a-3 under the 1940 Act, the Sub-Advisor hereby agrees that all records that it maintains for each Series are the property of the Fund, agrees to preserve for the periods described by Rule 31a-2 under the 1940 Act any records that it maintains for the Series and that are required to be maintained by Rule 31a-1 under the 1940 Act, and further agrees to surrender promptly to the Fund any records that it maintains for a Series upon request by the Fund or the Manager. The Sub-Advisor has no responsibility for the maintenance of Fund records except insofar as is directly related to the services the Sub-Advisor provides to a Series.
(k) Observe and comply with Rule 17j-1 under the 1940 Act and the Sub-Advisor's Code of Ethics adopted pursuant to that Rule as the same may be amended from time to time. The Manager acknowledges receipt of a copy of Sub-Advisor's current Code of Ethics. Sub-Advisor shall promptly forward to the Manager a copy of any material amendment to the Sub-Advisor's Code of Ethics along with certification that the Sub-Advisor has implemented procedures for administering the Sub-Advisor's Code of Ethics.
(l) From time to time as the Manager or the Fund may request, furnish the requesting party reports on portfolio transactions and reports on investments held by a Series, all in such detail as the Manager or the Fund may reasonably request. The Sub-Advisor will make available its officers and employees to meet with the Fund's Board of Directors at the Fund's principal place of business on due notice to review the investments of a Series.
(m) Provide such information as is customarily provided by a sub-advisor and may be required for the Fund or the Manager to comply with their respective obligations under applicable laws, including, without limitation, the Internal Revenue Code of 1986, as amended (the "Code"), the 1940 Act, the Investment Advisers Act, the Securities Act of 1933, as amended (the "Securities Act"), and any state securities laws, and any rule or regulation thereunder.
(n) Perform quarterly and annual tax compliance tests to monitor each Series' compliance with Subchapter M of the Code. The Sub-Advisor shall notify the Manager immediately upon having a reasonable basis for believing that a Series has ceased to be in compliance or that it might not be in compliance in the future. If it is determined that a Series is not in compliance with the requirements noted above, the Sub-Advisor, in consultation with the Manager, will take prompt action to bring the Series back into compliance (to the extent possible) within the time permitted under the Code.
(o) Provide a copy of the Sub-Advisor's Form ADV and any amendments thereto contemporaneously with the filing of such documents with the Securities and Exchange Commission or other regulatory agency.
